Duty to Give Notice to Owner. If the Owner, the Program Manager, or any other person with whom the Owner has a direct contractual relationship shall, in the judgment of the Design-Builder, acts or fails to act in such a manner as to (i) delay the progress of the construction of the Project or (ii) increase the cost of the Project, Design-Builder shall give prompt notice to Owner so as to permit Owner to take corrective action.
Appears in 12 contracts
Samples: Design Build Contract, Design Build Contract, Design Build Contract
Duty to Give Notice to Owner. If the Owner, the Program Manager, or any other person with whom the Owner has a direct contractual relationship shall, in the judgment of the Design-Builder, acts or fails to act in such a manner as to (i) delay the progress of the construction of the Project or (ii) increase the cost of the Project, Design-Builder shall give prompt notice to Owner so as to permit Owner to take corrective action.to
Appears in 1 contract
Samples: Design Build Contract
Duty to Give Notice to Owner. If the Owner, the Program ManagerExecutive Administrator, or any other person with whom the Owner or Executive Administrator respectively has a direct contractual relationship shall, in the judgment of the Design-Design- Builder, acts or fails to act in such a manner as to (i) delay the progress of the construction of the Project or (ii) increase the cost of the Project, Design-Builder shall give prompt notice to Owner so as to permit Owner to take corrective action.
Appears in 1 contract
Samples: gsfic.georgia.gov
Duty to Give Notice to Owner. If the Owner, the Program ManagerExecutive Administrator, or any other person with whom the Owner or Executive Administrator respectively has a direct contractual relationship shall, in the judgment of the Design-Builder, acts or fails to act in such a manner as to (i) delay the progress of the construction of the Project or (ii) increase the cost of the Project, Design-Builder shall give prompt notice to Owner so as to permit Owner to take corrective action.
Appears in 1 contract
Samples: Construction Contract
Duty to Give Notice to Owner. If the Owner, the Program ManagerArchitect, or any other person with whom the Owner or Architect respectively has a direct contractual relationship relationship, including the Program Manager, shall, in the judgment of the Design-BuilderConstruction Manager, acts act or fails fail to act in such a manner as to (i) delay the progress of the construction of the Project or (ii) increase the cost of the Project, Design-Builder shall give prompt notice to Owner so as to permit Owner to take corrective action.or
Appears in 1 contract
Samples: Construction Management Agreement
