Change in Contract Time or Contract Price Sample Clauses

Change in Contract Time or Contract Price. The Contractor may request an extension of time or change in the Contract price should the Work be obstructed or delayed by any justified unavoidable delays not caused in whole or in part by the Contractor, any subcontractor, or suppliers. However, delays caused by weather conditions will not be considered justified unavoidable delays unless they are caused by unusual weather as set forth in Section 4.2 of the Instructions to Bidders, in which case only an extension of time may be considered by City, but no additional compensation will be allowed for unusual weather. Furthermore, Contractor agrees that for any delays not caused by the City or any delays beyond the control of the City, no additional compensation will be due the Contractor and no change in the Contract price will be allowed by the City, only an extension of the Contract time will be considered by the City. The Contractor shall deliver requests for changes in the Contract price and/or completion time in writing to the Director, Department of Public Works within ten (10) calendar days of the occurrence requiring the change. Approved changes that alter the time of the Contract shall extend the completion time by a period equivalent to the cer- tified time lost by such occurrence. No change in Contract price and/or completion time shall be allowed if the above notice has not been properly given, such notice being a condition precedent to any such request by the Contractor. However, the Contractor shall continue with the Work as may be directed by the Director, Department of Public Works and shall not stop work on the Project unless directed to do so by the Director, Department of Public Works. SECTION 20. PAYMENT FOR WORK
Sample 1Sample 2Sample 3See All (10)
AutoNDA by SimpleDocs

Related to Change in Contract Time or Contract Price

  • C1 Contract Price C1.1 In consideration of the Contractor’s performance of its obligations under the Contract, the Authority shall pay the Contract Price in accordance with clause C2 (Payment and VAT).

  • Contract Price 5.01 Owner shall pay Contractor for completion of the Work in accordance with the Contract Documents the amounts that follow, subject to adjustment under the Contract:

  • THE CONTRACT PRICE A. This Contract is an indefinite-quantity contract for construction work and services. The Estimated Annual Value of this Contract is $2,000,000. This is only an estimate and may increase or decrease at the discretion of Sourcewell.

  • Payment and Contract Price C1 Contract Price C2 Payment and VAT C3 Recovery of Sums Due C4 Contract Price During Extension of the Initial Contract Period C5 Euro

  • PRICE ESCALATION/DE-ESCALATION (CPI) The County may allow a price escalation provision within this award. The original contract prices shall be firm for the entirety of the initial (1 year) contract period. A price escalation/de-escalation will be considered at the time of contract renewal and at 1-year intervals thereafter, provided the Contractor notifies the County, in writing, of the pending price escalation/de-escalation a minimum of sixty (60) days prior to the contract renewal date. Price adjustments shall be based on the latest version of the Consumers Price Index (CPI-U) for All Urban Consumers, All Items, U.S. City Average, non-seasonal, as published by the U.S. Department of Labor, Bureau of Labor Statistics. This information is available at xxx.xxx.xxx. Price adjustment shall be calculated by applying the simple percentage model to the CPI data. This method is defined as subtracting the base period index value (at the time of initial award) from the index value at time of calculation (latest version of the CPI published as of the date of request for price adjustment), divided by the base period index value to identify percentage of change, then multiplying the percentage of change by 100 to identify the percentage change. Formula is as follows: Current Index – Base Index / Base Index = % of Change % of Change x 100 = Percentage Change CPI-U Calculation Example: CPI for current period 232.945 Less CPI for base period 229.815 Equals index point change 3.130 Divided by base period CPI 229.815 Equals 0.0136 Result multiplied by 100 0.0136 x 100 Equals percent change 1.4% A price increase may be requested only at each time interval specified above, using the methodology outlined in this section. To request a price increase, Contractor shall submit a letter stating the percentage amount of the requested increase and adjusted price to the Orange County Procurement Division. The letter shall include the complete calculation utilizing the formula above, and a copy of the CPI-U index table used in the calculation. The maximum allowable increase shall not exceed 4%, unless authorized by the Manager, Procurement Division. If approved, the price adjustment shall become effective on the contract renewal date. All price adjustments must be accepted by the Manager, Procurement Division and shall be memorialized by written amendment to this contract. No retroactive contract price adjustments will be allowed. Should the CPI-U for All Urban Consumers, All Items, U.S City Average, as published by the U.S. Department of Labor, Bureau of Labor Statistics decrease during the term of the contract, or any renewals, the Contractor shall notify the Orange County Procurement Division of price decreases in the method outlined above. If approved, the price adjustment shall become effective on the contract renewal date. If the Contractor fails to pass the decrease on to the County, the County reserves the right to place the Contractor in default, cancel the award, and remove the Contractor from the County Vendor List for a period of time deemed suitable by the County. In the event of this occurrence, the County further reserves the right to utilize any options as stated herein.

  • Supervisory Differential Adjustment 99. The Appointing Officer may adjust the compensation of a supervisory employee whose schedule of compensation is set herein subject to the following conditions:

  • Contract Term Adjustment “Contract Term Adjustment” means adjustment only as provided for in the three circumstances described in this Subsection. Under these circumstances, the contract term shall be adjusted in writing to include additional calendar days in one or more Normal Operating Seasons equal to the actual time lost, except as limited by paragraph (b) in this Subsection. To qualify for such adjustment, Purchaser shall give written notice of the lost time not later than 30 days after end of Normal Operating Season in which time was lost and at least 10 days before Termination Date. Contracting Officer shall make prompt written acknowledgment of such notice, indicating concurrence with the number of days in the notice or the number of days Forest Service considers as qualifying for the adjustment. Lost portions of days shall be disregarded in computing time lost. The three circumstances qualifying for a Contract Term Adjustment are:

  • CONDITIONS FOR EMERGENCY/HURRICANE OR DISASTER - TERM CONTRACTS It is hereby made a part of this Invitation for Bids that before, during and after a public emergency, disaster, hurricane, flood, or other acts of God that Orange County shall require a “first priority” basis for goods and services. It is vital and imperative that the majority of citizens are protected from any emergency situation which threatens public health and safety, as determined by the County. Contractor agrees to rent/sell/lease all goods and services to the County or other governmental entities as opposed to a private citizen, on a first priority basis. The County expects to pay contractual prices for all goods or services required during an emergency situation. Contractor shall furnish a twenty-four (24) hour phone number in the event of such an emergency.

  • CFR PART 200 Contract Provisions Explanation Required Federal contract provisions of Federal Regulations for Contracts for contracts with ESC Region 8 and TIPS Members: The following provisions are required to be in place and agreed if the procurement is funded in any part with federal funds. The ESC Region 8 and TIPS Members are the subgrantee or Subrecipient by definition. Most of the provisions are located in 2 CFR PART 200 - Appendix II to Part 200—Contract Provisions for Non-Federal Entity Contracts Under Federal Awards at 2 CFR PART 200. Others are included within 2 CFR part 200 et al. In addition to other provisions required by the Federal agency or non-Federal entity, all contracts made by the non- Federal entity under the Federal award must contain provisions covering the following, as applicable.

  • Early Contract Termination The State may terminate this contract in whole or in part by giving fifteen (15) days written notice to the Purchaser when it is in the best interests of the State. If this contract is so terminated, the State shall be liable only for the return of that portion of the initial deposit that is not required for payment, and the return of unapplied payments. The State shall not be liable for damages, whether direct or consequential.

Time is Money Join Law Insider Premium to draft better contracts faster.