Common use of CONTRACT DATA Clause in Contracts

CONTRACT DATA. CONTRACT DATA Items marked "N/A" do not apply in this Contract. The following documents are also part of the Contract: Clause Reference · The Schedule of Operating and Maintenance Manuals [58] (N/A) · The Schedule of Other Contractors [8] · The Schedule of Key Personnel [9] · The Methodology and Program of Construction & Environmental Management Plan [27] · The Schedule of Key and Critical equipment to be deployed [27] on the work as per agreed program of construction · Site Investigation reports [14] The Borrower is Government of India/ Govt. of M.P. [1.1] The World Bank means International Bank for Reconstruction and Development (IBRD) [1.1] and loan refers to an I.B.R.D. Loan The Employer is Name: Government of Madhya Pradesh, Water Resources Department [1.1] Address: Mantralaya, Bhopal. Name of authorized Representative: Chief Engineer, Chambal Betwa Basin, Water Resources Department Bhopal (M.P.) The Engineer is [1.1] Name: Executive Engineer, Address: Water Resources Division, Narsingarh (M.P.) Name of Authorized Representative: Sub Divisional Officer Water Resources Sub Division. Narsinghgarh (M.P.) The Adjudicator appointed jointly by the Employer and Contractor is: *Name : Mr……………………………………………. *Address: …………………………………………………. The name and identification number of the Contract is RESTRUCTURING AND MODERNIZATION OF HEAD WORKS AND CANALS OF XXXXXXX XXX AND TINONIA TANK [1.1] The Works consist of- The Works consist of Re-sectioning of dam & spill channel, repair of sluice, repairing of pitching of main bund, re-sectioning of canal in selected reaches and lining in U/S and D/S of existing structures (1.1) The Start Date shall be the date of issue of notice to proceed with the work. [1.1] The Intended Completion Date for the whole of the Works is 22 months with the following milestones. Milestone dates Financial progress to be achieved Period from the date of issue of work order notice to proceed with the work Milestone-1 10% 08 Months Milestone-2 50% 16 Months Milestone-3 100 % 22 Months The following documents also form part of the Contract: [2.3] NIL The Contractor shall submit a revised Program including Environmental Management Plan for the Works (in such form and detail as the Engineer shall reasonably prescribe) within 15 days of delivery of the Letter of Acceptance. [27]

CONTRACT DATA. CONTRACT DATA Items marked "N/A" do not apply in this Contract. The following documents are also part of the Contract: Clause Reference · The Schedule of Operating and Maintenance Manuals [58] (N/A) · The Schedule of Other Contractors [8] · The Schedule of Key Personnel [9] · The Methodology and Program of Construction & Environmental Management Plan [27] · The Schedule of Key and Critical equipment to be deployed [27] on the work as per agreed program of construction · Site Investigation reports [14] The Borrower is Government of India/ Govt. of M.P. [1.1] The World Bank means International Bank for Reconstruction and Development (IBRD) [1.1] and loan refers to an I.B.R.D. Loan The Employer is Name: Government of Madhya Pradesh, Water Resources Department [1.1] Address: Mantralaya, Bhopal. Name of authorized Representative: Chief Engineer, Chambal Betwa Basin, Water Resources Department Bhopal (M.P.) Department, Bhopal. The Engineer is [(1.1] ) Name: Executive Engineer, Engineer Address: Water Resources Division, Narsingarh (M.P.) Narsinghgarh Name of Authorized Representative: Sub Divisional Officer Water Resources Sub Division. Officer, Narsinghgarh (M.P.) The Adjudicator appointed jointly by the Employer and Contractor is: *Name : Mr……………………………………………. *Address: …………………………………………………. The name and identification number of the Contract is Bid for RESTRUCTURING AND MODERNIZATION MODERNISATION OF HEAD WORKS AND CANALS OF XXXXXXX XXX AND TINONIA AGAR-AGRI TANK (CB-34) [1.1] The Works consist of- The Works consist of Rere-sectioning and lining of dam & spill channeldistribution network, repair of sluice, repairing canal structures and construction of pitching of main bund, re-sectioning of new canal in selected reaches structures and lining in U/S and D/S of existing structures (1.1) other works. The Start Date shall be the date of issue of notice to proceed with the work. [1.1] The Intended Completion Date for the whole of the Works is 22 24 months with the following milestones. [17, 28] Milestone dates Financial progress to be achieved Period from the date of issue of work order notice to proceed with the work Milestone-1 1025% 08 Months Milestone-2 5060% 16 Months Milestone-3 100 % 22 24 Months The following documents also form part of the Contract: [2.3] NIL The Contractor shall submit a revised Program including Environmental Management Plan for the Works (in such form and detail as the Engineer shall reasonably prescribe) within 15 days of delivery of the Letter of Acceptance. [27]

