Change Order Approval Procedure Sample Clauses

Change Order Approval Procedure. 15.2.6.2.1 During the term of this contract, HHSC or HMO may propose changes in the services, deliverables, or other aspects of this contract ("Changes"), pursuant to the procedures set forth in this article.
AutoNDA by SimpleDocs
Change Order Approval Procedure. (1) During the Initial Term of this Agreement HHSC or CONTRACTOR may propose changes in the Services, Deliverables, or other aspects of this Contract ("Changes"), including, but not limited to, issues that CONTRACTOR contends affects the actuarial soundness of CONTRACTOR's premium, and any such Changes will be implemented pursuant to the procedures set forth in this section 8.02.
Change Order Approval Procedure. In the event a change order for the Commerce Project is required that would result in an increase in Project Costs above the GMP, Developer shall submit such proposed change order for Owner’s Approval and if Owner fails to accept, reject or otherwise take any action with respect thereto within seven (7) Business Days (as hereinafter defined) after Owner’s receipt of such change order, such change order shall be deemed approved by Owner. If Exhibit 10.1 Owner disapproves of any such proposed change order in such seven (7) Business Day period, Owner and Developer shall reasonably cooperate in good faith to resolve the underlying issue necessitating the proposed change order. In the event a proposed change order would increase the Project Budget or the GMP or materially adversely affect the design, appearance, value, or quality of the Commerce Project, or materially extend any completion schedule, then Owner’s approval to such change order may be withheld in Owner’s sole discretion. In the event a proposed change order would not increase the Project Budget or the GMP or materially adversely affect the design, appearance, value, or quality of the Commerce Project, or materially extend any completion schedule, then Owner’s approval to such change order shall not be unreasonably withheld, conditioned or delayed. In any case, net costs associated with any such change order shall be deemed incorporated into the Project Budget and GMP if and to the extent such change order is an Owner Change Order (defined below) and causes the Project Costs to exceed the Project Budget. Following approval of the Plans and Specifications pursuant to Section 3.1 above, the Plans and Specifications may be modified from time to time as required by Owner in its discretion (each, an “Owner Change Order”); provided, however, that Developer’s prior written consent shall be required for any Owner Change Order that would materially alter: (i) the structural components, of the Commerce Project; (ii) the character or intended use of the Commerce Project in a manner that causes the Commerce Project to no longer comply with the Entitlements obtained from the City; (iii) the Project Schedule; or (iv) structural components, use or projected completion date of the Parking Garage; which consent shall not be unreasonably withheld, conditioned or delayed. By way of example and not limitation, additional costs and change orders to address site and construction costs that are shown on, or could be reas...

Related to Change Order Approval Procedure

  • Change Orders Any alteration or deviation from the Services mentioned or any other contractual specifications that result in a revision of this Agreement shall be executed and attached to this Agreement as a change order (“Change Order”).

  • Change Order (5) The Change Order is then submitted to the Project Manager who immediately processes the CO with OPC as required by Bulletin 3.5 and BGS’ Contracting Plan.

  • Approval Process Tenant shall notify Landlord whether it approves of the submitted working drawings within three business days after Landlord’s submission thereof. If Tenant disapproves of such working drawings, then Tenant shall notify Landlord thereof specifying in reasonable detail the reasons for such disapproval, in which case Landlord shall, within five business days after such notice, revise such working drawings in accordance with Tenant’s objections and submit the revised working drawings to Tenant for its review and approval. Tenant shall notify Landlord in writing whether it approves of the resubmitted working drawings within one business day after its receipt thereof. This process shall be repeated until the working drawings have been finally approved by Landlord and Tenant. If Tenant fails to notify Landlord that it disapproves of the initial working drawings within three business days (or, in the case of resubmitted working drawings, within one business day) after the submission thereof, then Tenant shall be deemed to have approved the working drawings in question. Any delay caused by Tenant’s unreasonable withholding of its consent or delay in giving its written approval as to such working drawings shall constitute a Tenant Delay Day (defined below). If the working drawings are not fully approved (or deemed approved) by both Landlord and Tenant by the 15th business day after the delivery of the initial draft thereof to Tenant, then each day after such time period that such working drawings are not fully approved (or deemed approved) by both Landlord and Tenant shall constitute a Tenant Delay Day.

  • Approval of Plans and Specifications The Plans and Specifications will conform to the requirements and conditions set out by applicable law or any effective restrictive covenant, and to all governmental authorities which exercise jurisdiction over the Leased Premises or the construction thereon.

  • Execution of Change Orders Change Orders shall be signed by the Contractor, ordinarily certified by the Design Professional, and approved by the Owner in accordance with the form of Change Order prescribed by the Owner. No request for payment by the Contractor for a Change Order shall be due, nor shall any such request appear on an Application for Payment, until the Change Order is executed by the Owner. In the event of emergency (see Article 1.4.4) or significant impact to the Overall Project Schedule, the Owner shall direct the Change Order to proceed upon a Force Account until the cost and time is resolved in the manner set forth in Paragraph 3.2.7.3 below.

