Indemnification by Licensee Licensee shall defend, indemnify and hold harmless Licensor and its Affiliates, and their respective officers, directors, employees, agents, shareholders, successors and assigns, (collectively, the “Licensor Parties”) from and against any Action, and any and all direct losses suffered or incurred by Licensor in connection with any third party claims (a) arising out of or resulting from any breach by Licensee of any provision of this Agreement, (b) regarding the Content (other than Licensed Content) of the websites associated with Licensed Domain Names, or (c) regarding any Content that was subject to a request for removal by a Governmental Authority, even if Licensee removes such Content within the time period proscribed by the Governmental Authority, provided that, in all cases, Licensee shall not be liable for any direct losses suffered or incurred by Licensor as a result of Licensor’s failure to provide Licensee with a reasonable period of time to remove Content in cases where (i) the basis or nature of the offense has not previously been identified by any Governmental Authority as offensive or inappropriate and (ii) Licensee has not also received notice from the Governmental Authority. Licensee’s obligation to indemnify Licensor shall be conditioned on (x) Licensor’s provision to Licensee of prompt notice of such an Action (except where any delay does not materially prejudice Licensee); (y) Licensor’s reasonable cooperation with Licensee in the defense and settlement of such an Action at Licensee’s cost; and (z) Licensee having exclusive control of the defense, settlement and/or compromise of such an Action (provided that Licensee may not settle any Action in a manner that adversely affects Licensor without Licensor’s prior written consent, not to be unreasonably withheld or delayed).
PATENT INDEMNIFICATION The Contractor agrees to assume the defense of and shall indemnify and save harmless the Owner and all persons acting for or on behalf of it from all suits and claims against them, or any of them, arising from or occasioned by the use of any material, Equipment or apparatus, or any part thereof which infringes or is alleged to infringe on any patent rights. In case such material, equipment or apparatus, or any part thereof, in any such suit is held to constitute infringement, the Contractor, within a reasonable time, shall at its own expense, and as the Owner may elect, replace such material, Equipment or apparatus with non-infringing material, Equipment or apparatus, or remove the material, equipment, or apparatus and refund the sums paid therefor.
Indemnification for Suits or Claims for Intellectual Property Infringement The Contractor shall indemnify and hold the Owner harmless from any suits or claims of infringement of any patent rights, trademarks or copyrights arising out of any patented, trademarked, or copyrighted materials, methods, or systems used by the Contractor.
Licensee Indemnification Licensee will indemnify, defend and hold harmless UM, its trustees, officers, agents and employees (collectively, the “Indemnified Parties”), from and against any and all liability, loss, damage, action, claim or expense suffered or incurred by the Indemnified Parties which results from or arises out of third party claims in connection with (individually, a “Liability” and collectively, the “Liabilities”):
Indemnification by Client Client shall indemnify and hold Dalmore, its affiliates and their representatives and agents harmless from, any and all actual or direct losses, liabilities, judgments, arbitration awards, settlements, damages and costs (collectively, “Losses”), resulting from or arising out of any third party suits, actions, claims, demands or similar proceedings (collectively, “Proceedings”) to the extent they are based upon (i) a breach of this Agreement by Client, (ii) the wrongful acts or omissions of Client, or (iii) the Offering.
Infringement Indemnification If notified promptly in writing of any judicial action brought against City based on an allegation that City’s use of the Licensed Software infringes a patent, copyright, or any right of a third party or constitutes misuse or misappropriation of a trade secret or any other right in intellectual property (Infringement), Contractor will hold City harmless and defend such action at its own expense. Contractor will pay the costs and damages awarded in any such action or the cost of settling such action, provided that Contractor shall have sole control of the defense of any such action and all negotiations or its settlement or compromise. If notified promptly in writing of any informal claim (other than a judicial action) brought against City based on an allegation that City’s use of the Licensed Software constitutes Infringement, Contractor will pay the costs associated with resolving such claim and will pay the settlement amount (if any), provided that Contractor shall have sole control of the resolution of any such claim and all negotiations for its settlement. In the event a final injunction is obtained against City’s use of the Licensed Software by reason of Infringement, or in Contractor’s opinion City’s use of the Licensed Software is likely to become the subject of Infringement, Contractor may at its option and expense: (a) procure for City the right to continue to use the Licensed Software as contemplated hereunder, (b) replace the Licensed Software with a non-infringing, functionally equivalent substitute Licensed Software, or (c) suitably modify the Licensed Software to make its use hereunder non-infringing while retaining functional equivalency to the unmodified version of the Licensed Software. If none of these options is reasonably available to Contractor, then the Agreement may be terminated at the option of either Party hereto and Contractor shall refund to City all amounts paid under this Agreement for the license of such infringing Licensed Software. Any unauthorized modification or attempted modification of the Licensed Software by City or any failure by City to implement any improvements or updates to the Licensed Software, as supplied by Contractor, shall void this indemnity unless City has obtained prior written authorization from Contractor permitting such modification, attempted modification or failure to implement. Contractor shall have no liability for any claim of Infringement based on City’s use or combination of the Licensed Software with products or data of the type for which the Licensed Software was neither designed nor intended to be used.