CONTRACT DATA. CONTRACT DATA Contract Data Items marked "N/A" do not apply in this Contract. The following documents are also part of the Contract: Clause Reference · The Schedule of Operating and Maintenance Manuals [58] (N/A) · The Schedule of Other Contractors [8] · The Schedule of Key Personnel [9] · The Methodology and Program of Construction & Environmental Management Plan [27] · The Schedule of Key and Critical equipment to be deployed [27] on the work as per agreed program of construction · Site Investigation reports [14] The Borrower is Government of India/ Govt. of M.P. [1.1] The World Bank means International Bank for Reconstruction and Development (IBRD) [1.1] and loan refers to an I.B.R.D. Loan The Employer is Name: Government of Madhya Pradesh, Water Resources Department [1.1] Address: Mantralaya, Bhopal. Name of authorized Representative: Chief Engineer, Chambal Betwa Xxxxxxx Xxxxx Basin, Water Resources Department Bhopal Indore (M.P.) ). The Engineer is [1.1] Name: Executive Engineer, Address: Water Resources Gandhi Sagar Dam Division, Narsingarh Gandhi Sagar (M.P.) Name of Authorized Representative: Sub Divisional Officer Water Resources Officer, Xxxxxx Xxxxx Xxx. Sub DivisionDivision No.2 Garoth, Distt. Narsinghgarh Mandsaur (M.P.) The Adjudicator appointed jointly by the Employer and Contractor is: *Name : Mr……………………………………………. *Address: …………………………………………………. The name and identification number of the Contract is RESTRUCTURING AND MODERNIZATION OF HEAD WORKS AND CANALS OF XXXXXXX XXX AND TINONIA Restructuring and Modernization of Head Works and Canals of GOPALPURA TANK [1.1] (NT/8B) The Works consist of- The Works consist of Re-sectioning resectioning of dam & spill channel, repair of sluice, repairing of pitching of main bund, re-sectioning resectioning of canal in selected reaches and lining in U/S and D/S of existing structures (1.1) The Start Date shall be the date of issue of notice to proceed with the work. [1.1] The Intended Completion Date for the whole of the Works is 22 23 months with the following milestones. Milestone dates Financial progress to be achieved Period from the date of issue of work order notice to proceed with the work Milestone-1 1025% 08 Months Milestone-2 5060% 16 Months Milestone-3 100 % 22 23 Months The following documents also form part of the Contract: [2.3] NIL The Contractor shall submit a revised Program including Environmental Management Plan for the Works (in such form and detail as the Engineer shall reasonably prescribe) within 15 days of delivery of the Letter of Acceptance. [27]

CONTRACT DATA. CONTRACT DATA Items marked "N/A" do not apply in this Contract. The following documents are also part of the Contract: Clause Reference · The Schedule of Operating and Maintenance Manuals [58] (N/A) · The Schedule of Other Contractors [8] · The Schedule of Key Personnel [9] · The Methodology and Program of Construction & Environmental Management Plan [27] · The Schedule of Key and Critical equipment to be deployed [27] on the work as per agreed program of construction · Site Investigation reports [14] The Borrower is Government of India/ Govt. of M.P. [1.1] The World Bank means International Bank for Reconstruction and Development (IBRD) [1.1] and loan refers to an I.B.R.D. Loan The Employer is Name: Government of Madhya Pradesh, Water Resources Department [1.1] Address: Mantralaya, Bhopal. Name of authorized Representative: Chief Engineer, Chambal Betwa Basin, Water Resources Department Bhopal (M.P.) The Engineer is [1.1] Name: Executive Engineer, Address: Water Resources Resource Division, Narsingarh Vidisha, (M.P.) Name of Authorized Representative: Sub Divisional Officer Water Resources Sub Division. Narsinghgarh , Basoda (M.P.) The Adjudicator appointed jointly by the Employer and Contractor is: *Name : Mr……………………………………………. [1.1] *Address: …………………………………………………. The name and identification number of the Contract is RESTRUCTURING AND MODERNIZATION OF HEAD WORKS AND CANALS OF XXXXXXX XXX AND TINONIA TANK Restructuring and modernization of Distribution System of Xxxxxx Tank [1.1] The Works consist of- The Works consist of Rere-sectioning and lining of dam & spill channeldistribution network, repair of sluice, repairing canal structures and construction of pitching of main bund, re-sectioning of new canal in selected reaches structures and lining in U/S and D/S of existing structures (1.1) other works. The Start Date shall be the date of issue of notice to proceed with the work. [1.1] The Intended Completion Date for the whole of the Works is 22 20 months with the following milestones. [17, 28] Milestone dates Financial progress to be achieved Period from the date of issue of work order notice to proceed with the work Milestone-1 10% 08 Months Milestone-2 50% 16 Months Milestone-3 100 % 22 20 Months The following documents also form part of the Contract: [2.3] NIL The Contractor shall submit a revised Program including Environmental Management Plan for the Works (in such form and detail as the Engineer shall reasonably prescribe) within 15 days of delivery of the Letter of Acceptance. [27]

