Completion of Construction Work Sample Clauses

Completion of Construction Work. Upon Substantial Completion of the Project, Tenant shall furnish the FCRHA with (a) a certification of the Architect (certified to the FCRHA) that it has examined the applicable plans and specifications (that shall include the Plans and Specifications in the case of Initial Construction Work or a Restoration of the Project) and that, in its best professional judgment, after diligent inquiry, to its best knowledge and belief, the Construction Work has been substantially completed in accordance with the plans and specifications applicable thereto and, as constructed, the Project complies with all applicable Requirements, (b) if required, a copy or copies of the temporary or permanent certificate(s) of occupancy for the Project issued by the Fairfax County Department of Public Works and Environmental Services (or such other appropriate Governmental Authority), and (c) with respect to the Initial Construction Work (or a Restoration) of the Project, within ninety (90) days of Substantial Completion, a complete set of “as built” plans, in either CADD format, to the extent available, or in field marked copies of the plans, and a survey showing the Project. The FCRHA shall have an unrestricted non-exclusive license to use such “as built” plans and survey for any purpose without paying any additional cost or compensation therefor, which license shall be subject to the rights of the parties preparing such plans and survey under copyright and other applicable laws.
Sample 1Sample 2Sample 3See All (9)
AutoNDA by SimpleDocs
Completion of Construction Work. Upon Final Completion of the Project, Tenant shall furnish Landlord with (a) a certification of the Architect (certified to Landlord) that it has examined the applicable plans and specifications (that shall include the Plans and Specifications in the case of Initial Construction Work or a Restoration of the Project) and that, in its best professional judgment, after diligent inquiry, to its best knowledge and belief, the Construction Work has been completed in accordance with the plans and specifications applicable thereto and, as constructed, the Project complies with all Applicable Laws, (b) if required, a copy or copies of the temporary or permanent certificate(s) of occupancy for the Project issued by the Fairfax County Department of Planning and Development (or such other appropriate Governmental Authority), and (c) with respect to the Initial Construction Work (or a Restoration for which “as built” plans will be issued) of the Project, within ninety (90) days after Substantial Completion, a complete set of “as built” plans and a survey showing the Project. Landlord shall have an unrestricted non-exclusive license to use such “as built” plans and survey in connection with any Restoration of the Project without paying any additional cost or compensation therefor, which license shall be subject to the rights of the parties preparing such plans and survey under copyright and other applicable laws.‌
Sample 1Sample 2See All (4)
Completion of Construction Work. The following procedures shall govern all issues of incomplete construction work, which are not specifically addressed elsewhere in this Agreement:
Sample 1
Completion of Construction Work. Upon substantial completion of a Restoration or a Capital Improvement having a total cost in excess of $250,000, Tenant shall furnish Administrator with (a) a certification of the architect or a licensed professional engineer acceptable to Administrator (certified to Landlord and Administrator) that it has examined the applicable plans and specifications and that, in its best professional judgment, after diligent inquiry, to its best knowledge and belief, the Restoration or the Capital Improvement, as the case may be, has been substantially completed in accordance with the plans and specifications applicable thereto and, as constructed, the Restoration or Capital Improvement, as the case may be, complies with the Building Code of New York City and all other Requirements, (b) a copy or copies of the temporary or permanent (whichever is applicable, if any) Certificate(s) of Occupancy for the relevant portion of the Premises, (c) copies of official certificates evidencing compliance with all Requirements, if any and (d) the most current set of available architectural plans. Tenant shall further furnish Administrator with a complete set of “as built” plans, as of the date a temporary or permanent (whichever is applicable) Certificate of Occupancy is issued, as soon as such are prepared, but in no event later than thirty (30) days after a temporary or permanent (as applicable) Certificate of Occupancy is issued. Administrator shall have a, non-exclusive, irrevocable license to use such “as built” plans and survey for the purpose of completing the Work on the Premises without paying any additional cost or compensation therefor, subject to copyright and similar rights under applicable law of the architect and other Persons who prepared such plans and surveys.
Sample 1
Completion of Construction Work. In case of a plot / land, the construction shall be completed within 2 years and in case of a shed / stall / built-up space, the construction / preparation shall be completed within 1 year from the date of execution of the Deed of Assignment or delivery of possession, whichever is earlier. If there is any delay in completion of the construction or the preparatory work, on justifiable reasons beyond the control of the Assignee, the Assignor may allow such extension as deemed fit and proper.
Sample 1

