Payment of Liquidated Damages With respect to any Liquidated Damages that accrue, Owner shall invoice Contractor for such Liquidated Damages. Contractor shall pay such Liquidated Damages within ten (10) Days after Contractor’s receipt of such invoice. To the extent Contractor does not pay such Liquidated Damages within such ten (10) Day period, Owner may, at its option, do one or more of the following: (i) withhold from Contractor amounts that are otherwise due and payable to Contractor in the amount of such Liquidated Damages and/or (ii) collect on the Letter of Credit in the amount of such Liquidated Damages. For the avoidance of doubt, prior to exercising such right to withhold or collect on the Letter of Credit, Owner shall not be required to provide the notice as set forth in Section 7.8. As used in this Agreement, Liquidated Damages are “paid” if and to the extent Owner exercises option (i) or (ii) above for the collection of Liquidated Damages.
Liquidated Damages The Company’s obligations to pay any partial liquidated damages or other amounts owing under the Transaction Documents is a continuing obligation of the Company and shall not terminate until all unpaid partial liquidated damages and other amounts have been paid notwithstanding the fact that the instrument or security pursuant to which such partial liquidated damages or other amounts are due and payable shall have been canceled.
Waiver of Liquidated Damages If the Partnership is unable to cause a Registration Statement to become effective on or before the Target Effective Date, then the Partnership may request a waiver of the Liquidated Damages, which may be granted by the consent of the Holders of at least the Registrable Securities Required Voting Percentage, in their sole discretion, and which such waiver shall apply to all the Holders of Registrable Securities included on such Registration Statement.
Payment of Damages The indemnification required hereunder shall be made by periodic payments of the amount thereof during the course of the investigation or defense, within 10 days as and when reasonably specific bills are received or loss, liability, claim, damage or expense is incurred and reasonable evidence thereof is delivered. In calculating any amount to be paid by an indemnifying party by reason of the provisions of this Agreement, the amount shall be reduced by all tax benefits and other reimbursements (including, without limitation, insurance proceeds) credited to or received by the other party related to the Damages.
Indemnification Exclusive Remedy In the absence of fraud, and -------------------------------- except for non-monetary equitable relief, if the Closing occurs, indemnification pursuant to the provisions of this Article 10 shall be the sole and exclusive remedy of the parties for any breach of any representation or warranty contained in this Agreement.
Consequential Damages Waiver EXCEPT FOR A BREACH OF SECTION 4.1 ("CONFIDENTIAL INFORMATION") OF THIS AGREEMENT, IN NO EVENT WILL EITHER PARTY BE LIABLE OR RESPONSIBLE TO THE OTHER FOR ANY TYPE OF INCIDENTAL, PUNITIVE, INDIRECT OR CONSEQUENTIAL DAMAGES, INCLUDING, BUT NOT LIMITED TO, LOST REVENUE, LOST PROFITS, REPLACEMENT GOODS, LOSS OF TECHNOLOGY, RIGHTS OR SERVICES, LOSS OF DATA, OR INTERRUPTION OR LOSS OF USE OF SERVICE OR EQUIPMENT, EVEN IF ADVISED OF THE POSSIBILITY OF SUCH DAMAGES, WHETHER ARISING UNDER THEORY OF CONTRACT, TORT (INCLUDING NEGLIGENCE), STRICT LIABILITY OR OTHERWISE.
Non-Exclusive Remedy Notwithstanding anything herein to the contrary, termination of this Agreement by a Party shall be without prejudice to other remedies such Party may have at law or equity.
