Common use of Completion of Construction Work Clause in Contracts

Completion of Construction Work. Upon Final Completion of the Project, Tenant shall furnish Landlord with (a) a certification of the Architect (certified to Landlord) that it has examined the applicable plans and specifications (that shall include the Plans and Specifications in the case of Initial Construction Work or a Restoration of the Project) and that, in its best professional judgment, after diligent inquiry, to its best knowledge and belief, the Construction Work has been completed in accordance with the plans and specifications applicable thereto and, as constructed, the Project complies with all Applicable Laws, (b) if required, a copy or copies of the temporary or permanent certificate(s) of occupancy for the Project issued by the Fairfax County Department of Planning and Development (or such other appropriate Governmental Authority), and (c) with respect to the Initial Construction Work (or a Restoration for which “as built” plans will be issued) of the Project, within ninety (90) days after Substantial Completion, a complete set of “as built” plans and a survey showing the Project. Landlord shall have an unrestricted non-exclusive license to use such “as built” plans and survey in connection with any Restoration of the Project without paying any additional cost or compensation therefor, which license shall be subject to the rights of the parties preparing such plans and survey under copyright and other applicable laws.‌

Completion of Construction Work. Upon Final Completion of the Project, Tenant shall will furnish Landlord with (a) a certification of the Architect (certified to Landlord) that it has examined the applicable plans and specifications (that shall will include the Plans and Specifications in the case of Initial Construction Work or a Restoration of the Project) and that, in its best professional judgment, after diligent inquiry, to its best knowledge and belief, the Construction Work has been completed in accordance with the plans and specifications applicable thereto and, as constructed, the Project complies with all Applicable Laws, (b) if required, a copy or copies of the temporary or permanent certificate(s) of occupancy for the Project issued by the Fairfax County Department of Planning and Development (or such other appropriate Governmental Authority), and (c) with respect to the Initial Construction Work (or a Restoration for which “as built” plans will be issued) of the Project, within ninety (90) 90 days after Substantial Completion, a complete set of “as built” plans and a survey showing the Project. Landlord shall will have an unrestricted non-exclusive license to use such “as built” plans and survey in connection with any Restoration of the Project without paying any additional cost or compensation therefor, which license shall will be subject to the rights of the parties preparing such plans and survey under copyright and other applicable laws.‌laws.

Completion of Construction Work. Upon Final Completion of the Project, Tenant shall furnish Landlord with (a) a certification of the Architect (certified to Landlord) that it has examined the applicable plans and specifications (that shall include the Plans and Specifications in the case of Initial Construction Work or a Restoration of the Project) and that, in its best professional judgment, after diligent inquiry, to its best knowledge and belief, the Construction Work has been completed in accordance with the plans and specifications applicable thereto and, as constructed, the Project complies with all Applicable Laws, (b) if required, a copy or copies of the temporary or permanent certificate(s) of occupancy for the Project issued by the Fairfax County Department of Planning and Development (or such other appropriate Governmental Authority), and (c) with respect to the Initial Construction Work (or a Restoration for which “as built” plans will be issued) of the Project, within ninety (90) days after Substantial Completion, a complete set of “as built” plans and a survey showing the Project. Landlord shall have an unrestricted non-exclusive license to use such “as built” plans and survey in connection with any Restoration of the Project without paying any additional cost or compensation therefor, which license shall be subject to the rights of the parties preparing such plans and survey under copyright and other applicable laws.‌laws.