Cost of the Work § 6.1 For purposes of this Agreement, the Cost of the Work shall be the total cost to the Owner to construct all elements of the Project designed or specified by the Architect and shall include contractors’ general conditions costs, overhead and profit. The Cost of the Work also includes the reasonable value of labor, materials, and equipment, donated to, or otherwise furnished by, the Owner. The Cost of the Work does not include the compensation of the Architect; the costs of the land, rights-of-way, financing, or contingencies for changes in the Work; or other costs that are the responsibility of the Owner.
Repayment of the Loan The Borrower agrees to repay the EMIs/Monthly Instalments and the other Outstanding Dues to BHFL on or before the respective Due Dates by any of the repayment modes as set out in the Loan Agreement or the Top-Up Loan Addendum, or in such manner and at such place, as may be agreed between the Borrower and BHFL. • BHFL may, at the request of the Borrower in writing, agree to change the repayment mode. BHFL may, at any time, in its discretion revise the repayment schedule in its sole and absolute discretion and notify the Borrower in advance accordingly. • The EMI/Monthly Instalment amount shall be arrived at so as to comprise the repayment of the Loan Amount and payment of Interest calculated on the basis of the Interest Rate within the Loan Tenure. The Borrower agrees to continue paying EMIs/Monthly Instalments until all Outstanding Dues under the Loan have been repaid in full to BHFL.
Term Loan The Borrower may, upon notice from the Borrower to the Administrative Agent, at any time or from time to time voluntarily prepay the Term Loan in whole or in part together with the applicable Prepayment Premium; provided that (A) such notice must be received by the Administrative Agent not later than 11:00 a.m. (1) three Business Days prior to any date of prepayment of LIBOR Rate Loans and (2) on the date of prepayment of Base Rate Loans; (B) any such prepayment of LIBOR Rate Loans shall be in a principal amount of $500,000 or a whole multiple of $100,000 in excess thereof (or, if less, the entire principal amount thereof then outstanding); (C) any prepayment of Base Rate Loans shall be in a principal amount of $500,000 or a whole multiple of $100,000 in excess thereof (or, if less, the entire principal amount thereof then outstanding); and (D) any prepayment of the Term Loan shall be applied in the inverse order of maturity with respect to the remaining amortization payments. Each such notice shall specify the date and amount of such prepayment and the Type(s) of Loans to be prepaid. The Administrative Agent will promptly notify each Lender of its receipt of each such notice, and of the amount of such Lender’s Applicable Percentage of such prepayment. If such notice is given by the Borrower, the Borrower shall make such prepayment and the payment amount specified in such notice shall be due and payable on the date specified therein. Any prepayment of a LIBOR Rate Loan shall be accompanied by all accrued interest on the amount prepaid, together with any additional amounts required pursuant to Section 3.05. On the date of any voluntary prepayment of any Term Loan pursuant to this Section 2.05(a)(ii), the Borrower shall pay to the Administrative Agent, for the benefit of the Lenders, whether before or after an Event of Default, the applicable Prepayment Premium. Subject to Section 2.15, each such prepayment shall be applied to the Loans of the Lenders in accordance with their respective Applicable Percentages.
The Loan Section 2.01. The Bank agrees to lend to the Borrower, on the terms and conditions set forth or referred to in the Loan Agreement, various currencies that shall have an aggregate value equivalent to the amount of one hundred million dollars ($100,000,000), being the sum of withdrawals of the proceeds of the Loan, with each withdrawal valued by the Bank as of the date of such withdrawal.
Refinancing Preparation Advance If the Financing Agreement provides for the repayment out of the proceeds of the Financing of an advance made by the Association or the Bank (“Preparation Advance”), the Association shall, on behalf of the Recipient, withdraw from the Financing Account on or after the Effective Date the amount required to repay the withdrawn and outstanding balance of the advance as at the date of such withdrawal from the Financing Account and to pay all accrued and unpaid charges, if any, on the advance as at such date. The Association shall pay the amount so withdrawn to itself or the Bank, as the case may be, and shall cancel the remaining unwithdrawn amount of the advance.”
Loans The Sponsor has agreed to make loans to the Company in the aggregate amount of up to $300,000 (the “Insider Loans”) pursuant to a promissory note substantially in the form annexed as an exhibit to the Registration Statement. The Insider Loans do not bear any interest and are repayable by the Company on the earlier of December 31, 2021 or the consummation of the Offering.
Temporary Credit for Unamortized Specified Road Construction Cost When, under B8.33, Contracting Officer orders a delay or interruption of Purchaser’s Operations for more than 30 days when scheduled operations would be occurring but for the order, the Contracting Officer shall credit the unamortized cost of Specified Roads to Purchaser’s Timber Sale Account, upon the written request of Purchaser or at the discretion of Contracting Officer. The amount credited to Purchaser shall be limited to stumpage paid above Base Rates. Any Specified Road construction cost credited to Purchaser pursuant to this Subsection may be refunded or transferred at the request of Purchaser. However, if Purchaser has outstanding debt owing the United States, Contracting Officer must apply the amount of credit that could be refunded to the debt owed in accordance with the Debt Collection Improvement Act of 1996, as amended. Upon written notice from Contracting Officer that the basis for the delay or interruption no longer exists, Purchaser shall pay for timber a per unit amount, in addition to Current Contract Rates, that is equal to the amount credited to Purchaser’s Timber Sale Account divided by 80 percent of the estimated remaining volume of the contract, until the full amount credited to Purchaser has been returned.
Cost of Tendering 8.1 The Tenderer shall bear all costs associated with the preparation and submission of its Tender, and the Procuring Entity shall not be responsible or liable for those costs, regardless of the conduct or outcome of the Tendering process.
Revolving Loans The Borrower shall repay to the Lenders on the Maturity Date the aggregate principal amount of all Revolving Loans outstanding on such date.
E-RATE Authorized users who receive E-rate funding are encouraged to review Universal Service Fund rules and regulations to verify the applicability of this Contract to the E-rate program. NEW YORK STATE RIGHTS OGS Reserved Rights New York State reserves the right to:
