Common use of Key Persons Clause in Contracts

Key Persons. Contractor acknowledges and agrees that Agency selected Contractor, and is entering into this Contract, because of the special qualifications of Contractor's key persons identified in the Statement of Work (each a “Key Person” and, together, “Key Persons”). Neither Contractor nor a Key Person may delegate performance of the powers and responsibilities that a Key Person is required to provide under this Contract to another Contractor employee, subcontractor or agent without first obtaining the written consent of Agency. Further, Contractor may not re-assign or transfer a Key Person to other duties or positions such that the Key Person is no longer available to provide the Agency with the required expertise, experience, judgment, and personal attention, without first obtaining Agency's written consent to such re-assignment or transfer, which Agency will not unreasonably withhold or delay. Notwithstanding the foregoing, Contractor may replace a Key Person in the event the Key Person is no longer available due to circumstances beyond Contractor’s reasonable control, such as death, illness, or termination of employment with Contractor. In the event Contractor requests that Agency approve a re-assignment or transfer of a Key Person, or if Contractor must replace a Key Person, Agency may interview, review the qualifications of, and approve or reject the proposed replacement for the Key Person. Any such replacement must have substantially equivalent or better qualifications than the Key Person being replaced. Any replacement personnel approved by Agency in writing (email acceptable) will thereafter be deemed a Key Person for purposes of this Contract, and the Statement of Work will be deemed amended to include such Key Person.

Key Persons. Contractor acknowledges and agrees that Agency selected Contractor, and is entering into this Contract, because of the special qualifications of Contractor's key persons identified in the Statement of Work (each a “Key Person” and, together, “Key Persons”). Neither Contractor nor a Key Person may delegate performance of the powers and responsibilities that a Key Person is required to provide under this Contract to another Contractor employee, subcontractor or agent without first obtaining the written consent of Agency. Further, Contractor may not re-assign or transfer a Key Person to other duties or positions such that the Key Person is no longer available to provide the Agency with the required expertise, experience, judgment, and personal attention, without first obtaining Agency's written consent to such re-re- assignment or transfer, which Agency will not unreasonably withhold or delay. Notwithstanding the foregoing, Contractor may replace a Key Person in the event the Key Person is no longer available due to circumstances beyond Contractor’s reasonable control, such as death, illness, or termination of employment with Contractor. In the event Contractor requests that Agency approve a re-assignment or transfer of a Key Person, or if Contractor must replace a Key Person, Agency may interview, review the qualifications of, and approve or reject the proposed replacement for the Key Person. Any such replacement must have substantially equivalent or better qualifications than the Key Person being replaced. Any replacement personnel approved by Agency in writing (email acceptable) will thereafter be deemed a Key Person for purposes of this Contract, and the Statement of Work will be deemed amended to include such Key Person.

Key Persons. Contractor acknowledges and agrees that Agency selected Contractor, and is entering into this Contract, because of the special qualifications of Contractor's key persons identified in the Statement of Work (each a “Key Person” and, together, “Key Persons”). Neither Contractor nor a Key Person may delegate performance of the powers and responsibilities that a Key Person is required to provide under this Contract to another Contractor employee, subcontractor or agent without first obtaining the written consent of Agency. Further, Contractor may not re-assign or transfer a Key Person to other duties or positions such that the Key Person is no longer available to provide the Agency with the required expertise, experience, judgment, and personal attention, without first obtaining Agency's written consent to such re-assignment or transfer, which Agency will not unreasonably withhold or delay. Notwithstanding the foregoing, Contractor may replace a Key Person in the event the Key Person is no longer available due to circumstances beyond Contractor’s reasonable control, such as death, illness, or termination of employment with Contractor. In the event Contractor requests that Agency approve a re-re- assignment or transfer of a Key Person, or if Contractor must replace a Key Person, Agency may interview, review the qualifications of, and approve or reject the proposed replacement for the Key Person. Any such replacement must have substantially equivalent or better qualifications than the Key Person being replaced. Any replacement personnel approved by Agency in writing (email acceptable) will thereafter be deemed a Key Person for purposes of this Contract, and the Statement of Work will be deemed amended to include such Key Person.