Related to Completion of Construction Work

  • Completion of Construction (a) For the purposes of this Agreement, the terms "

  • Commencement and Completion of Construction The Company shall begin Construction Activities no later than January 1, 2014 (“Commencement Date”) and secure a final Certificate of Compliance by August 27, 2015 (hereinafter, “Completion Date”).

  • DAF Construction The DAF shall be designed and constructed in accordance with Good Utility Practice. Within one hundred twenty (120) Calendar Days after the Commercial Operation Date, unless the Developer and Connecting Transmission Owner agree on another mutually acceptable deadline, the Developer shall deliver to the Connecting Transmission Owner and NYISO “as- built” drawings, information and documents for the DAF, such as: a one-line diagram, a site plan showing the Large Generating Facility and the DAF, plan and elevation drawings showing the layout of the DAF, a relay functional diagram, relaying AC and DC schematic wiring diagrams and relay settings for all facilities associated with the Developer’s step-up transformers, the facilities connecting the Large Generating Facility to the step-up transformers and the DAF, and the impedances (determined by factory tests) for the associated step-up transformers and the Large Generating Facility. The Developer shall provide to, and coordinate with, Connecting Transmission Owner and NYISO with respect to proposed specifications for the excitation system, automatic voltage regulator, Large Generating Facility control and protection settings, transformer tap settings, and communications, if applicable.

  • ICIF Construction The ICIF shall be designed and constructed in accordance with Good Utility Practice. Within one hundred twenty (120) Calendar Days after the Commercial Operation Date, unless the Parties agree on another mutually acceptable deadline, Interconnection Customer shall deliver to Transmission Provider and Transmission Owner “as-built” drawings, information and documents for the ICIF, such as: a one-line diagram, a site plan showing the Generating Facility and the ICIF, plan and elevation drawings showing the layout of the ICIF, a relay functional diagram, relaying AC and DC schematic wiring diagrams and relay settings for all facilities associated with the Interconnection Customer’s step-up transformers, the facilities connecting the Generating Facility to the step-up transformers and the ICIF, and the impedances (determined by factory tests) for the associated step-up transformers and the Generating Facility. Interconnection Customer shall provide Transmission Provider and Transmission Owner with Interconnection Customer’s specifications for the excitation system, automatic voltage regulator, Generating Facility control and protection settings, transformer tap settings, and communications, if applicable.

  • Commencement of Construction Construction of the Project will start within thirty (30) days after notification to the Developer by the Owner, or as soon thereafter as weather and ground conditions permit.

  • Project Construction The Contractor agrees to provide continuous on-site supervision on each Job Order, while progress on the project is being accomplished. The Contractor’s Project Manager will ensure:

  • New Construction If this contract is for a Property that is newly constructed and the new construction option is selected, coverage begins on day one (1) of month thirteen

  • Pre-Construction Phase Employer’s Liability, Workers’ Compensation, Comprehensive General Liability and Comprehensive Automobile Liability in the amounts as set forth in the UGSC.

  • General Construction 20.2.1. Binding Nature.............................................. 20.2.2. Entire Agreement............................................ 20.2.3. Governing Law............................................... 20.2.4. Indulgences Not Waivers..................................... 20.2.5. Titles Not to Affect Interpretation......................... 20.2.6.

  • Contract Construction 6.27.1 The parties acknowledge that each party and its counsel have reviewed this CONTRACT and that the normal rule of construction to the effect that any ambiguities are to be resolved against the drafting party shall not be employed in the interpretation of this CONTRACT or any amendment or exhibits hereto.

Time is Money Join Law Insider Premium to draft better contracts faster.