Cancellation of Initial Full-Scale Project Sample Clauses

Cancellation of Initial Full-Scale Project. AES shall have the right, in its sole discretion, to cancel the Initial Full-Scale Project within [**] of the Effective Date by written notice to A123 solely as a result of AES's failure (after the exercise of commercially reasonable efforts) to obtain any necessary initial agreement, acknowledgement of rights, approval or permit required for such Project from the responsible independent system operator or similar entity or any regulatory or government body in Chile. If AES elects to cancel the Initial Full-Scale Project, then AES shall provide written notice of cancellation to A123 and, within [**] of such notice, pay A123 an amount equal to the corresponding amount set forth in Exhibit D based on the date of such cancellation, which shall represent A123's sole and exclusive compensation for such cancellation ("Cancellation Fee"). Notwithstanding anything herein to the contrary, if, pursuant to Section 4.1(b), A123 has received payments from AES in excess of the Cancellation Fee, it shall be obligated to reimburse AES in an amount equal to such excess payment within [**] of A123's receipt of the notice of cancellation.
Sample 1Sample 2
AutoNDA by SimpleDocs

Related to Cancellation of Initial Full-Scale Project

  • Completion of Improvements Landlord, through its general contractor (“Contractor”), shall furnish and install within the Premises those items of general design, engineering and construction, shown on the final plans and specifications approved by Landlord and Tenant pursuant to the Schedule of Approvals below, in compliance with all applicable laws, ordinances, codes, rules and regulations and matters of record, and complete any construction required in the Common Areas of the Building when such construction is required by or arises out of completion of such work (collectively the “Improvements”). The contractor constructing the Improvements in the Premises shall be selected pursuant to a procedure whereby the final Plans and Specifications (as such term is defined in this Exhibit B) are submitted to Xxxxxxx Xxxxxx Builders, Inc. (“XXX”) and Pinnacle Contracting Corporation (collectively, the “Approved Contractors”), who shall be requested to each submit to Landlord and to Tenant a sealed contract bid using such forms reasonably acceptable to Landlord in order to provide an “apples to apples” bidding process. The sealed bids shall be delivered to Tenant and Landlord and opened jointly by Landlord and Xxxxxx. Tenant, in Tenant’s sole and absolute discretion, shall select the Contractor from the two Approved Contractors (regardless of which has the lower bid). Each bid from the contractors shall specify any allowances for exclusions and shall further provide that said bids are without overtime premiums or bonuses necessary to complete the Improvements in accordance with the terms hereof. The architect engaged by Xxxxxx to prepare the Space Plan and Plans and Specifications and related design work for the Improvements shall be Xxxxxxx (the “Architect”). Landlord shall disburse amounts of the Allowance (up to the maximum specified below) to Architect within thirty (30) days after receipt of paid invoices from Architect or Tenant for Architect’s services; provided, however, notwithstanding the foregoing, Landlord shall pay $[***] for the Architect’s preparation of the Space Plan (as evidenced by the Architect’s invoice number 68045 dated October 15, 2010), at Landlord’s sole cost and expense (and without using the Allowance or any portion thereof). The definition of Improvements shall include all costs associated with completing the Improvements, including but not limited to, fees payable to Xxxxxxx, space planning, design, architectural, and engineering fees, contracting, labor and material costs, municipal fees, plan check and permit costs, and document development and/or reproduction, and all costs and expenses for any construction manager(s) engaged by Xxxxxx (provided such soft costs for architectural and engineering services charged against the Allowance shall not exceed $[***] per square feet of Usable Area in the Premises) at Tenant’s sole option. The Space Plan and the Plans and Specifications (each as defined in Section 3 of this Exhibit B) shall be subject to Landlord’s prior review and approval, which approval shall not be unreasonably withheld, conditioned or delayed. Landlord’s approval of any iteration of a Space Plan or Plans and Specifications shall be deemed granted unless Landlord provides a reasonable disapproval or approval to Tenant prior to the sixth (6th) business day after Landlord’s receipt of the Space Plan or Plans and Specifications. Without limiting Landlord’s discretion to reasonably withhold its approval, Tenant agrees that it shall be reasonable for Landlord to withhold its approval of any aspect of Tenant’s Space Plan or Plans and Specifications (or, in either case, any proposed changes thereto) which (i) adversely affect Building systems, the structure of the Building or the safety of the Building and/or its occupants, (ii) would violate any governmental laws, rules or ordinances; (iii) would require any changes that adversely impact the base, shell and core of the Building, and/or (iv) are inconsistent with the standards of first class office buildings in the vicinity of the Building, as reasonably determined by Landlord and the Contractor. Landlord shall provide a written statement of any disapproval of any Space Plan or Plans and Specifications stating the reasons for Xxxxxxxx’s disapproval. Tenant acknowledges and agrees that any change in the scope of work or details of construction after Xxxxxx’s and Landlord’s approval of the Plans and Specifications shall constitute a “Change Order”, the costs of which may be charged against any available amounts of the Allowance under this Exhibit B. To the extent the Change Order delays construction of the Improvements, the same shall be a Tenant Delay. [***] = CONFIDENTIAL INFORMATION HAS BEEN OMITTED AND FILED SEPARATELY WITH THE SECURITIES AND EXCHANGE COMMISSION. CONFIDENTIAL TREATMENT HAS BEEN REQUESTED WITH RESPECT TO THIS OMITTED INFORMATION.

