Common use of Conduct of the Work Clause in Contracts

Conduct of the Work. Contractor shall: • Prior to the start of Work, submit to the Administrator, the Contractor Safety Agreement attached as Exhibit E-1, the Department of Industrial Relations Reporting Form attached as Exhibit E-2, and the Workers Compensation Acknowledgement attached as Exhibit E-3 each signed by an authorized representative of Contractor • Submit all required samples, product data, certificates, operations and maintenance instructions, guarantees, and other submittals no later than five (5) days after the date the City issues a Notice to Proceed. • Ensure all necessary permits and approvals for the Work have been obtained. • Protect all materials to be used in the Work in accordance with the specifications. • Protect existing facilities and personal property. • Remove from the project site all debris resulting from performance of the Work no less often than daily. If Contractor fails to do so, City may, after twenty-four (24) hours' notice to Contractor, clean up the site and deduct the cost from the Contract Price. • For projects scheduled to require more than three (3) days to complete, prepare and submit a written daily activity report to City for each day on which work is performed, including weekends and holidays when worked, and submit the reports to the City no later than the next day that the City is open for business. The daily reports shall, at a minimum, include the following information: construction activities and locations, start or completion of activities, progress on construction activities (including units or portions of work completed), tests or inspections performed, deliveries of material or equipment, delays or potential delays, visitors to the site, weather conditions, construction equipment used, and personal injuries or damage to property. • Unload, hoisting and otherwise handling its own materials, supplies and equipment. • Keep itself fully informed of all applicable laws including existing and future state and federal laws and county and municipal ordinances and regulations which in any manner affect those engaged or employed in the work, or the materials used in the work, or which in any way affect the conduct of work, and of all such orders and decrees of bodies or tribunals having any jurisdiction or authority over the same. • Observe and comply with, and cause all of its agents and employees to observe and comply with, all such applicable laws; and shall protect and indemnify the City, and all elected officials, officers, employees, and agents thereof connected with the Work, against any claim or liability arising from or based on the violation of any such law, ordinance, regulation, order, or decree. If any discrepancy or inconsistency is discovered in the plans, drawings, specifications, or contract for the work in relation to any such law, ordinance, regulation, order or decree, Contractor shall forthwith report the same to the Administrator in writing. • Set up, identify, coordinate, provide safe access, and obtain all inspections for its work, as required by any authorized agency or applicable code, prior to covering up work.

Conduct of the Work. Contractor shall: • Prior Do all things necessary to faithfully perform and complete the start Work in a competent manner. • All work shall be performed by experienced personnel directly employed and supervised by the Contractor. The Contractor shall provide management and technical supervision daily through competent supervisor as required. • The Contractor shall be responsible for the skills, methods and actions of Work, submit all employees. • The Contractor shall cooperate to enable the Administrator, Administrator to determine the Contractor Safety Agreement attached as Exhibit E-1, the Department of Industrial Relations Reporting Form attached as Exhibit E-2, Contractor's conformity with these specifications and the Workers Compensation Acknowledgement attached as Exhibit E-3 each signed adequacy of the work being performed. The Contractor shall give personal daily supervision of the work and be available for consultation with the Administrator or an engineer or inspector designated by an authorized representative of Contractor Administrator. • Submit all required samples, product data, certificates, operations and maintenance instructions, guarantees, and other submittals no later than five (5) days after the date the City issues a Notice to Proceed. • Ensure all necessary permits and approvals for the Work have been obtained. • Protect all materials to be used in the Work in accordance with the specifications. • Protect existing facilities and personal property. • Remove from the project site all debris resulting from performance of the Work no less often than daily. If Contractor fails to do so, City may, after twenty-four (24) hours' notice to Contractor, clean up the site and deduct the cost from the Contract Price. • For projects scheduled to require more than three (3) days to complete, prepare and submit a written daily activity report to City for each day on which work is performed, including weekends and holidays when worked, and submit the reports to the City no later than the next day that the City is open for business. The daily reports shall, at a minimum, include the following information: construction activities and locations, start or completion of activities, progress on construction activities (including units or portions of work completed), tests or inspections performed, deliveries of material or equipment, delays or potential delays, visitors to the site, weather conditions, construction equipment used, and personal injuries or damage to property. • Unload, hoisting hoist and otherwise handling handle its own materials, supplies and equipment. • Keep itself fully informed of all applicable laws including existing and future state and federal laws and county and municipal ordinances and regulations which in any manner affect those engaged or employed in the work, or the materials used in the work, or which in any way affect the conduct of work, and of all such orders and decrees of bodies or tribunals having any jurisdiction or authority over the same. • Observe and comply with, and cause all of its agents and employees to observe and comply with, all such applicable laws; and shall protect and indemnify the City, and all elected officials, officers, employees, and agents thereof connected with the Work, against any claim or liability arising from or based on the violation of any such law, ordinance, regulation, order, or decree. If any discrepancy or inconsistency is discovered in the plans, drawings, specifications, or contract for the work in relation to any such law, ordinance, regulation, order or decree, Contractor shall forthwith report the same to the Administrator in writing. • Set up, identify, coordinate, provide safe access, and obtain all inspections for its work, as required by any authorized agency or applicable code, prior to covering up work.

Conduct of the Work. Contractor shall: • Prior to the start of Work, submit to the Administrator, the Contractor Safety Agreement agreement attached as Exhibit E-1A-2, the Department of Industrial Relations Reporting Form form attached as Exhibit E-2A-3, and the Workers Compensation Acknowledgement attached as Exhibit E-3 X- 0 each signed by an authorized representative of Contractor • Submit all required samples, product data, certificates, operations and maintenance instructions, guarantees, and other submittals no later than five (5) days after the date the City issues a Notice to Proceed. • Ensure all necessary permits and approvals for the Work have been obtained. • Protect all materials to be used in the Work in accordance with the specifications. • Protect existing facilities and personal property. • Remove from the project site all debris resulting from performance of the Work no less often than daily. If Contractor fails to do so, City may, after twenty-four (24) hours' notice to Contractor, clean up the site and deduct the cost from the Contract Price. • For projects scheduled to require more than three (3) days to complete, prepare and submit a written daily activity report to City for each day on which work is performed, including weekends and holidays when worked, and submit the reports to the City no later than the next day that the City is open for business. The daily reports shall, at a minimum, include the following information: construction activities and locations, start or completion of activities, progress on construction activities (including units or portions of work completed), tests or inspections performed, deliveries of material or equipment, delays or potential delays, visitors to the site, weather conditions, construction equipment used, and personal injuries or damage to property. • Unload, hoisting and otherwise handling its own materials, supplies and equipment. • Keep itself fully informed of all applicable laws including existing and future state and federal laws and county and municipal ordinances and regulations which in any manner affect those engaged or employed in the work, or the materials used in the work, or which in any way affect the conduct of work, and of all such orders and decrees of bodies or tribunals having any jurisdiction or authority over the same. • Observe and comply with, and cause all of its agents and employees to observe and comply with, all such applicable laws; and shall protect and indemnify the City, and all elected officials, officers, employees, and agents thereof connected with the Work, against any claim or liability arising from or based on the violation of any such law, ordinance, regulation, order, or decree. If any discrepancy or inconsistency is discovered in the plans, drawings, specifications, or contract for the work in relation to any such law, ordinance, regulation, order or decree, Contractor shall forthwith report the same to the Administrator in writing. • Set up, identify, coordinate, provide safe access, and obtain all inspections for its work, as required by any authorized agency or applicable code, prior to covering up work.