Contracting Parties Assignment Sample Clauses

Contracting Parties Assignment. (a) The Contracting Parties shall not sell, assign, transfer, charge, mortgage, encumber, dispose of or otherwise alienate all or any part of any interest, whether legal or beneficial, in this Project Agreement, the Construction Contract or any other Implementing Agreement without the prior written consent of Hospital, which consent may be unreasonably withheld or delayed. (b) Section 6.1(a) shall not apply to: (i) the grant of security or any other interest to Lender under any of the Lending Agreements or any agreement collateral thereto between Lender and Contractor; or (ii) any subcontract or any sub-subcontract entered into by Project Co or the Contractor or their subcontractors in connection with the Project.
View SourceView Similar (10)
Contracting Parties Assignment. (a) The Contracting Parties shall not sell, assign, transfer, charge, mortgage, encumber, dispose of or otherwise alienate all or any part of any interest, whether legal or beneficial, in this Project Agreement, the Construction Contract or any other Implementing Agreement without the prior written consent of Hospital, which consent may be unreasonably withheld or delayed.‌ (b) Section 6.1 (a) shall not apply to: (i) the grant of security or any other interest to Lender under any of the Lending Agreements or any agreement collateral thereto between Lender and Contractor; (ii) any subcontract or any sub-subcontract entered into by Project Co or the Contractor or their subcontractors in connection with the Project; or (iii) the sale, assignment or transfer (the “Transfer”) by Project Co, within the first ninety (90) days after the date of Financial Close, of all of Project Co’s legal and beneficial interest in this Project Agreement, the Construction Contract and the other Implementing Agreements (collectively, the “Rights”) to [REDACTED] “Transferee”), provided that (A) Project Co has obtained the prior written consent of Agent and Lender to the Transfer; (B) [REDACTED] shall be controlled by the same Person or Persons that controlled Project Co as of the date of Financial Close; (C) the proposed Transferee enters into an agreement with Hospital, in form and substance satisfactory to Hospital, acting reasonably, and any other party to this Project Agreement, the Construction Contract and the other Implementing Agreements wherein the Transferee acquires the Rights and assumes the obligations of Project Co under this Project Agreement, the Construction Contract and the other Implementing Agreements and agrees to perform all of the obligations and observe all of the covenants of Project Co in respect of this Project Agreement, the Construction Contract and the other Implementing Agreements; (D) Project Co has obtained the prior written consent of Hospital to the Transfer, not to be unreasonably withheld or delayed; (E) the bonds referred to in GC 11.2.1 of the Construction Contract are replaced by bonds identical in form and substance thereto except that the Transferee shall be an obligee thereunder and the Subguard Policy (as defined in GC 11.2.4 of the Construction Contract) is replaced by a policy identical in form and substance thereto except that the Transferee shall be insured thereunder, the whole subject to the approval of Hospital, acting reasonably; a...
View Source

Related to Contracting Parties Assignment

  • Subcontracting; Assignment The Contractor may not subcontract any portion of the services provided under this Contract without obtaining the prior written approval of the Procurement Officer, nor may the Contractor assign this Contract or any of its rights or obligations hereunder, without the prior written approval of the Procurement Officer provided, however, that a contractor may assign monies receivable under a contract after due notice to the State. Any subcontracts shall include such language as may be required in various clauses contained within this Contract, exhibits, and attachments. The Contract shall not be assigned until all approvals, documents, and affidavits are completed and properly registered. The State shall not be responsible for fulfillment of the Contractor’s obligations to its subcontractors.

  • SUBCONTRACTS - ASSIGNMENT Contractor shall not subcontract or assign this Agreement, or any part thereof, or interest therein, directly or indirectly, voluntarily or involuntarily, to any person without obtaining the prior written consent by County. Contractor remains legally responsible for the performance of all contract terms including work performed by third parties under subcontracts. Any subcontracting will be subject to all applicable provisions of this Agreement. Contractor shall be held responsible by County for the performance of any subcontractor whether approved by County or not. Contractor hereby assigns to the County all rights, title, and interest in and to all causes of action it may have under Section 4 of the ▇▇▇▇▇▇▇ Act (15 U.S.C. Sec. 15) or under the ▇▇▇▇▇▇▇▇▇▇ Act (Chapter 2 (commencing with Section 16700) of Part 2 of Division 7 of the Business and Professions Code), arising from the purchase if goods, materials, or services by the Contractor for sale to the County pursuant to this Agreement.