  • Implementation Schedule TIME IS OF THE ESSENCE with regard to all dates and time periods set forth and/or incorporated herein. Any material modification or deviation from an approved schedule described in this Agreement shall occur only upon approval of the City and RDA, with any such approvals required to be in writing as an amendment to this Agreement, and which approvals shall not be unreasonably withheld. City shall cooperate and act promptly with respect to any and all permits or approvals necessary for completion of the Project. Notwithstanding the above, this Agreement shall not limit the discretion of the City, or any of its duly appointed and authorized governing bodies, boards or entities, in approving or rejecting any aspect of the Project or improvements contemplated on or about the Property.

  • Construction Change Directives 7.3.1 A Construction Change Directive is written order prepared by the Architect and signed by the Owner and Architect, directing a change in the Work and stating a proposed basis for adjustment, if any, in the Contract Sum, or Contract Time, or both. The Owner may by Construction Change Directive, without invalidating the Contract, order changes in the Work within the general scope of the Contract consisting of additions, deletions or other revisions, the Contract Sum and Contract Time being adjusting accordingly.

  • ARTICLE GRIEVANCE PROCEDURE The parties to this Agreement are agreed that it is of the utmost importance to adjust complaints and grievances as quickly as possible. Unless agreed to by both the Company and the Union, no grievance shall be presented, the alleged circumstances of which originated or occurred, or should have come to the attention of the employee concerned, more than five (5) working days prior to its original presentation in writing at Step A grievance shall consist of a dispute concerning interpretation and/or application of any Article, Schedule or Clause in this Agreement. Should a grievance arise it shall be handled as follows. Prior to filing a formal grievance, an employee will, with the assistance of his xxxxxxx, refer the on an informal basis to his immediate Supervisor. If the grievance cannot be settled as a result of this discussion, then it may be dealt with as follows: STEP The employee shall a written grievance with his immediate Supervisor within five (5) working days of the incident giving rise to the complaint. The immediate Supervisor shall answer the grievance within five (5) working days. The grievance shall specify the Article or Articles and subsections of the Agreement of which a violation is alleged, indicate the relief sought and be signed by the employee. STEP Should the employee be dissatisfied with the disposition of the grievance at Step the grievance may be referred to the Plant Manager within five (5) working days after receipt of the immediate Supervisor's reply at Step The Plant Manager shall convene a meeting with the and Chief Xxxxxxx and shall answer the grievance in writing within five (5) working days of such meeting. STEP If no settlement is reached at Step the the Union Grievance Committee and representatives of Management shall meet to discuss the grievance within five (5) working days of receipt of the reply of the Plant Manager. The Union's National Representative will be in attendance at this meeting. If the grievance is not settled within five (5) working days it may be referred to arbitration as hereinafter provided. The Union or the Company may initiate a grievance beginning at Step of the Grievance Procedure. Such grievance shall be filed within five (5) working days of the incident giving rise to the complaint and be in the form prescribed in Step Any such grievance may be referred to arbitration under Article by either the Union in the case of a Union grievance or the Company in the case of a Company grievance. The Union may not institute a grievance directly affecting an employee or employees which such employee or employees could themselves institute and the regular Grievance Procedure shall not thereby be by-passed except where the grievance would affect the Bargaining Unit as a whole. This Clause shall not preclude a group grievance signed by a group of employees commencing at Step Any complaint or grievance which is not commenced or processed through the next stage of the Grievance or Arbitration Procedure within the time specified shall be deemed to have been dropped. However, time limits specified in the Grievance Procedure may be extended by mutual agreement in writing between the Company and the Union. An employee who has been discharged or suspended may file a written grievance at Step within five (5) working days of the discharge or suspension. Rolling Sunset Clause: In taking disciplinary action within twenty-four (24) months from the date of a suspension or dismissal (reinstatement) for a similar infraction, the Company may consider the employee's entire record preceding suspension or dismissal (reinstatement), as the case may be. In taking disciplinary action within twelve 2) months from the date of an oral or written warning for a similar infraction, the Company may consider the employee's entire record preceding the employee's oral or written warning, as the case may be.

  • Construction Progress Schedule A schedule indicating proposed activity sequences and durations, milestone dates for receipt and approval of pertinent information, preparation, submittal, and processing of Shop Drawings and Samples, delivery of materials or equipment requiring long-lead time procurement, and proposed date(s) of Material Completion and Occupancy and Final Completion. The schedule will be developed to represent the sixteen or seventeen CSI Specification Divisions. It shall have a minimum number of activities as required to adequately represent to Owner the complete scope of work and define the Project’s critical path and associated activities. If the Project is to be phased, then each individual Phase should be identified from start through completion of the overall Project and should be individually scheduled and described, including any Owner’s occupancy requirements and showing portions of the Project having occupancy priority. The format of the schedule will have dependencies indicated on a monthly grid identifying milestone dates such as construction start, phase construction, structural top out, dry-in, rough-in completion, metal stud and drywall completion, equipment installation, systems operational, Material Completion and Occupancy Date, final inspection dates, Punchlist, and Final Completion date.

  • Implementation of Corrective Action Plan After the Corrective Action Plan is finalized, the Purchasers shall use reasonable best efforts to implement the finalized Corrective Action Plan on the timeline set forth therein and provide periodic reports (as provided for therein) to the Sellers on the status of their implementation of the Corrective Action Plan.

Time is Money Join Law Insider Premium to draft better contracts faster.