Patent and Copyright Indemnification a. The Contractor, at its expense, shall defend, indemnify, and hold DSHS harmless from and against any claims against DSHS that any Product or Work Product supplied hereunder, or DSHS’s use of the Product or Work Product within the terms of this Contract, infringes any patent, copyright, utility model, industrial design, mask work, trade secret, trademark, or other similar proprietary right of a third party worldwide. Product shall mean any Contractor-supplied equipment, Software, or documentation. The Contractor shall pay all costs of such defense and settlement and any penalties, costs, damages and attorneys’ fees awarded by a court or incurred by DSHS provided that DSHS:
Intellectual Property Infringement Indemnification 1.1 We will defend you against any third party claim(s) that the Tyler Software or Documentation infringes that third party’s patent, copyright, or trademark, or misappropriates its trade secrets, and will pay the amount of any resulting adverse final judgment (or settlement to which we consent). You must notify us promptly in writing of the claim and give us sole control over its defense or settlement. You agree to provide us with reasonable assistance, cooperation, and information in defending the claim at our expense.
Indemnification Process 20.2.1 As used in this Section 20, “Indemnified Person” means a person whom an Indemnifying Party is obligated to indemnify, defend and/or hold harmless under Section 20.1.
Indemnification by Customer Customer shall indemnify, defend and hold harmless MSIL and its affiliates from and against any loss, liability, damage, cost or expense (including attorneys' and accountants' fees and expenses incurred in the defense of any demands, claims or lawsuits) actually and reasonably incurred arising from any act, omission, conduct, or activity undertaken by MSIL on behalf of Customer, including, without limitation, any demands, claims or lawsuits initiated by a limited partner (or assignee thereof); provided that (i) MSIL has determined, in good faith, that the act, omission, conduct, or activity giving rise to the claim for indemnification was in the best interests of the Customer, and (ii) the act, omission, conduct or activity that was the basis for such loss, liability, damage, cost or expense was not the result of misconduct or negligence. Notwithstanding the foregoing, no indemnification of MSIL or its affiliates by Customer shall be permitted for any losses, liabilities or expenses arising from or out of any alleged violation of federal or state securities laws unless (i) there has been a successful adjudication on the merits of each count involving alleged securities law violations as to the particular indemnitee, or (ii) such claims have been dismissed with prejudice on the merits by a court of competent jurisdiction as to the particular indemnitee, or (iii) a court of competent jurisdiction approves a settlement of the claims against the particular indemnitee and finds that indemnification of the settlement and related costs should be made, provided with regard to such court approval, the indemnitee must apprise the court of the position of the SEC and the positions of the respective securities administrators of Massachusetts, Missouri, Tennessee and/or those other states and jurisdictions in which the plaintiffs claim that they were offered or sold Units, with respect to indemnification for securities laws violations before seeking court approval for indemnification. Furthermore, in any action or proceeding brought by a limited partner in the right of Customer to which MSIL or any affiliate thereof is a party defendant, any such person shall be indemnified only to the extent and subject to the conditions specified in the Delaware Revised Uniform Limited Partnership Act, as amended, and this Section 2. The Customer shall make advances to MSIL or its affiliates hereunder only if: (i) the demand, claim lawsuit or legal action relates to the performance of duties or services by such persons to Customer; (ii) such demand, claim lawsuit or legal action is not initiated by a limited partner; and (iii) such advances are repaid, with interest at the legal rate under Delaware law, if the person receiving such advance is ultimately found not to be entitled to indemnification hereunder.