Key Persons. Contractor acknowledges and agrees that Agency selected Contractor, and is entering into this ContractPrice Agreement, because of the special qualifications of Contractor's key persons identified in the Statement of Work (each a “Key Person” and, together, “Key Persons”). Neither Contractor nor a Key Person may delegate performance of the powers and responsibilities that a Key Person is required to provide under this Contract Price Agreement to another Contractor employee, subcontractor or agent without first obtaining the written consent of Agency. Further, Contractor may not re-assign or transfer a Key Person to other duties or positions such that the Key Person is no longer available to provide the Agency with the required expertise, experience, judgment, and personal attention, without first obtaining Agency's written consent to such re-assignment or transfer, which Agency will not unreasonably withhold or delay. Notwithstanding the foregoing, Contractor may replace a Key Person in the event the Key Person is no longer available due to circumstances beyond Contractor’s reasonable control, such as death, illness, or termination of employment with Contractor. In the event Contractor requests that Agency approve a re-assignment or transfer of a Key Person, or if Contractor must replace a Key Person, Agency may interview, review the qualifications of, and approve or reject the proposed replacement for the Key Person. Any such replacement must have substantially equivalent or better qualifications than the Key Person being replaced. Any replacement personnel approved by Agency in writing (email acceptable) will thereafter be deemed a Key Person for purposes of this ContractPrice Agreement, and the Statement of Work will be deemed amended to include such Key Person.

Key Persons. Contractor acknowledges and agrees that Agency selected Contractor, and is entering into this Contract, because of the special qualifications of Contractor's key persons identified in the Statement of Work (each a “Key Person” and, together, “Key Persons”). Neither Contractor nor a Key Person may delegate performance of the powers and responsibilities that a Key Person is required to provide under this Contract to another Contractor employee, subcontractor or agent without first obtaining the written consent of Agency. Further, Contractor may not re-assign or transfer a Key Person to other duties or positions such that the Key Person is no longer available to provide the Agency with the required expertise, experience, judgment, and personal attention, without first obtaining Agency's written consent to such re-assignment or transfer, which Agency will not unreasonably withhold or delay. Notwithstanding the foregoing, Contractor may replace a Key Person in the event the Key Person is no longer available due to circumstances beyond Contractor’s reasonable control, such as death, illness, or termination of employment with Contractor. In the event Contractor requests that Agency approve a re-assignment or transfer of a Key Person, or if Contractor must replace a Key Person, Agency may interview, review the qualifications of, and approve or reject the proposed replacement for the Key Person. Any such replacement must have substantially equivalent or better qualifications than the Key Person being replaced. Any replacement personnel approved by Agency in writing (email acceptable) will thereafter be deemed a Key Person for purposes of this Contract, and the Statement of Work will be deemed amended to include such Key Person.

Key Persons. Contractor acknowledges and agrees that Agency selected Contractor, and is entering into this Contract, because of the special qualifications of Contractor's key persons identified in the Statement of Work (each a “Key Person” and, together, “Key Persons”). Neither Contractor nor a Key Person may delegate performance of the powers and responsibilities that a Key Person is required to provide under this Contract to another Contractor employee, subcontractor subcontractor, or agent without first obtaining the written consent of Agency. Further, Contractor may not re-assign or transfer a Key Person to other duties or positions such that the Key Person is no longer available to provide the Agency with the required expertise, experience, judgment, and personal attention, without first obtaining Agency's written consent to such re-re- assignment or transfer, which Agency will not unreasonably withhold or delay. Notwithstanding the foregoing, Contractor may replace a Key Person in the event the Key Person is no longer available due to circumstances beyond Contractor’s reasonable control, such as death, illness, or termination of employment with Contractor. In the event Contractor requests that Agency approve a re-assignment or transfer of a Key Person, or if Contractor must replace a Key Person, Agency may interview, review the qualifications of, and approve or reject the proposed replacement for the Key Person. Any such replacement must have substantially equivalent or better qualifications than the Key Person being replaced. Any replacement personnel approved by Agency in writing (email acceptable) will thereafter be deemed a Key Person for purposes of this Contract, and the Statement of Work will be deemed amended to include such Key Person.