  • Inventions Assignment During the Employment Period, the Executive shall promptly disclose, grant and assign to the Company for its and its Affiliates’ sole use and benefit any and all inventions, improvements, technical information and suggestions reasonably relating to the business of the Company and its Affiliates (collectively, the “Inventions”) that the Executive may develop or acquire during the Employment Period (whether or not during usual working hours), together with all patent applications, letters patent, copyrights and reissues thereof that may at any time be granted for or with respect to the Inventions. In connection with the previous sentence, the Executive shall, at the expense of the Company, including a reasonable payment based on the Executive’s last per diem earnings with the Company for the time involved if (a) the Executive is not then in the Company’s employ, or (b) if the Executive is not then receiving severance payments pursuant to Section 8(b) above, or (c) if the Executive has not otherwise received one or more severance payments with respect to such period (whether on a lump sum, pre-paid, or accelerated basis or otherwise), (i) promptly execute and deliver such applications, assignments, descriptions and other instruments as may be necessary or proper in the opinion of the Company to vest title to the Inventions and any patent applications, patents, copyrights, reissues or other proprietary rights related thereto in the Company and to enable it to obtain and maintain the entire right and title thereto throughout the world, and (ii) render such reasonable assistance to the Company as may be required in the prosecution of applications for said patents, copyrights, reissues or other proprietary rights, in the prosecution or defense of interferences or infringements that may be declared involving any said applications, patents, copyrights or other proprietary rights and in any litigation in which the Company may be involved relating to the Inventions. The covenant contained in this Section 11 shall survive the termination or expiration of the Employment Period and any termination of this Agreement.

  • Contracting Parties The Government customer (Licensee) is the “Ordering Activity”, “defined as an entity authorized to order under GSA contracts as set forth in GSA ORDER 4800.2G ADM, as may be revised from time to time. The Licensee cannot be an individual because any implication of individual licensing triggers the requirements for legal review by Federal Employee unions. Conversely, because of competition rules, the contractor must be defined as a single entity even if the contractor is part of a corporate group. The Government cannot contract with the group, or in the alternative with a set of contracting parties.