CONTRACT DATA. CONTRACT DATA Items marked "N/A" do not apply in this Contract. The following documents are also part of the Contract: Clause Reference · The Schedule of Operating and Maintenance Manuals [58] (N/A) · The Schedule of Other Contractors [8] · The Schedule of Key Personnel [9] · The Methodology and Program of Construction & Environmental Management Plan [27] · The Schedule of Key and Critical equipment to be deployed [27] on the work as per agreed program of construction · Site Investigation reports [14] The Borrower is Government of India/ Govt. of M.P. [1.1] The World Bank means International Bank for Reconstruction and Development (IBRD) [1.1] and loan refers to an I.B.R.D. Loan The Employer is Name: Government of Madhya Pradesh, Water Resources Department [1.1] Address: Mantralaya, Bhopal. Name of authorized Representative: Chief Engineer, Chambal Betwa Xxxxxxx Xxxxx Basin, Water Resources Department Bhopal Indore (M.P.) ). The Engineer is [(1.1] ) Name: Executive Engineer, Address: Water Resources Division, Narsingarh Division Ujjain (M.P.) Name of Authorized Representative: Sub Divisional Officer Water Resources Sub Division. Narsinghgarh Ghattiya, Distt. Ujjain (M.P.) The Adjudicator appointed jointly by the Employer and Contractor is: *Name : Mr……………………………………………. *Address: …………………………………………………. The name and identification number of the Contract is RESTRUCTURING AND MODERNIZATION OF HEAD WORKS AND CANALS OF XXXXXXX XXX AND TINONIA Restructuring and Modernization of Head Works and Canals of DEVIKHEDA TANK (NT/18A) [1.1] The Works consist of- The Works consist of Re-sectioning of dam & spill channel, repair of sluice, repairing of pitching of main bund, re-sectioning of canal in selected reaches and lining in U/S and D/S of existing structures (1.1) The Start Date shall be the date of issue of notice to proceed with the work. [1.1] The Intended Completion Date for the whole of the Works is 22 24 months with the following milestones. Milestone dates Financial progress to be achieved Period from the date of issue of work order notice to proceed with the work Milestone-1 1025% 08 Months Milestone-2 5060% 16 Months Milestone-3 100 % 22 24 Months The following documents also form part of the Contract: [2.3] NIL The Contractor shall submit a revised Program including Environmental Management Plan for the Works (in such form and detail as the Engineer shall reasonably prescribe) within 15 days of delivery of the Letter of Acceptance. [27]

CONTRACT DATA. CONTRACT DATA Items marked "N/A" do not apply in this Contract. The following documents are also part of the Contract: Clause Reference · The Schedule of Operating and Maintenance Manuals [58] (N/A) · The Schedule of Other Contractors [8] · The Schedule of Key Personnel [9] · The Methodology and Program of Construction & Environmental Management Plan [27] · The Schedule of Key and Critical equipment to be deployed [27] on the work as per agreed program of construction · Site Investigation reports [14] The Borrower is Government of India/ Govt. of M.P. [1.1] The World Bank means International Bank for Reconstruction and Development (IBRD) [1.1] and loan refers to an I.B.R.D. Loan The Employer is Name: Government of Madhya Pradesh, Water Resources Department [1.1] Address: Mantralaya, Bhopal. Name of authorized Representative: Chief Engineer, Chambal Betwa Basin, Water Resources Department Bhopal (M.P.) ). The Engineer is [(1.1] ) Name: Executive Engineer, Address: Water Resources Division, Narsingarh Division SEHORE (M.P.) Name of Authorized Representative: Sub Divisional Officer Water Resources Sub Division. Narsinghgarh Dn, Ichhawar Distt Sehore (M.P.) The Adjudicator appointed jointly by the Employer and Contractor is: *Name : Mr……………………………………………. *Address: …………………………………………………. The name and identification number of the Contract is RESTRUCTURING AND MODERNIZATION OF HEAD WORKS WORK AND CANALS OF XXXXXXX XXX AND TINONIA MOONDLA TANK PACKAGE NO. CB/ 32A [1.1] The Works consist of- The Works consist of Rere-sectioning and lining of dam & spill channeldistribution network, repair of sluice, repairing canal structures and construction of pitching of main bund, re-sectioning of new canal in selected reaches structures and lining in U/S and D/S of existing structures (1.1) other works. The Start Date shall be the date of issue of notice to proceed with the work. [1.1] The Intended Completion Date for the whole of the Works is 22 24 months with the following milestones. [17, 28] Milestone dates Financial progress to be achieved Period from the date of issue of work order notice to proceed with the work Milestone-1 1025% 08 Months Milestone-2 5060% 16 Months Milestone-3 100 % 22 24 Months The following documents also form part of the Contract: [2.3] NIL The Contractor shall submit a revised Program including Environmental Management Plan for the Works (in such form and detail as the Engineer shall reasonably prescribe) within 15 days of delivery of the Letter of Acceptance. [27]