Key Persons. Contractor Consultant acknowledges and agrees that Agency selected ContractorConsultant, and is entering into this Contract, because of the special qualifications of ContractorConsultant's key persons identified in the Statement of Work (each a “Key Person” and, together, “Key Persons”). Neither Contractor Consultant nor a Key Person may delegate performance of the powers and responsibilities that a Key Person is required to provide under this Contract to another Contractor Consultant employee, subcontractor or agent without first obtaining the written consent of Agency. Further, Contractor Consultant may not re-assign or transfer a Key Person to other duties or positions such that the Key Person is no longer available to provide the Agency with the required expertise, experience, judgment, and personal attention, without first obtaining Agency's written consent to such re-re- assignment or transfer, which Agency will not unreasonably withhold or delay. Notwithstanding the foregoing, Contractor Consultant may replace a Key Person in the event the Key Person is no longer available due to circumstances beyond ContractorConsultant’s reasonable control, such as death, illness, or termination of employment with ContractorConsultant. In the event Contractor Consultant requests that Agency approve a re-assignment or transfer of a Key Person, or if Contractor Consultant must replace a Key Person, Agency may interview, review the qualifications of, and approve or reject the proposed replacement for the Key Person. Any such replacement must have substantially equivalent or better qualifications than the Key Person being replaced. Any replacement personnel approved by Agency in writing (email acceptable) will thereafter be deemed a Key Person for purposes of this Contract, and the Statement of Work will be deemed amended to include such Key Person.

Key Persons. Contractor acknowledges and agrees that Agency selected Contractor, and is entering into this Contract, because of the special qualifications of Contractor's ’s key persons identified in the Statement of Work (each a “Key Person” and, together, “Key Persons”). Neither Contractor nor a Key Person may delegate performance of the powers and responsibilities that a Key Person is required to provide under this Contract to another Contractor employee, subcontractor or agent without first obtaining the written consent of Agency. Further, Contractor may not re-assign or transfer a Key Person to other duties or positions such that the Key Person is no longer available to provide the Agency with the required expertise, experience, judgment, and personal attention, without first obtaining Agency's written consent to such re-re- assignment or transfer, which Agency will not unreasonably withhold or delay. Notwithstanding the foregoing, Contractor may replace a Key Person in the event the Key Person is no longer available due to circumstances beyond Contractor’s reasonable control, such as death, illness, or termination of employment with Contractor. In the event Contractor requests that Agency approve a re-assignment or transfer of a Key Person, or if Contractor must replace a Key Person, Agency may interview, review the qualifications of, and approve or reject the proposed replacement for the Key Person. Any such replacement must have substantially equivalent or better qualifications than the Key Person being replaced. Any replacement personnel approved by Agency in writing (email acceptable) will thereafter be deemed a Key Person for purposes of this Contract, and the Statement of Work will be deemed amended to include such Key Person.

Key Persons. Contractor acknowledges and agrees that Agency selected Contractor, and is entering into this Contract, because of the special qualifications of Contractor's key persons identified in the Statement of Work (each a “Key Person” and, together, “Key Persons”). Neither Contractor nor a Key Person may delegate performance of the powers and responsibilities that a Key Person is required to provide under this Contract to another Contractor contractor employee, subcontractor subcontractor, or agent without first obtaining the written consent of Agency. Further, Contractor may not re-assign or transfer a Key Person to other duties or positions such that the Key Person is no longer available to provide the Agency with the required expertise, experience, judgment, and personal attention, without first obtaining Agency's written consent to such re-re- assignment or transfer, which Agency will not unreasonably withhold or delay. Notwithstanding the foregoing, Contractor may replace a Key Person in the event the Key Person is no longer available due to circumstances beyond Contractor’s reasonable control, such as death, illness, or termination of employment with Contractor. In the event Contractor requests that Agency approve a re-assignment or transfer of a Key Person, or if Contractor must replace a Key Person, Agency may interview, review the qualifications of, and approve or reject the proposed replacement for the Key Person. Any such replacement must have substantially equivalent or better qualifications than the Key Person being replaced. Any replacement personnel approved by Agency in writing (email acceptable) will thereafter be deemed a Key Person for purposes of this Contract, and the Statement of Work will be deemed amended to include such Key Person.

