Time limit for claims No Indemnified Party may make a Claim for indemnification under Section 6.1 in respect of any Claim unless notice in writing of the Claim, incorporating a statement setting out in reasonable detail the grounds on which the Claim is based, has been given by the Indemnified Party prior to the expiration of the applicable Survival Period as set forth in Part VI of Appendix B.
Contractor Claims In the event of any demand by Contractor for (A) a time extension, including, without limitation, for relief from damages or penalties for delay assessed by the District under the Contract, (B) payment by the District of money or damages arising from work done by, or on behalf of, the Contractor pursuant to the Contract and payment of which is not otherwise expressly provided for or to which Contractor is not otherwise entitled to, or (C) an amount of payment disputed by the District, the parties shall attempt to resolve the dispute by those procedures set forth in Public Contract Code section 9204 and/or Article 1.5 (commencing with section 20104) of Chapter 1, Part, 3, Division 2, of the Public Contract Code, if applicable, the provisions of which are each attached hereto and incorporated herein by this reference. If a claim, or any portion thereof, remains in dispute upon satisfaction of all applicable dispute resolution requirements, the Contractor shall comply with all claims presentation requirements as provided in Chapter 1 (commencing with section 900) and Chapter 2 (commencing with section 910) of Part 3 of Division 3.6 of Title 1 of Government Code as a condition precedent to the Contractor’s right to bring a civil action against the District. For purposes of those provisions, the running of the time within which a claim must be presented to the District shall be tolled from the time the Contractor submits its written claim until the time the claim is denied, including any time utilized by any applicable meet and confer process. Pending resolution of the dispute, Contractor and its subcontractors shall continue to perform the Work under the Contract and shall not cause a delay of the Work during any dispute, claim, negotiation, mediation, or arbitration proceeding, except by written agreement of the District.
Indemnification for Certain Claims The Party providing services hereunder, its affiliates and its parent company, shall be indemnified, defended and held harmless by the Party receiving services hereunder against any claim, loss or damage arising from the receiving company’s use of the services provided under this Agreement pertaining to (1) claims for libel, slander or invasion of privacy arising from the content of the receiving company’s own communications, or (2) any claim, loss or damage claimed by the End User of the Party receiving services arising from such company’s use or reliance on the providing company’s services, actions, duties, or obligations arising out of this Agreement.
Indemnification for Suits or Claims for Intellectual Property Infringement The Contractor shall indemnify and hold the Owner harmless from any suits or claims of infringement of any patent rights, trademarks or copyrights arising out of any patented, trademarked, or copyrighted materials, methods, or systems used by the Contractor.
ATTORNEYS’ FEES AND LITIGATION EXPENSES 16. Lead Counsel will apply to the Court for a collective award of attorneys’ fees to Plaintiffs’ Counsel to be paid solely from (and out of) the Settlement Fund. Lead Counsel also will apply to the Court for payment or reimbursement of Litigation Expenses, which may include a request for reimbursement of Lead Plaintiff’s costs and expenses directly related to its representation of the Settlement Class, to be paid solely from (and out of) the Settlement Fund. Lead Counsel’s application for an award of attorneys’ fees and/or Litigation Expenses is not the subject of any agreement between Defendants and Lead Plaintiff other than what is set forth in this Stipulation.
Indemnification by Contractor (a) Contractor shall defend, indemnify and hold harmless District, its officers, directors, employees, agents, volunteers, and Affiliates and District’s Board of Education from any and all damages, costs and expenses, including attorneys’ fees, arising out of any third party claims for damages for bodily injury (including death) or for damage to real property or tangible personal property resulting from, arising out of or otherwise related to Contractor’s performance of this Agreement.
RESPONSIBILITY FOR CLAIMS AND LIABILITY It is hereby stipulated and agreed between the parties that, with respect to any claim or action brought by a third party and arising out of the activities described in this IGA or stems from any matter arising out of any actual or alleged infringement of any patent, trademark, copyright, or service xxxx, or other actual or alleged unfair competition disparagement of product or service, or other tort or any type whatsoever, or any actual or alleged violation of trade regulations, each party shall only be liable for payment of that portion of any and all liability, costs, expenses, demands, settlements, or judgments resulting from the negligence actions or omissions of its own agents, officers, and employees. Either Party may self-fund its obligations under this IGA. However, nothing herein shall be construed as a waiver of any Party’s sovereign immunity or the immunities available to the officials, officers and employees of the Parties. To the extent allowed by law, the CITY shall ensure that any contractor retained or selected by the CITY to provide services related to the UTILITIES RELOCATOIN work contemplated in this IGA shall agree to indemnify and hold harmless the COUTNY as well as its commissioners, officers, officials, employees, and agents, from and against any and all loss and/or expense which it or any of them may suffer or pay as a result of claims or suits due to, because of, or arising out of any and all such injuries, deaths and/or damage, arising out of the UTILITIES RELOCATION work irrespective of the COUNTY’s negligence (except that no Party shall be indemnified for their own sole negligence). Any contractor retained by the CITY, if requested, shall assume and defend at the contractor’s own expense, any suit, action or other legal proceedings arising therefrom in which the COUNTY, and/or its commissioners, officers, officials, employees, and agents, are named as a party, and the contractor hereby agrees to satisfy, pay, and cause to be discharged of record any judgment which may be rendered against the COUNTY and/or its commissioners, officers, officials, employees, and agents, arising therefrom. The CITY shall ensure that the provisions of this Article are included in all contracts and subcontracts.
Indemnification by Licensee Licensee shall defend, indemnify and hold harmless Licensor and its Affiliates, and their respective officers, directors, employees, agents, shareholders, successors and assigns, (collectively, the “Licensor Parties”) from and against any Action, and any and all direct losses suffered or incurred by Licensor in connection with any third party claims (a) arising out of or resulting from any breach by Licensee of any provision of this Agreement, (b) regarding the Content (other than Licensed Content) of the websites associated with Licensed Domain Names, or (c) regarding any Content that was subject to a request for removal by a Governmental Authority, even if Licensee removes such Content within the time period proscribed by the Governmental Authority, provided that, in all cases, Licensee shall not be liable for any direct losses suffered or incurred by Licensor as a result of Licensor’s failure to provide Licensee with a reasonable period of time to remove Content in cases where (i) the basis or nature of the offense has not previously been identified by any Governmental Authority as offensive or inappropriate and (ii) Licensee has not also received notice from the Governmental Authority. Licensee’s obligation to indemnify Licensor shall be conditioned on (x) Licensor’s provision to Licensee of prompt notice of such an Action (except where any delay does not materially prejudice Licensee); (y) Licensor’s reasonable cooperation with Licensee in the defense and settlement of such an Action at Licensee’s cost; and (z) Licensee having exclusive control of the defense, settlement and/or compromise of such an Action (provided that Licensee may not settle any Action in a manner that adversely affects Licensor without Licensor’s prior written consent, not to be unreasonably withheld or delayed).
Patent Expenses Unless agreed otherwise, the Party filing a Patent Application will pay all preparation and filing expenses, prosecution fees, issuance fees, post issuance fees, patent maintenance fees, annuities, interference expenses, and attorneys’ fees for that Patent Application and any resulting Patent(s). If a license to any CRADA Subject Invention is granted to Collaborator, then Collaborator will be responsible for all expenses and fees, past and future, in connection with the preparation, filing, prosecution, and maintenance of any Patent Applications and Patents claiming exclusively licensed CRADA Subject Inventions and will be responsible for a pro-rated share, divided equally among all licensees, of those expenses and fees for non-exclusively licensed CRADA Subject Inventions. Collaborator may waive its exclusive option rights at any time, and incur no subsequent financial obligation for those Patent Application(s) or Patent(s).
Indemnification Claims (a) In the event that any of the Parties are entitled, or seek to assert rights, to indemnification under this Article VI, the Party or Parties seeking indemnification (the “Indemnified Parties”) shall give written notification to the other Party or Parties (the “Indemnifying Parties”) of the commencement of any suit or proceeding relating to a third party claim for which indemnification pursuant to this Article VI may be sought. Such notification shall be given within 20 Business Days after receipt by the Indemnified Parties of notice of such suit or proceeding, and shall describe in reasonable detail (to the extent known by the Indemnified Parties) the facts constituting the basis for such suit or proceeding and the amount of the claimed damages; provided, however, that no delay on the part of the Indemnified Parties in notifying the Indemnifying Parties shall relieve the Indemnifying Parties of any liability or obligation hereunder except to the extent of any damage or liability caused by or arising out of such failure. Within 20 days after delivery of such notification, the Indemnifying Parties may, upon written notice thereof to the Indemnified Parties seeking indemnification, assume control of the defense of such suit or proceeding with counsel reasonably satisfactory to the Indemnified Party seeking indemnification; provided that the Indemnifying Parties may not assume control of the defense of a suit or proceeding involving criminal liability or in which equitable relief is sought against the Indemnified Party seeking indemnification. If the Indemnifying Parties do not so assume control of such defense, the Indemnified Parties seeking indemnification shall control such defense. The Party not controlling such defense (the “Non-Controlling Party”) may participate therein at its own expense; provided that if the Indemnifying Parties assumes control of such defense and the Indemnified Parties seeking indemnification reasonably concludes that the Indemnifying Parties and the Indemnified Parties seeking indemnification have conflicting interests or different defenses available with respect to such suit or proceeding, the reasonable fees and expenses of counsel to the Indemnified Parties shall be considered “Damages” for purposes of this Agreement. The Party or Parties controlling such defense (the “Controlling Party”) shall keep the Non-Controlling Party advised of the status of such suit or proceeding and the defense thereof and shall consider in good faith recommendations made by the Non-Controlling Party with respect thereto. The Non-Controlling Party shall furnish the Controlling Party with such information as it may have with respect to such suit or proceeding (including copies of any summons, complaint or other pleading which may have been served on such party and any written claim, demand, invoice, billing or other document evidencing or asserting the same) and shall otherwise cooperate with and assist the Controlling Party as reasonably needed in the defense of such suit or proceeding at the sole cost and expense of the Indemnifying Parties under Section 6.1 or 6.2, which cost and expense shall be considered “Damages” for purposes of this Agreement. The Indemnifying Parties shall not agree to any settlement of, or the entry of any judgment arising from, any such suit or proceeding without the prior written consent of the Indemnified Parties, which shall not be unreasonably withheld or delayed; provided that the consent of the Indemnified Parties shall not be required if the Indemnifying Parties agrees in writing to pay any amounts payable pursuant to such settlement or judgment and such settlement or judgment includes a complete release of the Indemnified Parties from further liability and has no other materially adverse effect on the Indemnified Parties. The Indemnified Parties shall not agree to any settlement of, or the entry of any judgment arising from, any such suit or proceeding without the prior written consent of the Indemnifying Parties, which shall not be unreasonably withheld or delayed.