CONTRACT DATA. CONTRACT DATA Items marked "N/A" do not apply in this Contract. The following documents are also part of the Contract: Clause Reference · The Schedule of Operating and Maintenance Manuals [58] (N/A) · The Schedule of Other Contractors [8] · The Schedule of Key Personnel [9] · The Methodology and Program of Construction & Environmental Management Plan [27] · The Schedule of Key and Critical equipment to be deployed [27] on the work as per agreed program of construction · Site Investigation reports [14] The Borrower is Government of India/ Govt. of M.P. [1.1] The World Bank means International Bank for Reconstruction and Development (IBRD) [1.1] and loan refers to an I.B.R.D. Loan The Employer is Name: Government of Madhya Pradesh, Water Resources Department [1.1] Address: Mantralaya, Bhopal. Name of authorized Representative: Chief Engineer, Chambal Betwa Xxxxxx Xxxxx Basin, Water Resources Department Bhopal (M.P.) The Engineer is [1.1] Name: Executive Engineer, Address: Water Resources Division, Narsingarh Bhopal (M.P.) Name of Authorized Representative: Sub Divisional Officer Water Resources Sub Division. Narsinghgarh Berasia (M.P.) The Adjudicator appointed jointly by the Employer and Contractor is: *Name : Mr……………………………………………. *Address: …………………………………………………. The name and identification number of the Contract is RESTRUCTURING AND MODERNIZATION OF HEAD WORKS AND CANALS OF XXXXXXX XXX AND TINONIA Restructuring and Modernization of Head Works and Canals of GARETIA TANK & KARONDIA TANK [1.1] The Works consist of- The Works consist of Re-sectioning Resectioning of dam & spill channel, repair of sluice, repairing of pitching of main bund, re-re sectioning of canal in selected reaches and lining in U/S and D/S of existing structures structures, construction new V.R.B, at R.D. 360 m. & R.D. 1185 m. of main canal, repair of escape and V.R.B. 3 no., construction of new C.D. works at R.D. 348 m., 1140 m. & 1590 m. of main canal of Karondia Tank & construction of chute fall at R.D. 105 m. of spill channel, construction of guide bund from R.D. 135 m. to 210 m. on both flank of spill channel, Re-sectioning of main canal and minor 2, 3 & 5 and construction of minor no. 4 and its structure and other work in Garetia Tank (1.1) The Start Date shall be the date of issue of notice to proceed with the work. [1.1] The Intended Completion Date for the whole of the Works is 22 24 months with the following milestones. [17, 28] Milestone dates Financial progress to be achieved Period from the date of issue of work order notice to proceed with the work Milestone-1 1025% 08 Months Milestone-2 5060% 16 Months Milestone-3 100 % 22 24 Months The following documents also form part of the Contract: NIL [2.3] NIL The Contractor shall submit a revised Program including Environmental Management Plan for the Works (in such form and detail as the Engineer shall reasonably prescribe) within 15 days of delivery of the Letter of Acceptance. [27]

