Issuer to Pursue Remedies Sample Clauses

Issuer to Pursue Remedies. Against Suppliers, Contractors -------------------------------------------------------- and Subcontractors and Their Sureties. At the direction and sole cost of the ------------------------------------- Company (to the extent that such cost is not payable and actually paid from the Project Fund), the Issuer will promptly proceed, either separately or in conjunction with others, to exhaust the remedies of the Issuer against any defaulting supplier, contractor or subcontractor and against any surety therefor, for the performance of any contract made in connection with the Project. If the Company shall so notify the Issuer, the Company may, in its own name or in the name of the Issuer, prosecute or defend any action or proceeding or take any other action involving any such supplier, contractor, subcontractor or surety which the Company deems reasonably necessary, and in such event the Issuer agrees to cooperate fully with the Company and to take all action necessary, to the extent it might lawfully do so, to effect the substitution of the Company for the Issuer in any such action or proceeding. Any moneys recovered by way of damages, refunds, adjustments or otherwise in connection with the foregoing prior to the Completion Date shall be paid into the Project Fund and after the Completion Date shall be used as authorized by Section 4.3.
Sample 1Sample 2Sample 3
AutoNDA by SimpleDocs

Related to Issuer to Pursue Remedies

  • Failure to Pursue Remedies The failure of any party to seek redress for violation of, or to insist upon the strict performance of, any provision of this Agreement shall not prevent a subsequent act, which would have originally constituted a violation, from having the effect of an original violation.

  • Defaults Remedies (a) It shall be an Event of Default:

  • Events of Default Remedies If any of the following events (“Events of Default”) shall occur:

  • Additional Remedies of Trustee Upon Event of Default During the continuance of any Event of Default, so long as such Event of Default shall not have been remedied, the Trustee, in addition to the rights specified in Section 6.14, shall have the right, in its own name and as trustee of the Trust Fund, to take all actions now or hereafter existing at law, in equity or by statute to enforce its rights and remedies and to protect the interests, and enforce the rights and remedies, of the Certificateholders (including the institution and prosecution of all judicial, administrative and other proceedings and the filings of proofs of claim and debt in connection therewith). Except as otherwise expressly provided in this Agreement, no remedy provided for by this Agreement shall be exclusive of any other remedy, and each and every remedy shall be cumulative and in addition to any other remedy, and no delay or omission to exercise any right or remedy shall impair any such right or remedy or shall be deemed to be a waiver of any Event of Default.

  • Events of Default Rights and Remedies Section 7.1 Events of Default Section 7.2 Rights and Remedies Section 7.3 Certain Notices

  • Defaults and Remedies Section 6.01.

  • UCC Remedies (a) Upon the occurrence of and during the continuance of an Event of Default under this Agreement or the other Financing Documents, Agent, in addition to all other rights, options, and remedies granted to Agent under this Agreement or at law or in equity, may exercise, either directly or through one or more assignees or designees, all rights and remedies granted to it under all Financing Documents and under the UCC in effect in the applicable jurisdiction(s) and under any other applicable law; including, without limitation:

  • REMEDIES IN EVENT OF DEFAULT Upon the occurrence of an Event of Default, at the option of Lessor, which may be exercised at any time after an Event of Default shall have occurred, Lessor shall have all rights and remedies available to it, at law or in equity, including, without limitation, all of the rights and remedies under the Facility Lease and the other Lease Documents. Subject to the requirements f applicable law, all materials at that time on or near the Leased Property which are the property of Lessee and which are to be used in connection with the completion of the Project shall be subject to the Liens created by the Lease Documents. In addition to, and without limitation of, the foregoing, Lessor is authorized to charge all money expended for completion the Project against sums hereunder which have not already been advanced (even if the aggregate amount of such sums expended and all amounts previously advanced hereunder exceed the amount of the Project Funds which Lessor has agreed to advance hereunder); and Lessee agrees to pay to Lessor Rent under the Facility Lease calculated, in part, thereunder based upon all sums advanced hereunder, including, without limitation, all sums expended in good faith by Lessor in connection with the completion of the project), and, in addition thereto, Lessee agrees to pay to Lessor (as Rent under the Facility Lease), for services in connection with said completion of the Project, such additional sums as shall compensate Lessor for the time and effort Lessor and its employees shall have expended in connection therewith. Lessor is authorized, but not obligated in any event, to do all such things in connection with the construction of the Project as Lessor, in its sole and absolute discretion, may deem advisable, including, without limitation, the right to make any payments with respect to any obligation of Lessee to Lessor or to any other Person in connection with the completion of construction of the Project and to make additions and changes in the Project Plans, to employ contractors, subcontractors and agents and to take any and all such action, either in Lessor's own name or in the name of Lessee, and Lessee hereby grants Lessor an irrevocable power of attorney to act in its name in connection with the foregoing. This power of attorney, being coupled with an interest, shall be irrevocable until all of the Obligations are fully paid and performed and shall not be affected by any disability or incapacity which Lessee may suffer and shall survive the same. The power of attorney conferred on Lessor by the provisions of this Section 11 is provided solely to protect the interests of Lessor and shall not impose any duty on Lessor to exercise any such power and neither Lessor nor such attorney-in-fact shall be liable for any act, omission, error in judgment or mistake of law, except as the same may result from its gross negligence or wilful misconduct. In the event that Lessor takes possession of the Leased Property and assumes control of the project as aforesaid, it shall not be obligated to continue the construction of the Project and/or the operation of the Project for any period of time longer than Lessor shall see fit (in its sole and absolute discretion), and Lessor may thereafter, at any time, abandon its efforts and refuse to make further payments for the account of Lessee, whether or not the Project has been completed. In addition, at Lessor's option and without demand, notice or protest, the occurrence of any Event of Default shall also constitute a default under any one or more of the Related Party Agreements.

  • Events of Default and Remedies Section 8.01

  • Acceleration; Remedies Upon the occurrence and during the continuance of an Event of Default, then, and in any such event, (a) if such event is a Bankruptcy Event, automatically the Commitments shall immediately terminate and the Loans (with accrued interest thereon), and all other amounts under the Credit Documents (including, without limitation, the maximum amount of all contingent liabilities under Letters of Credit) shall immediately become due and payable, and (b) if such event is any other Event of Default, any or all of the following actions may be taken: (i) with the written consent of the Required Lenders, the Administrative Agent may, or upon the written request of the Required Lenders, the Administrative Agent shall, declare the Commitments to be terminated forthwith, whereupon the Commitments shall immediately terminate; (ii) the Administrative Agent may, or upon the written request of the Required Lenders, the Administrative Agent shall, declare the Loans (with accrued interest thereon) and all other amounts owing under this Agreement and the Notes to be due and payable forthwith and direct the Borrower to pay to the Administrative Agent cash collateral as security for the LOC Obligations for subsequent drawings under then outstanding Letters of Credit an amount equal to the maximum amount of which may be drawn under Letters of Credit then outstanding, whereupon the same shall immediately become due and payable; and/or (iii) with the written consent of the Required Lenders, the Administrative Agent may, or upon the written request of the Required Lenders, the Administrative Agent shall, exercise such other rights and remedies as provided under the Credit Documents and under applicable law.

Time is Money Join Law Insider Premium to draft better contracts faster.