  • Construction of Improvements (A) Lessee warrants and agrees that the Building will be constructed on the Leased Premises, and all other improvements to the land, including the parking lot, approaches, and service areas, will be constructed in all material respects by Lessee substantially in accordance with the plot, plans, and specifications heretofore submitted to Lessor.

  • Location of Improvements; No Encroachments All improvements which were considered in determining the Appraised Value of the Mortgaged Property lay wholly within the boundaries and building restriction lines of the Mortgaged Property, and no improvements on adjoining properties encroach upon the Mortgaged Property. No improvement located on or being part of the Mortgaged Property is in violation of any applicable zoning law or regulation;

  • Cancellation of Insurance Allow any insurance policy required to be carried hereunder to be terminated or lapse or expire without provision for adequate renewal thereof.

  • Completion of IPO The IPO shall have been completed.

  • Condition of Improvements The Improvements and the Tangible Personal Property (including but not limited to the mechanical systems, plumbing, electrical, wiring, appliances, fixtures, heating, air conditioning and ventilating equipment, elevators, boilers, equipment, roofs, structural members and furnaces) shall be in the same condition at Closing as they are as of the date hereof, reasonable wear and tear excepted. Prior to Closing, the Contributor shall not have diminished the quality or quantity of maintenance and upkeep services heretofore provided to the Real Property and the Tangible Personal Property and the Contributor shall not have diminished the Inventory. The Contributor shall not have removed or caused or permitted to be removed any part or portion of the Real Property or the Tangible Personal Property unless the same is replaced, prior to Closing, with similar items of at least equal quality and acceptable to the Acquiror.

  • Cancellation of Indebtedness No Credit Party shall cancel any claim or debt owing to it, except for reasonable consideration negotiated on an arm's-length basis and in the ordinary course of its business consistent with past practices.

  • Cancellation of Agreement In the event that prior to the Closing Date (a) trading in securities on the New York Stock Exchange generally, or in securities of the Bank in particular, shall have been suspended, or minimum prices established by the New York Stock Exchange, or any new restrictions on transactions in securities shall have been established by the New York Stock Exchange or by the Commission or by any other United States Federal or State agency or by any action of the United States Congress or by executive order to such a degree as, in your judgment as the Representatives, to affect materially and adversely the marketing of the Securities or (b) existing financial, political or economic conditions in Europe, the United States or elsewhere shall have undergone any change which, in your judgment as the Representatives, would materially and adversely affect the market for the Securities, this Agreement and all obligations of the Underwriters hereunder may be canceled at, or at any time prior to, the Closing Date by you, as the Representatives, without liability on the part of any Underwriter to the Bank or of the Bank to any Underwriter, subject to Section 11(e). Notice of such cancellation shall be given to the Bank in writing, or by cable or telephone confirmed in writing.

  • Notice to Proceed Contractor shall not, and shall not be obligated to, commence performance of the Work (other than the LNTP Work) until Owner issues the full notice to proceed (“Notice to Proceed” or “NTP”) authorizing the same pursuant to the terms and conditions of this Agreement. Upon Contractor’s receipt from Owner of the NTP, Contractor shall promptly commence with the performance of the Work. The NTP shall be issued in the form attached hereto as Attachment H, Schedule H-2. Contractor shall timely file in the required superior court and post at the Site a notice of commencement as required under La. Rev. Stat. §9:4801, et. seq. and shall provide copies of such notice of commencement to Subcontractors and Sub-subcontractors as required under La. Rev. Stat. §9:4801, et. seq. Owner shall not issue an NTP until the following conditions have been met:

  • Cancellation of Notes Paid, Converted, Etc The Company shall cause all Notes surrendered for the purpose of payment at maturity, repurchase upon a Fundamental Change, redemption, registration of transfer or exchange or conversion (other than any Notes exchanged pursuant to Section 14.12), if surrendered to the Company or any of its agents or Subsidiaries, to be surrendered to the Trustee for cancellation. All Notes delivered to the Trustee shall be canceled promptly by it in accordance with its customary procedures. Except for any Notes surrendered for registration of transfer or exchange, or as otherwise expressly permitted by any of the provisions of this Indenture, no Notes shall be authenticated in exchange for any Notes surrendered to the Trustee for cancellation. The Trustee shall dispose of canceled Notes in accordance with its customary procedures and, after such disposition, shall deliver evidence of such disposition to the Company, at the Company’s written request in a Company Order.

Time is Money Join Law Insider Premium to draft better contracts faster.