CONTRACT DATA. The Consultant is advised to read the NEC3 Professional Service Contract (Third edition with amendments of June 2006 and April 2013) and the relevant Guidance Notes and Flow Charts, published by the Institution of Civil Engineers, in order to understand the implications of this Data which is required. Copies of these documents may be obtained from the Engineering Contract Strategies (telephone (00) 000 000 0000). Each item of data given below is cross-referenced to the clause in the NEC3 Professional Service Contract to which it mainly applies.
CONTRACT DATA. The Conditions of Contract are the NEC3 Professional Services Contract (Third edition with amendments of June 2006 and April 2013) published by the Institution of Civil Engineers, copies of which may be obtained from Engineering Contract Strategies (telephone 000-000 0000). (Amendments made since the publication of the Third Edition of June 2005 may be downloaded from xxxxx://xxx.xxxxxxxxxxx.xxx/getmedia/a3043061-189e-4fce-a7c3-f28caf62cace/PSC.pdf.aspx) Each item of data given below is cross-referenced to the clause in the NEC3 Professional Services Contract which requires it.
CONTRACT DATA. Data provided by the Employer Completion of the data in full is essential to create a complete contract.
CONTRACT DATA. Data provided by the Employer Clause Statement Data General
CONTRACT DATA. CONTRACT DATA Items marked "N/A" do not apply in this Contract. The following documents are also part of the Contract: Clause Reference · The Schedule of Operating and Maintenance Manuals [58] (N/A) · The Schedule of Other Contractors [8] · The Schedule of Key Personnel [9] · The Methodology and Program of Construction & Environmental Management Plan [27] · The Schedule of Key and Critical equipment to be deployed [27] on the work as per agreed program of construction · Site Investigation reports [14] The Borrower is Government of India/ Govt. of M.P. [1.1] The World Bank means International Bank for Reconstruction and Development (IBRD) [1.1] and loan refers to an I.B.R.D. Loan The Employer is Name: Government of Madhya Pradesh, Water Resources Department [1.1] Address: Mantralaya, Bhopal. Name of authorized Representative: Chief Engineer, Xxxxxxx Xxxxx Basin, Water Resources Department Indore (M.P.) The Engineer is [1.1] Name: Executive Engineer, Address: Water Resources Division, Ujjain (M.P.) Name of Authorized Representative: Sub Divisional Officer Water Resources Sub Division. Ghattia (M.P.) The Adjudicator appointed jointly by the Employer and Contractor is: *Name : Mr……………………………………………. *Address: …………………………………………………. The name and identification number of the Contract is Restructuring and Modernization of Head Works and Canals of JASTAKHEDI TANK [1.1]
CONTRACT DATA. Part C1.2b - Data provided by the Contractor Clause Statement Data
CONTRACT DATA. CONTRACT DATA Items marked "N/A" do not apply in this Contract. The following documents are also part of the Contract: Clause Reference · The Schedule of Operating and Maintenance Manuals [58] (N/A) · The Schedule of Other Contractors [8] · The Schedule of Key Personnel [9] · The Methodology and Program of Construction & Environmental Management Plan [27] · The Schedule of Key and Critical equipment to be deployed [27] on the work as per agreed program of construction · Site Investigation reports [14] The Borrower is Government of India/ Govt. of M.P. [1.1] The World Bank means International Bank for Reconstruction and Development (IBRD) [1.1] and loan refers to an I.B.R.D. Loan The Employer is Name: Government of Madhya Pradesh, Water Resources Department [1.1] Address: Mantralaya, Bhopal. Name of authorized Representative: Chief Engineer, Ganga Basin, Water Resources Department Rewa (M.P.). The Engineer is [1.1] Name: Executive Engineer, Address: Water Resources Division, Rewa (M.P.) Name of Authorized Representative: Sub Divisional Officer W. R. Survey Sub Dn Mauganj (M.P.) The Adjudicator appointed jointly by the Employer and Contractor is: *Name : Mr……………………………………………. *Address: …………………………………………………. The name and identification number of the Contract is Restructuring & Modernization work of Atari and Xxxxxxxx Tank Schemes and their Canal System. (GB-3) [1.1] The Works consist of- Restructuring & Modernization work of Atari and Xxxxxxxx Tank Schemes and their Canal System. (GB-3) including lining , earthwork, road work and other repairing of structure and other works. The Start Date shall be the date of issue of notice to proceed with the work. [1.1] The Intended Completion Date for the whole of the Works is 24 months with the following milestones. [17, 28] Milestone dates Financial progress to be achieved Period from the date of issue of work order Milestone-1 25% 08 Months Milestone-2 60% 16 Months Milestone-3 100 % 24 Months The following documents also form part of the Contract: [2.3] NIL The Contractor shall submit a revised Program including Environmental Management Plan for the Works (in such form and detail as the Engineer shall reasonably prescribe) within 15 days of delivery of the Letter of Acceptance. [27]
CONTRACT DATA. Precedence in interpretation of the contract: In the event of any ambiguity, inconsistency or conflict between the General Conditions of Contract, Special Conditions, Pricing Data, Service information, or other, the order of precedence shall be as follows: Firstly, the Service information (C3) and Annexes thereto shall prevail; Secondly the Contract Data (C1.2) and Conditions of Contract; Thirdly the General Conditions of Contract; Fourthly the Pricing data; Lastly any schedules, drawings and other documents included with this agreement. General Conditions of Contract The General Conditions of Contract comprise the NEC3 Term Service Contract, April 2013, published by the NEC, and the following “Particular Conditions”, which include amendments and additions to such General Conditions. The following Particular Conditions amplify the General Conditions of Contract and highlight areas in that document that require specific attention. Wherein in the contract it is stated no contract data is required accordingly the conditions of contract remain unaltered as per NEC3 Term Service Contract, April 2013.
CONTRACT DATA. C1.1 FORM OF OFFER AND ACCEPTANCE (Agreement) OFFER The TENDERER is to complete and sign the Form of Offer The Employer, Identified in the Acceptance signature block, has solicited offers to enter into a contract in respect of the following works;
CONTRACT DATA. PART 2: DATA PROVIDED BY THE CONTRACTOR Clause 4.4.3: Selection of Sub-Contractors The Tenderer shall list in page T.2.3.7 the Subcontractors and Suppliers whom he intends to appoint in respect of the various specialist items of work to be done or goods supplied on this contract. Alternatives may be mentioned. The Tenderer shall state whether he intends to carry out any specialised work or supply of goods himself. Acceptance of this tender shall not be construed as approval of all or any of the listed specialist Subcontractors or Suppliers. Should any of or all of the specialist Subcontractors or Suppliers not be approved subsequent to the acceptance of the tender, it shall in no way invalidate this tender, and the tendered unit rates for the various items of work shall remain final and binding, even in the event of a Subcontractor or Supplier not listed below being approved by the Employer.
