CONTRACTOR’S WARRANTY OF ADHERENCE TO COUNTY’S CHILD SUPPORT COMPLIANCE PROGRAM
Assignment Liability Indemnity Force Majeure Consequential Damages and Default Notwithstanding any other provision of this Agreement, the liability, indemnification and insurance provisions of the Transmission Operating Agreement (“TOA”) or other applicable operating agreements shall apply to the relationship between the System Operator and the Interconnection Transmission Owner and the liability, indemnification and insurance provisions of the Tariff apply to the relationship between the System Operator and the Interconnection Customer and between the Interconnecting Transmission Owner and the Interconnection Customer.
Damages for breach of maintenance obligations 17.8.1 In the event that the Concessionaire fails to repair or rectify any defect or deficiency set forth in the Maintenance Requirements within the period specified therein, it shall be deemed to be in breach of this Agreement and the Authority shall be entitled to recover Damages, to be calculated and paid for each day of delay until the breach is cured, at the higher of (a) 0.5% (zero point five per cent) of Performance Guarantee, and (b) 0.1% (zero point one per cent) of the cost of such repair or rectification as estimated by the Independent Engineer. Recovery of such Damages shall be without prejudice to the rights of the Authority under this Agreement, including the right of Termination thereof.
Force Majeure, Notice of Delay, and No Damages for Delay The Contractor will not be responsible for delay resulting from its failure to perform if neither the fault nor the negligence of the Contractor or its employees or agents contributed to the delay and the delay is due directly to acts of God, wars, acts of public enemies, strikes, fires, floods, or other similar cause wholly beyond the Contractor’s control, or for any of the foregoing that affect subcontractors or suppliers if no alternate source of supply is available to the Contractor. In case of any delay the Contractor believes is excusable, the Contractor will notify the Department or Customer in writing of the delay or potential delay and describe the cause of the delay either (1) within 10 days after the cause that creates or will create the delay first arose, if the Contractor could reasonably foresee that a delay could occur as a result, or (2) if delay is not reasonably foreseeable, within five days after the date the Contractor first had reason to believe that a delay could result. The foregoing will constitute the Contractor’s sole remedy or excuse with respect to delay. Providing notice in strict accordance with this paragraph is a condition precedent to such remedy. No claim for damages will be asserted by the Contractor. The Contractor will not be entitled to an increase in the Contract price or payment of any kind from the Department or Customer for direct, indirect, consequential, impact or other costs, expenses or damages, including but not limited to costs of acceleration or inefficiency, arising because of delay, disruption, interference, or hindrance from any cause whatsoever. If performance is suspended or delayed, in whole or in part, due to any of the causes described in this paragraph, after the causes have ceased to exist the Contractor will perform at no increased cost, unless the Department or Customer determines, in its sole discretion, that the delay will significantly impair the value of the Contract to the State of Florida or to Customers, in which case the Department or Customer may (1) accept allocated performance or deliveries from the Contractor, provided that the Contractor grants preferential treatment to Customers with respect to commodities or contractual services subjected to allocation, or (2) purchase from other sources (without recourse to and by the Contractor for the related costs and expenses) to replace all or part of the commodity or contractual services that are the subject of the delay, which purchases may be deducted from the Contract quantity, or (3) terminate the Contract in whole or in part.
EVENTS CONSTITUTING MATERIAL BREACH OF AGREEMENT The Applicant shall be in Material Breach of this Agreement if it commits one or more of the following acts or omissions (each a “Material Breach”):
POSSESSION OF GAS AN INDEMNIFICATION 1. As between the parties hereto, Seller shall be deemed to be in control and possession of the gas deliverable hereunder until it shall have been delivered to Buyer at the Point of Delivery after which Buyer shall be deemed to be in control and possession thereof.
Arbitration, Damages, Jury Trial and Warranties The City does not ever accept binding arbitration or the payment of damages or penalties upon the occurrence of a contingency, and expressly denies such acceptance for this Agreement. The City never consents to a jury trial to resolve any disputes that may arise hereunder, and expressly denies such consent for this Agreement. Contractor waives its right to a jury trial to resolve any disputes that may arise hereunder. No provision of any document within the Agreement between the Parties will be given effect which attempts to exclude, modify, disclaim or otherwise attempt to limit implied warranties of merchantability and fitness for a particular purpose.
Epidemic Failure Warranty Supplier warrants all Products against Epidemic Failure for a period of three years after DXC’s Acceptance. Epidemic Failure means the occurrence of the same failure, defect, or non-conformity with an Order in 2% or more of Products within any three-month period.
Defendant’s Breach of Plea Agreement If the defendant commits any crimes, violates any conditions of release, or violates any term of this plea agreement between the signing of this plea agreement and the date of sentencing, or fails to appear for sentencing, or if the defendant provides information to the Probation Office or the Court that is intentionally misleading, incomplete, or untruthful, or otherwise breaches this plea agreement, the United States will be released from its obligations under this agreement. The defendant, however, will remain bound by the terms of the agreement, and will not be allowed to withdraw his plea of guilty. The defendant also understands and agrees that in the event he violates this plea agreement, all statements made by him to law enforcement agents subsequent to the execution of this plea agreement, any testimony given by him before a grand jury or any tribunal or any leads from such statements or testimony shall be admissible against him in any and all criminal proceedings. The defendant waives any rights that he might assert under the United States Constitution, any statute, Rule 11(f) of the Federal Rules of Criminal Procedure, Rule 410 of the Federal Rules of Evidence, or any other federal rule that pertains to the admissibility of any statements made by him subsequent to this plea agreement.
Contractor’s Warranty Contractor warrants that it complies with all Federal Immigration laws and regulations that relate to its employees and complies with A.R.S. § 23- 214.A, Verification of Employment Eligibility. Contractor shall not employ aliens in accordance with A.R.S. § 34-301, Employment of Aliens on Public Works Prohibited. Contractor acknowledges that pursuant to A.R.S. § 41-4401,