Key Persons. Contractor acknowledges and agrees that Agency selected Contractor, and is entering into this Contract, because of the special qualifications of Contractor's key persons identified in the Statement of Work (each a “Key Person” and, together, “Key Persons”). Neither Contractor nor a any Key Person may delegate performance of the powers and responsibilities that a Key Person is required to provide under this Contract to another Contractor employee, subcontractor or agent without first obtaining the written consent of Agency. Further, Contractor may not re-assign or transfer a Key Person to other duties or positions such that the Key Person is no longer available to provide the Agency with the required expertise, experience, judgment, and personal attention, without first obtaining Agency's written consent to such re-re- assignment or transfer, which Agency will not unreasonably withhold or delay. Notwithstanding the foregoing, Contractor may replace a Key Person in the event the Key Person is no longer available due to circumstances beyond Contractor’s reasonable control, such as death, illness, or termination of employment with Contractor. In the event Contractor requests that Agency approve a re-assignment or transfer of a Key Person, or if Contractor must replace a Key Person, Agency may interview, review the qualifications of, and approve or reject the proposed replacement for the Key Person. Any such replacement must have substantially equivalent or better qualifications than the Key Person being replaced. Any replacement personnel approved by Agency in writing (email acceptable) will thereafter be deemed a Key Person for purposes of this Contract, and the Statement of Work will be deemed amended to include such Key Person.

Key Persons. Contractor acknowledges and agrees that Agency District selected Contractor, and is entering into this ContractAgreement, because of the special qualifications of Contractor's key persons identified in the Statement of Work (each a “Key Person” and, together, “Key Persons”). Neither Contractor nor a Key Person may delegate performance of the powers and responsibilities that a Key Person is required to provide under this Contract Agreement to another Contractor employee, subcontractor or agent without first obtaining the written consent of AgencyDistrict. Further, Contractor may not re-assign or transfer a Key Person to other duties or positions such that the Key Person is no longer available to provide the Agency District with the required expertise, experience, judgment, and personal attention, without first obtaining AgencyDistrict's written consent to such re-assignment or transfer, which Agency District will not unreasonably withhold or delay. Notwithstanding the foregoing, Contractor may replace a Key Person in the event the Key Person is no longer available due to circumstances beyond Contractor’s reasonable control, such as death, illness, or termination of employment with Contractor. In the event Contractor requests that Agency District approve a re-re- assignment or transfer of a Key Person, or if Contractor must replace a Key Person, Agency District may interview, review the qualifications of, and approve or reject the proposed replacement for the Key Person. Any such replacement must have substantially equivalent or better qualifications than the Key Person being replaced. Any replacement personnel approved by Agency District in writing (email acceptable) will thereafter be deemed a Key Person for purposes of this ContractAgreement, and the Statement of Work will be deemed amended to include such Key Person.

Key Persons. Contractor acknowledges and agrees that Agency selected Contractor, and is entering into this ContractPrice Agreement, because of the special qualifications of Contractor's key persons identified in the Statement of Work (each a “Key Person” and, together, “Key Persons”). Neither Contractor nor a Key Person may delegate performance of the powers and responsibilities that a Key Person is required to provide under this Contract Price agreement to another Contractor employee, subcontractor or agent without first obtaining the written consent of Agency. Further, Contractor may not re-assign or transfer a Key Person to other duties or positions such that the Key Person is no longer available to provide the Agency with the required expertise, experience, judgment, and personal attention, without first obtaining Agency's written consent to such re-assignment or transfer, which Agency will not unreasonably withhold or delay. Notwithstanding the foregoing, Contractor may replace a Key Person in the event the Key Person is no longer available due to circumstances beyond Contractor’s reasonable control, such as death, illness, or termination of employment with Contractor. In the event Contractor requests that Agency approve a re-re- assignment or transfer of a Key Person, or if Contractor must replace a Key Person, Agency may interview, review the qualifications of, and approve or reject the proposed replacement for the Key Person. Any such replacement must have substantially equivalent or better qualifications than the Key Person being replaced. Any replacement personnel approved by Agency in writing (email acceptable) will thereafter be deemed a Key Person for purposes of this ContractPrice Agreement, and the Statement of Work will be deemed amended to include such Key Person.