  • Enforcement of Due-on-Sale Clauses; Assumption and Modification Agreements; Certain Assignments (a) When any Mortgaged Property is conveyed by the Mortgagor, the Master Servicer or Subservicer, to the extent it has knowledge of such conveyance, shall enforce any due-on-sale clause contained in any Mortgage Note or Mortgage, to the extent permitted under applicable law and governmental regulations, but only to the extent that such enforcement will not adversely affect or jeopardize coverage under any Required Insurance Policy. Notwithstanding the foregoing: (i) the Master Servicer shall not be deemed to be in default under this Section 3.13(a) by reason of any transfer or assumption which the Master Servicer is restricted by law from preventing; and (ii) if the Master Servicer determines that it is reasonably likely that any Mortgagor will bring, or if any Mortgagor does bring, legal action to declare invalid or otherwise avoid enforcement of a due-on-sale clause contained in any Mortgage Note or Mortgage, the Master Servicer shall not be required to enforce the due-on-sale clause or to contest such action. (b) Subject to the Master Servicer's duty to enforce any due-on-sale clause to the extent set forth in Section 3.13(a), in any case in which a Mortgaged Property is to be conveyed to a Person by a Mortgagor, and such Person is to enter into an assumption or modification agreement or supplement to the Mortgage Note or Mortgage which requires the signature of the Trustee, or if an instrument of release signed by the Trustee is required releasing the Mortgagor from liability on the Mortgage Loan, the Master Servicer is authorized, subject to the requirements of the sentence next following, to execute and deliver, on behalf of the Trustee, the assumption agreement with the Person to whom the Mortgaged Property is to be conveyed and such modification agreement or supplement to the Mortgage Note or Mortgage or other instruments as are reasonable or necessary to carry out the terms of the Mortgage Note or Mortgage or otherwise to comply with any applicable laws regarding assumptions or the transfer of the Mortgaged Property to such Person; provided, however, none of such terms and requirements shall either (i) both (A) constitute a "significant modification" effecting an exchange or reissuance of such Mortgage Loan under the REMIC Provisions and (B) cause any portion of any REMIC formed under the Series Supplement to fail to qualify as a REMIC under the Code or (subject to Section 10.01(f)), result in the imposition of any tax on "prohibited transactions" or (ii) constitute "contributions" after the start-up date under the REMIC Provisions. The Master Servicer shall execute and deliver such documents only if it reasonably determines that (i) its execution and delivery thereof will not conflict with or violate any terms of this Agreement or cause the unpaid balance and interest on the Mortgage Loan to be uncollectible in whole or in part, (ii) any required consents of insurers under any Required Insurance Policies have been obtained and (iii) subsequent to the closing of the transaction involving the assumption or transfer (A) the Mortgage Loan will continue to be secured by a first mortgage lien pursuant to the terms of the Mortgage, (B) such transaction will not adversely affect the coverage under any Required Insurance Policies, (C) the Mortgage Loan will fully amortize over the remaining term thereof, (D) no material term of the Mortgage Loan (including the interest rate on the Mortgage Loan) will be altered nor will the term of the Mortgage Loan be changed and (E) if the seller/transferor of the Mortgaged Property is to be released from liability on the Mortgage Loan, such release will not (based on the Master Servicer's or Subservicer's good faith determination) adversely affect the collectability of the Mortgage Loan. Upon receipt of appropriate instructions from the Master Servicer in accordance with the foregoing, the Trustee shall execute any necessary instruments for such assumption or substitution of liability as directed in writing by the Master Servicer. Upon the closing of the transactions contemplated by such documents, the Master Servicer shall cause the originals or true and correct copies of the assumption agreement, the release (if any), or the modification or supplement to the Mortgage Note or Mortgage to be delivered to the Trustee or the Custodian and deposited with the Mortgage File for such Mortgage Loan. Any fee collected by the Master Servicer or such related Subservicer for entering into an assumption or substitution of liability agreement will be retained by the Master Servicer or such Subservicer as additional servicing compensation. (c) The Master Servicer or the related Subservicer, as the case may be, shall be entitled to approve a request from a Mortgagor for a partial release of the related Mortgaged Property, the granting of an easement thereon in favor of another Person, any alteration or demolition of the related Mortgaged Property (or, with respect to a Cooperative Loan, the related Cooperative Apartment) without any right of reimbursement or other similar matters if it has determined, exercising its good faith business judgment in the same manner as it would if it were the owner of the related Mortgage Loan, that the security for, and the timely and full collectability of, such Mortgage Loan would not be adversely affected thereby and that any portion of any REMIC formed under the Series Supplement would not fail to continue to qualify as a REMIC under the Code as a result thereof and (subject to Section 10.01(f)) that no tax on "prohibited transactions" or "contributions" after the startup day would be imposed on any such REMIC as a result thereof. Any fee collected by the Master Servicer or the related Subservicer for processing such a request will be retained by the Master Servicer or such Subservicer as additional servicing compensation. (d) Subject to any other applicable terms and conditions of this Agreement, the Trustee and Master Servicer shall be entitled to approve an assignment in lieu of satisfaction with respect to any Mortgage Loan, provided the obligee with respect to such Mortgage Loan following such proposed assignment provides the Trustee and Master Servicer with a "Lender Certification for Assignment of Mortgage Loan" in the form attached hereto as Exhibit M, in form and substance satisfactory to the Trustee and Master Servicer, providing the following: (i) that the substance of the assignment is, and is intended to be, a refinancing of such Mortgage; (ii) that the Mortgage Loan following the proposed assignment will have a rate of interest at least 0.25 percent below or above the rate of interest on such Mortgage Loan prior to such proposed assignment; and (iii) that such assignment is at the request of the borrower under the related Mortgage Loan. Upon approval of an assignment in lieu of satisfaction with respect to any Mortgage Loan, the Master Servicer shall receive cash in an amount equal to the unpaid principal balance of and accrued interest on such Mortgage Loan and the Master Servicer shall treat such amount as a Principal Prepayment in Full with respect to such Mortgage Loan for all purposes hereof.