Common use of Effect of Injunctions or Other Court Orders Clause in Contracts

Effect of Injunctions or Other Court Orders. The Parties recognize the right of the District to withdraw, at its absolute discretion, the utilization of the Agreement as part of any bid specification should a Court of competent jurisdiction issue any order, or any applicable statute which could result, temporarily or permanently in delay of the bidding, awarding and/or construction on the Project. Notwithstanding such an action by the District, or such court order or statutory provision, the Parties agree that the Agreement shall remain in full force and effect on covered Project Work to the maximum extent legally possible.

Effect of Injunctions or Other Court Orders. The Parties recognize the right of the District City to withdraw, at its absolute discretion, the utilization of the Agreement as part of any bid specification should a Court of competent jurisdiction issue any order, or any applicable statute which could result, temporarily or permanently in delay of the bidding, awarding and/or construction on the Project. Notwithstanding such an action by the DistrictCity, or such court order or statutory provision, the Parties agree that the Agreement shall remain in full force and effect on covered Project Work to the maximum extent legally possible.

Effect of Injunctions or Other Court Orders. The Parties recognize the right of the District to withdraw, at its absolute discretion, the utilization of the Agreement as part of any bid specification should a Court of competent jurisdiction issue any order, or any applicable statute be enacted which could result, temporarily or permanently permanently, in delay of the bidding, awarding and/or awarding, or construction on of the Project. Notwithstanding any such an action by the District, or such court order or statutory provision, the Parties agree that the Agreement shall remain in full force and effect on covered Project Work to the maximum extent legally possible.

Effect of Injunctions or Other Court Orders. The Parties recognize the right of the District City to withdraw, at its absolute discretion, the utilization of the Agreement as part of any bid specification should a Court of competent jurisdiction issue any order, or any applicable statute which could result, temporarily or permanently permanently, in delay of the bidding, awarding and/or construction on of the Project. Notwithstanding such an action by the DistrictCity, or such court order or statutory provision, the Parties agree that the Agreement shall remain in full force and effect on other covered Project Work Work; provided however, that the continuance of the Project is not determined to be financially or legally detrimental to the maximum extent legally possibleCity, at its sole and absolute discretion.

Effect of Injunctions or Other Court Orders. The Parties recognize the right of the District to withdraw, at its absolute discretion, the utilization of the Agreement as part of any bid specification should a Court of competent jurisdiction issue any order, or any applicable statute which could result, temporarily or permanently in delay of the bidding, awarding and/or construction on the Project. Notwithstanding such an action by the District, or such court order or statutory provision, the Parties agree that the Agreement shall remain in full force and effect the fact on covered Project Work to the maximum extent legally possible.

Effect of Injunctions or Other Court Orders. The Parties parties recognize the right of the District City to withdraw, at its absolute discretion, the utilization of the Agreement as part of any bid specification should a Court of competent jurisdiction issue any order, or any applicable statute be enacted, which could result, temporarily or permanently in delay of the bidding, awarding and/or construction on of the Project. Notwithstanding such an action by the DistrictCity, or such court order or statutory provision, the Parties parties agree that the Agreement shall remain in full force and effect on covered Project Work to the maximum extent legally possible.

Effect of Injunctions or Other Court Orders. The Parties recognize the right of the District City to withdraw, at its absolute discretion, the utilization of the Agreement as part of any bid specification should a Court of competent jurisdiction issue any order, or any applicable statute which could result, temporarily or permanently in delay of the bidding, awarding and/or construction on the Project. Notwithstanding such an action by the District, or such court order or statutory provision, the Parties agree that the Agreement shall remain in full force and effect on covered Project Work to the maximum extent legally possible.

Effect of Injunctions or Other Court Orders. The Parties recognize the right of the District to withdraw, at its absolute discretion, the utilization of the Agreement as part of any bid procurement specification should a Court of competent jurisdiction issue any order, or any applicable statute which could result, temporarily or permanently in delay of the biddingprocurement, awarding and/or construction on the Project. Notwithstanding such an action by the District, or such court order or statutory provision, the Parties agree that the Agreement shall remain in full force and effect the fact on covered Project Work to the maximum extent legally possible.

Effect of Injunctions or Other Court Orders. The Parties recognize the right of the District City to withdraw, at its absolute discretion, the utilization of the Agreement as part of any bid specification should a Court of competent jurisdiction issue any order, or any applicable statute which could result, temporarily or permanently in delay of the bidding, awarding and/or construction on the Project. Notwithstanding such an action by the DistrictCity, or such court order or statutory provision, the Parties agree that the Agreement shall remain in full force and effect the fact on covered Project Work to the maximum extent legally possible.

Effect of Injunctions or Other Court Orders. The Parties recognize the right of the District to withdraw, at its absolute discretion, the utilization of the Agreement as part of any bid specification should a Court of competent jurisdiction issue any order, or any applicable statute which could result, temporarily or permanently in delay of the bidding, awarding and/or construction on the Projectof Project Work. Notwithstanding such an action by the District, or such court order or statutory provision, the Parties agree that the Agreement shall remain in full force and effect on covered Project Work to the maximum extent legally possible.

Effect of Injunctions or Other Court Orders. The Parties parties recognize the right of the District to withdraw, at its absolute discretion, the utilization of the Agreement as part of any bid specification should a Court of competent jurisdiction issue any order, or any applicable statute which could result, temporarily or permanently in delay of the bidding, awarding and/or construction on the Project. Notwithstanding such an action by the District, or such court order or statutory provision, the Parties parties agree that the Agreement shall remain in full force and effect the fact on covered Project Work to the maximum extent legally possible.

Effect of Injunctions or Other Court Orders. The Parties recognize the right of the District City to withdraw, at its absolute discretion, the utilization of the Agreement as part of any bid specification should a Court of competent jurisdiction issue any order, or any applicable statute which could result, temporarily or permanently in delay of the bidding, awarding and/or construction on of the Project. Notwithstanding such an action by the DistrictCity, or such court order or statutory provision, the Parties agree that the Agreement shall remain in full force and effect on covered Project Work Work; provided however, that the continuance of the Project is not determined to be financially or legally detrimental to the maximum extent legally possibleCity, at its sole and absolute discretion.