TERMINATION BY THE CONTRACTOR If the Work is stopped for a period of thirty days under an order of any court or other public authority having jurisdiction, or as a result of an act of government, such as a declaration of a national emergency making materials unavailable, through no act or fault of the Contractor or a Subcontractor or their agents or employees or any other persons performing any of the Work under a contract with the Contractor, or if the Work should be stopped for a period of thirty days by the Contractor because the Architect has not issued a Certificate for Payment as provided in Paragraph 9.7 of these General Conditions or because the State has not made payment thereon as provided in Paragraph 9.7, then the Contractor may, upon seven additional days written notice to the State and the Architect, terminate the Contract and recover from the State payment for all Work executed and for any proven loss sustained upon any materials, equipment, tools, construction equipment and machinery, including reasonable profit and damages.
TERMINATION BY MPS - BREACH BY CONTRACTOR If Contractor fails to fulfill its obligations under this Contract in a timely or proper manner, or violates any of its provisions, MPS shall thereupon have the right to terminate it by giving five (5) days written notice before the effective date of termination of the Contract, specifying the alleged violations, and effective date of termination. The Contract shall not be terminated if, upon receipt of the notice, Contractor promptly cures the alleged violation with five (5) days. In the event of termination, MPS will only be liable for services rendered through the date of termination and not for the uncompleted portion, or for any materials or services purchased or paid for by Contractor for use in completing the Contract.
Waiver of Breach The waiver by either party of the breach of any provision of this Agreement shall not operate or be construed as a waiver of any subsequent breach by either party.
Notification of Breach During the term of this Agreement:
Authority; No Breach By Agreement (a) NDC has the corporate power and authority necessary to execute, deliver and perform its obligations under this Agreement and to consummate the transactions contemplated hereby. The execution, delivery and performance of this Agreement and the consummation of the transactions contemplated herein, including the Merger, have been duly and validly authorized by all necessary corporate action in respect thereof on the part of NDC. This Agreement represents a legal, valid, and binding obligation of NDC, enforceable against NDC in accordance with its terms (except in all cases as such enforceability may be limited by applicable bankruptcy, insolvency, reorganization, receivership, conservatorship, moratorium, or similar Laws affecting the enforcement of creditors' rights generally and except that the availability of the equitable remedy of specific performance or injunctive relief is subject to the discretion of the court before which any proceeding may be brought).
Termination of the Contract 11.1. The Coordinator may terminate the contract if the Co-beneficiary has inadequately discharged or failed to discharge any of the contractual obligations, insofar as this is not due to force majeure, after notification of the Co-beneficiary by registered letter has remained without effect for one month.
Event of Breach 7.1 The following circumstances shall be deemed Event of Default:
Damages for delay by the Concessionaire In the event that (i) the Concessionaire does not procure fulfilment of any or all of the Conditions Precedent set forth in Clause 4.1.3 within a period of 180 (one hundred and eighty) days from the date of this Agreement, and (ii) the delay has not occurred as a result of failure to fulfil the obligations under Clause 4.1.2 or other breach of this Agreement by the Authority, or due to Force Majeure, the Concessionaire shall pay to the Authority Damages in an amount calculated at the rate of 0.2% (zero point two per cent) of the Performance Security for each day's delay until the fulfilment of such Conditions Precedent, subject to a maximum of 20% (twenty percent) of the Performance Security.
Repeat Violations Xxxxxx agrees to comply with all regulatory requirements and acknowledges that repeat violations could result in increased penalties in the future.
Non-Waiver of Breach The waiver by any party hereto of the other party’s prompt and complete performance, or breach or violation, of any term or provision of this Agreement shall be effected solely in a writing signed by such party, and shall not operate nor be construed as a waiver of any subsequent breach or violation, and the waiver by any party hereto to exercise any right or remedy which he or it may possess shall not operate nor be construed as the waiver of such right or remedy by such party, or as a bar to the exercise of such right or remedy by such party, upon the occurrence of any subsequent breach or violation.
