Approval Process Tenant shall notify Landlord whether it approves of the submitted working drawings within three business days after Landlord’s submission thereof. If Tenant disapproves of such working drawings, then Tenant shall notify Landlord thereof specifying in reasonable detail the reasons for such disapproval, in which case Landlord shall, within five business days after such notice, revise such working drawings in accordance with Tenant’s objections and submit the revised working drawings to Tenant for its review and approval. Tenant shall notify Landlord in writing whether it approves of the resubmitted working drawings within one business day after its receipt thereof. This process shall be repeated until the working drawings have been finally approved by Landlord and Tenant. If Tenant fails to notify Landlord that it disapproves of the initial working drawings within three business days (or, in the case of resubmitted working drawings, within one business day) after the submission thereof, then Tenant shall be deemed to have approved the working drawings in question. Any delay caused by Tenant’s unreasonable withholding of its consent or delay in giving its written approval as to such working drawings shall constitute a Tenant Delay Day (defined below). If the working drawings are not fully approved (or deemed approved) by both Landlord and Tenant by the 15th business day after the delivery of the initial draft thereof to Tenant, then each day after such time period that such working drawings are not fully approved (or deemed approved) by both Landlord and Tenant shall constitute a Tenant Delay Day.
Final Approval Order 62. The Parties shall jointly seek entry of a Final Approval Order, the text of which the Parties shall agree upon. The dismissal orders, motions or stipulation to implement this Section shall, among other things, seek or provide for a dismissal with prejudice and waiving any rights of appeal.
Final Approval After Acceptance, Engineer shall perform any required modifications, changes, alterations, corrections, redesigns, and additional work necessary to receive Final Approval by the County. "Final Approval" in this sense shall mean formal recognition that the Engineering Services have been fully carried out.
Final Approval Hearing “Final Approval Hearing” shall mean the hearing at which the Court will consider and finally decide whether to enter the Final Judgment.
Inspection Testing Authorization and Right of Access 2.1 Equipment Testing and Inspection 2.2 Authorization Required Prior to Parallel Operation
Bidding Process 3.1. Bidding shall generally commence based on the sequence of the lot being shown on the PAH Website. However the Auctioneer has the right to vary the sequence without having to give prior notice to the intended bidders.
New Project Approval Consultant and District recognize that Consultant’s Services may include working on various projects for District. Consultant shall obtain the approval of District prior to the commencement of a new project.
Project Approval The County may issue a Job Order Authorization for the Work, to include the firm-fixed-price of the Job Order and the project duration. Contractor agrees that all clauses of this Contract are applicable to any Job Order issued hereunder. The County reserves the right to reject a Contractor’s Quote based on unjustifiable quantities and/or methods, performance periods, inadequate documentation, or other inconsistencies or deficiencies on the Contractor’s part in the sole opinion of the County. The County reserves the right to issue a unilateral Job Order authorization for the Work if a Quote price cannot be mutually agreed upon. This is based upon unjustifiable quantities in the sole opinion of the County. The County also reserves the right to not issue a Job Order Authorization if the County’s requirement is no longer valid or the project is not funded. In these instances, the Contractor has no right of claim to recover Quote expenses. The County may pursue continuing valid requirements by other means where Contract was not reached with the Contractor.
Required Regulatory Approvals Certain transactions required, permitted or otherwise contemplated by this Agreement may under certain circumstances require prior filings with and approvals, or non-disapprovals, from the Indiana Department of Insurance or the Indiana Insurance Commissioner. Such transactions include: (a) issuance or purchase of any additional capital stock of the Company or other securities convertible into or exchangeable or exercisable for capital stock of the Company pursuant to Sections 1.2 or 3.4; (b) transfer of Shares to a wholly owned subsidiary of a Shareholder, to another Shareholder or to a wholly owned subsidiary of another Shareholder pursuant to Sections 3.1(a) or 3.4; (c) exercise of preemptive rights by a Shareholder pursuant to Section 3.2; and (d) exercise of call rights by the Company or a Shareholder pursuant to Section 3.3 (including pursuant to the two provisos in Section 3.1(b)). Notwithstanding anything to the contrary contained in this Agreement, any such transactions requiring filings with and approvals, or non-disapprovals, from the Indiana Department of Insurance or the Indiana Insurance Commissioner shall not, to the extent within the control of a party hereto, be entered into or consummated unless and until the required filings have been made and the required approvals (or non-disapprovals) have been obtained, and to the extent not within the control of an applicable party hereto, such party shall use best efforts to cause such transactions not to be entered into or consummated unless and until the required filings have been made and the required approvals (or non-disapprovals) have been obtained.
Approval of Plans and Specifications The Plans and Specifications will conform to the requirements and conditions set out by applicable law or any effective restrictive covenant, and to all governmental authorities which exercise jurisdiction over the Leased Premises or the construction thereon.