CONTRACT DATA. CONTRACT DATA Items marked "N/A" do not apply in this Contract. The following documents are also part of the Contract: Clause Reference · The Schedule of Operating and Maintenance Manuals [58] (N/A) · The Schedule of Other Contractors [8] · The Schedule of Key Personnel [9] · The Methodology and Program of Construction & Environmental Management Plan [27] · The Schedule of Key and Critical equipment to be deployed [27] on the work as per agreed program of construction · Site Investigation reports [14] The Borrower is Government of India/ Govt. of M.P. [1.1] The World Bank means International Bank for Reconstruction and Development (IBRD) [1.1] and loan refers to an I.B.R.D. Loan The Employer is Name: Government of Madhya Pradesh, Water Resources Department [1.1] Address: Mantralaya, Bhopal. Name of authorized Representative: Chief Engineer, Chambal Betwa Ganga Basin, Water Resources Department Bhopal Rewa (M.P.) ). The Engineer is [1.1] Name: Executive Engineer, Address: Water Resources Division, Narsingarh Rewa (M.P.) Name of Authorized Representative: Sub Divisional Officer Water Resources W. R. Survey Sub Division. Narsinghgarh Dn Mauganj (M.P.) The Adjudicator appointed jointly by the Employer and Contractor is: *Name : Mr……………………………………………. *Address: …………………………………………………. The name and identification number of the Contract is RESTRUCTURING AND MODERNIZATION OF HEAD WORKS AND CANALS OF XXXXXXX XXX AND TINONIA TANK Restructuring & Modernization work of Atari and Xxxxxxxx Tank Schemes and their Canal System. (GB-3) [1.1] The Works consist of- The Works consist Restructuring & Modernization work of Re-sectioning of dam & spill channelAtari and Xxxxxxxx Tank Schemes and their Canal System. (GB-3) including lining , repair of sluiceearthwork, road work and other repairing of pitching of main bund, re-sectioning of canal in selected reaches structure and lining in U/S and D/S of existing structures (1.1) other works. The Start Date shall be the date of issue of notice to proceed with the work. [1.1] The Intended Completion Date for the whole of the Works is 22 24 months with the following milestones. [17, 28] Milestone dates Financial progress to be achieved Period from the date of issue of work order notice to proceed with the work Milestone-1 1025% 08 Months Milestone-2 5060% 16 Months Milestone-3 100 % 22 24 Months The following documents also form part of the Contract: [2.3] NIL The Contractor shall submit a revised Program including Environmental Management Plan for the Works (in such form and detail as the Engineer shall reasonably prescribe) within 15 days of delivery of the Letter of Acceptance. [27]

CONTRACT DATA. CONTRACT DATA Items marked "N/A" do not apply in this Contract. The following documents are also part of the Contract: Clause Reference · The Schedule of Operating and Maintenance Manuals [58] (N/A) · The Schedule of Other Contractors [8] · The Schedule of Key Personnel [9] · The Methodology and Program of Construction & Environmental Management Plan [27] · The Schedule of Key and Critical equipment to be deployed [27] on the work as per agreed program of construction · Site Investigation reports [14] The Borrower is Government of India/ Govt. of M.P. [1.1] The World Bank means International Bank for Reconstruction and Development (IBRD) [1.1] and loan refers to an I.B.R.D. Loan The Employer is Name: Government of Madhya Pradesh, Water Resources Department [1.1] Address: Mantralaya, Bhopal. Name of authorized Representative: Chief Engineer, Chambal Betwa Basin, Water Resources Department Bhopal (M.P.) The Engineer is [1.1] Name: Executive Engineer, Address: Water Resources Resource Division, Narsingarh Vidisha, (M.P.) Name of Authorized Representative: Sub Divisional Officer Water Resources Sub Division. Narsinghgarh , Basoda (M.P.) The Adjudicator appointed jointly by the Employer and Contractor is: *Name : Mr……………………………………………. [1.1] *Address: …………………………………………………. The name and identification number of the Contract is RESTRUCTURING AND MODERNIZATION OF HEAD WORKS AND CANALS OF XXXXXXX XXX AND TINONIA TANK Restructuring and modernization of Distribution System of Xxxxxx Tank [1.1] The Works consist of- The Works consist of Rere-sectioning and lining of dam & spill channeldistribution network, repair of sluice, repairing canal structures and construction of pitching of main bund, re-sectioning of new canal in selected reaches structures and lining in U/S and D/S of existing structures (1.1) other works. The Start Date shall be the date of issue of notice to proceed with the work. [1.1] The Intended Completion Date for the whole of the Works is 22 24 months with the following milestones. [17, 28] Milestone dates Financial progress to be achieved Achieved Period from the date of issue of work order notice to proceed with the work Milestone-1 1020% 08 Months Milestone-2 50% 16 Months Milestone-3 100 % 22 24 Months The following documents also form part of the Contract: [2.3] NIL The Contractor shall submit a revised Program including Environmental Management Plan for the Works (in such form and detail as the Engineer shall reasonably prescribe) within 15 days of delivery of the Letter of Acceptance. [27]