Contract Time Extension Clause Samples

Contract Time Extension. The Contractor shall perform fully, entirely, and in an acceptable manner, the Work within the Contract Time stated in this Agreement. Contractor shall notify the City on writing, not less than ten (days) prior to end of the Contract Time if the Contractor finds it impossible to complete the Work. Contractor shall detail fully in the request reasons for the extension. The City, in its sole discretion, may grant an extension if the Work has been delayed on account of unusual circumstances beyond the control of the Contractor, or that quantities of the Work done or to be done are in excess of estimated quantities in sufficient amount to warrant the extension for the completion to such date as may seem reasonable and proper.
View SourceView Similar (9)
Contract Time Extension. Contractor shall perform fully, entirely, and in an acceptable manner, the Work within the Contract Time stated in this Agreement. If Contractor determines it is impossible to complete the Work within the Contract Time, Contractor shall request an extension from the City, in writing, not less than ten days prior to end of the Contract Time. Contractor’s extension request shall detail fully in the reasons for the requested extension. The City, in its sole discretion, may grant or deny Contractor’s extension request. The City will only grant extension requests if the Work has been delayed by circumstances beyond Contractor’s control, or if the Material quantities substantially exceed the estimated quantities.
View SourceView Similar (3)
Contract Time Extension. The Contractor shall perform fully, entirely, and in an acceptable manner, the Work within the Contract Time stated in this Agreement. Contractor shall notify the City on writing, not less than ten (days) prior to end of the Contract Time if the Contractor finds it impossible to complete the Work. Contractor shall detail fully in the request reasons for the extension. The City, in its sole discretion, may grant an extension if the Work has been delayed on account of unusual circumstances beyond the control of the Contractor, or that quantities of the Work done or to be done are in excess of estimated quantities in sufficient amount to warrant the extension for the completion to such date as may seem reasonable and proper. Contractor certifies that an examination has been made of the scope and location of work and proposes to furnish all necessary machinery, equipment, tools, labor and other means for the Work and to furnish all materials specified in the manner and at the time prescribe; and understands that the quantities of work shown herein are approximate only and are subject to increase or decrease; and further understands all quantities of work, whether increased or decreased, are to be performed at the following unit prices. 2021.501 Mobilization Lump Sum 1 $ $ 2355.506 Bituminous Material – Fog Seal Gal 1,710 $ $ 2563.501 Traffic Control Lump Sum 1 $ $ 2573.530 Inlet Protection Each 46 $ $ THIS AGREEMENT is made this 13th day of March, 2021 (the “Effective Date”) by and between
View Source
Contract Time Extension. A. The Contractor shall complete the work in a manner acceptable to the Owner within the time stated in the Contract. B. The Number of days allowed for the completion of the work included in the contract has been fixed by the Owner, and is stated in the Agreement and Notice to Proceed. C. In the event of unusual or changed conditions which affect or delay the prosecution and completion of the work, the Engineer will, upon written request from the Contractor, authorize such extension of time as in his judgment, is fair and reasonable.
View Source
Contract Time Extension. The Library may grant an extension of Contract Time when a controlling item of work on the critical path of ▇▇▇▇’▇ progress schedule is delayed by factors not reasonably anticipated or foreseeable at the time of bid. Such time extension may be allowed only for delays occurring during the time for performance set forth in the progress schedule. Extensions of Contract Time will not be granted for delays due, in whole or in part, to the fault or negligence of ▇▇▇▇ or any entity or person for whom ▇▇▇▇ is responsible. Utility Conflicts, Relocation, and Adjustment Delays – The ▇▇▇▇ is solely responsible for the coordination and resolution of all utility conflicts, relocations, and adjustments. Delays resulting from the resolution of utility conflicts, relocations, and adjustments to utilities will not be considered as the basis for granting a change in Contract Amount or Contract Time.
View Source

Related to Contract Time Extension

  • Time Extension CONTRACTOR shall provide a time extension request on completion of Task Order for delays caused by others (Permitting Agencies, COUNTY or Contract Cities, or unforeseen conditions such as inclement weather, etc.) and at no fault by CONTRACTOR, subject to approval by COUNTY. COUNTY will review the request and determine in its sole discretion whether the situation warrant a time extension at no-cost or with costs. If CONTRACTOR completes the Task Order beyond the stipulated completion date without COUNTY’s specific written approval for time extension, CONTRACTOR will be subject to liquidated damages and may be construed as non-responsive, which may affect CONTRACTOR for considerations for future Task Orders or projects.

  • Time Extensions 2.03.1 If Contractor requests an extension of time to complete its performance, then the Director, in consultation with the CPO, may, in his or her sole discretion, extend the time so long as the extension does not exceed 90 days. The extension must be in writing but does not require amendment of this Agreement. Contractor is not entitled to damages for delay(s) regardless of the cause of the delay(s).

  • Contract Extension The Contract is extended for a period of six (6) months pursuant to the same terms and conditions of the contract and any executed written amendments, with a new Contract expiration date of May 31, 2025.

  • Lease Extension If this Lease shall not have been terminated --------------- pursuant to any provisions hereof and there is no Material Breach (as defined herein) by Tenant hereunder at the time set for exercise of the Extension Terms (as herein defined) and at the time set for commencement thereof, then Tenant may, at Tenant's option, extend the term of this Lease for five (5) successive additional terms of four (4) years each (each an "Extension Term," collectively the "Extension Terms") commencing on the expiration of the original term, or the immediately preceding Extension Term, as the case may be. Tenant may exercise such option by giving Landlord written notice at least ten (10) months prior to the expiration of the original or the immediately preceding Extension Term, as the case may be. Upon the giving by Tenant to Landlord of such written notice and the compliance by Tenant with the foregoing provisions of this Paragraph 15, this Lease shall be deemed to be automatically extended upon all the Covenants, agreements, terms, provisions and conditions set forth in this Lease, except that Base Rent for each such Extension Term shall be as provided on Exhibit D. If Tenant fails or omits to so give to Landlord the written notice referred to above, Landlord shall provide Tenant with written notice of Tenant's failure to exercise the Extension Term, and upon receipt of such notice, Tenant shall be allowed fifteen (15) days to exercise the extension option allowed for herein. If Landlord fails to provide such notice, Tenant's renewal option shall expire upon the expiration of the then current term. Failure to respond to Landlord's notice within such fifteen (15) days shall be deemed to be a waiver by Tenant of its extension option hereunder.

  • Term of Contract; Contract Extension The Contract will be in effect from the Effective Date (15 December 2016) through 31 December 2018. DAS, in its sole discretion, may extend this Contract for additional terms beyond the original term, prior to Termination or expiration, one or more times for a combined total period not to exceed the complete length of the original term.