Obligation Absolute; Partial Liquidated Damages The Company’s obligations to issue and deliver the Conversion Shares upon conversion of this Debenture in accordance with the terms hereof are absolute and unconditional, irrespective of any action or inaction by the Holder to enforce the same, any waiver or consent with respect to any provision hereof, the recovery of any judgment against any Person or any action to enforce the same, or any setoff, counterclaim, recoupment, limitation or termination, or any breach or alleged breach by the Holder or any other Person of any obligation to the Company or any violation or alleged violation of law by the Holder or any other Person, and irrespective of any other circumstance which might otherwise limit such obligation of the Company to the Holder in connection with the issuance of such Conversion Shares; provided, however, that such delivery shall not operate as a waiver by the Company of any such action the Company may have against the Holder. In the event the Holder of this Debenture shall elect to convert any or all of the outstanding principal amount hereof, the Company may not refuse conversion based on any claim that the Holder or anyone associated or affiliated with the Holder has been engaged in any violation of law, agreement or for any other reason, unless an injunction from a court, on notice to Holder, restraining and or enjoining conversion of all or part of this Debenture shall have been sought and obtained, and the Company posts a surety bond for the benefit of the Holder in the amount of 150% of the outstanding principal amount of this Debenture, which is subject to the injunction, which bond shall remain in effect until the completion of arbitration/litigation of the underlying dispute and the proceeds of which shall be payable to the Holder to the extent it obtains judgment. In the absence of such injunction, the Company shall issue Conversion Shares or, if applicable, cash, upon a properly noticed conversion. If the Company fails for any reason to deliver to the Holder such Conversion Shares pursuant to Section 4(c)(ii) by the Share Delivery Date, the Company shall pay to the Holder, in cash, as liquidated damages and not as a penalty, for each $1,000 of principal amount being converted, $10 per Trading Day (increasing to $20 per Trading Day on the fifth (5th) Trading Day after such liquidated damages begin to accrue) for each Trading Day after such Share Delivery Date until such Conversion Shares are delivered or Holder rescinds such conversion. Nothing herein shall limit a Hxxxxx’s right to pursue actual damages or declare an Event of Default pursuant to Section 8 hereof for the Company’s failure to deliver Conversion Shares within the period specified herein and the Holder shall have the right to pursue all remedies available to it hereunder, at law or in equity including, without limitation, a decree of specific performance and/or injunctive relief. The exercise of any such rights shall not prohibit the Holder from seeking to enforce damages pursuant to any other Section hereof or under applicable law.
Non-exclusive Remedy; Survival The indemnification and contribution provided for under this Agreement shall be in addition to any other rights to indemnification or contribution that any indemnified party may have pursuant to law or contract and shall remain in full force and effect regardless of any investigation made by or on behalf of the indemnified party or any officer, director or controlling Person of such indemnified party and shall survive the transfer of Registrable Securities and the termination or expiration of this Agreement.
Sole and Exclusive Remedy Except in the event of fraud or any Willful Breach of any representation, warranty or covenant or agreement contained herein, if this Agreement is validly terminated pursuant to Section 8.1, Parent’s receipt of the Termination Fee to the extent owed pursuant to Section 8.3(b) and any amounts owed pursuant to Section 8.3(d), and Parent’s right to seek specific performance pursuant to Section 9.10 (subject to the limitations set forth in Section 9.10), will be the sole and exclusive remedies of Parent and Merger Sub against (A) the Company and its Subsidiaries; and (B) the former, current and future holders of any equity, controlling persons, Representatives, Affiliates, members, managers, general or limited partners, stockholders, directors, officers, employees, agents, attorneys and assignees of each of the Company, its Subsidiaries and each of their respective Affiliates and former, current and future holders of any equity, controlling persons, Representatives, Affiliates, members, managers, general or limited partners, stockholders, directors, officers, employees, agents, attorneys and assignees of each of the foregoing (the Persons in clauses (A) and (B) collectively, the “Company Related Parties”) in respect of this Agreement and the Transactions. Except in the event of fraud or any Willful Breach of any representation, warranty or covenant or agreement contained herein, upon payment of the Termination Fee to Parent or its designee, none of the Company Related Parties will have any further monetary liability or obligation to (A) Parent or Merger Sub; or (B) the former, current and future direct or indirect holders of any equity, controlling persons, Representatives, Affiliates (other than Parent or Merger Sub), members, managers, general or limited partners, stockholders and assignees of each of Parent and Merger Sub (the Persons in clauses (A) and (B) collectively, the “Parent Related Parties”) relating to or arising out of this Agreement or the Transactions (except that the Company and its Subsidiaries (or their Affiliates) will remain obligated with respect to, and Parent and Merger Sub may be entitled to remedies with respect to, the Confidentiality Agreement, Section 8.3(a) (with respect to the expenses of the Company) and Section 8.3(d), as applicable.
