Building Use Agency facilities may be used for Union activities according to current building use policies, so long as the facility is available and proper scheduling has been arranged.
Maintenance Repairs Utility Installations Trade Fixtures and Alterations (a) Subject to the provisions of Paragraphs 2.2 (Lessor’s warranty as to condition), 2.3 (Lessor’s warranty as to compliance with covenants, etc.), 7.2 (Lessor’s obligations to repair), 9 (damage and destruction), and 14 (condemnation), Lessee shall, at Lessee’s sole cost and expense and at all times, keep the Premises and every part thereof in good order, condition and repair, structural and non-structural (whether or not such portion of the Premises requiring repair, or the means of repairing the same, are reasonably or readily accessible to Lessee, and whether or not the need for such repairs occurs as a result of Lessee’s use, any prior use, the elements or the age of such portion of the Premises), including, without limiting the generality of the foregoing all equipment or facilities serving the Premises, such as plumbing, heating, air conditioning, ventilating, electrical, lighting facilities, boilers, fired or unfired pressure vessels, fire sprinkler and/or standpipe and hose or other automatic fire extinguishing system, including fire alarm and/or smoke detection systems and equipment, fire hydrants, fixtures, walls (interior and exterior), foundations, ceilings, roofs, floors, windows, doors, plate glass, skylights, landscaping, driveways, parking lots, fences, retaining walls, signs, sidewalks and parkways located in, on, about, or adjacent to the Premises. Lessee shall not cause or permit any Hazardous Substance to be spilled or released in, on, under or about the Premises (including through the plumbing or sanitary sewer system) and shall promptly, at Lessee’s expense, take all investigatory and/ore remedial action reasonably recommended, whether or not formally ordered or required, for the cleanup of any contamination of, and for the maintenance, security and/or monitoring of, the Premises, the elements surrounding same, or neighboring properties that was caused or materially contributed to by Lessee, or pertaining to or involving any Hazardous Substance and/or storage tank brought onto the premises by or for lessee or under its control. Lessee, in keeping the Premises in good order, condition and repair, shall exercise and perform good maintenance practices. Lessee’s obligations shall include restorations, replacements or renewals when necessary to keep the Promises and all improvements thereon or a part thereof in good order, condition and state of repair. If Lessee occupies the Premises for seven (7) years or more, lessor may require Lessee to repaint the exterior of the buildings on the Premises as reasonably required, but not more frequently than once every seven (7) years.
Building With respect to each parcel of Real Estate, all of the buildings, structures and improvements now or hereafter located thereon. Business Day. Any day on which banking institutions located in the same city and State as the Agent’s Head Office are located are open for the transaction of banking business and, in the case of LIBOR Rate Loans, which also is a LIBOR Business Day.
SLEEPING CAPACITY/DISTURBANCES Tenant and all other occupants of the premises will be required to vacate the premises and forfeit the rental fee and security deposit for any of the following: Occupancy exceeding the sleeping capacity of the property, using the premises for any illegal activity, causing damage to the premises rented or to any of the neighboring properties and any other acts that interfere with neighbors' right to quiet enjoyment of their premises. HOLD HARMLESS None of iTrip Vacations, Sea Oats Vacation Property Management, Inc. or the owner of the premises assume risk, responsibility or any liability for, and the Tenant hereby releases, waives, relinquishes and discharges iTrip Vacations, Sea Oats Vacation Property Management, Inc., the owner of the premises and all directors, officers, employees, agents or other representatives of such parties from, any (i) loss, damage, illness, injury or exposure to COVID-19, other viruses or the flu to persons or their personal property that occurs during their stay on the premises; (ii) any inconveniences, damage, loss or injury arising from any temporary defects or stoppage in supply of water, gas, cable service, internet service, electricity or plumbing or (iii) any inconveniences, damage, loss or injury arising from or due to weather conditions, insects, natural disasters, acts of God, or other reasons beyond their control. POOL & PATIO If the premises include a private or community pool (including hot tubs), then the Tenant hereby acknowledges that the premises they have reserved include a community pool and the undersigned agrees and acknowledges that the community pool and patio/deck can be dangerous areas, that the deck/patio can be slippery when wet, and that injury may occur to anyone who is not careful. With full knowledge of the above facts and warnings, the undersigned Tenant accepts and assumes all risks involved to Tenant and all of Tenant's guests in or related to the use of the private or community pool (including hot tubs) and patio areas.
Buildings The Employer will provide and maintain all state-owned buildings, facilities, and equipment in accordance with the specific written order(s) of the Michigan Departments of Licensing and Regulatory Affairs and/or Military and Veterans Affairs. Where facilities are leased by the Employer, the Employer shall make every reasonable effort to assure that such facilities comply with the order(s) of the Michigan Departments of Licensing and Regulatory Affairs and/or Military and Veterans Affairs.
Utility Installations Trade Fixtures Alterations 8.3.1 The term “Utility Installations” refers to all floor and window coverings, air and/or vacuum lines, power panels, electrical distribution, security and fire protection systems, communication cabling, lighting fixtures, HVAC equipment, plumbing, and fencing in or on the Premises. The term “
ADJACENT EXCAVATION-SHORING 32. If an excavation shall be made upon land adjacent to the demised premises, or shall be authorized to be made, Tenant shall afford to the person causing or authorized to cause such excavation, license to enter upon the demised premises for the purpose of doing such work as said person shall deem necessary to preserve the wall or the building of which demised premises form a part from injury or damage and to support the same by proper foundations without any claim for damages or indemnity against Owner, or diminution or abatement of rent.
Underground Tanks If underground or other storage tanks storing Hazardous Materials located on the Premises or the Project are used by Tenant or are hereafter placed on the Premises or the Project by Tenant, Tenant shall install, use, monitor, operate, maintain, upgrade and manage such storage tanks, maintain appropriate records, obtain and maintain appropriate insurance, implement reporting procedures, properly close any underground storage tanks, and take or cause to be taken all other actions necessary or required under applicable state and federal Legal Requirements, as such now exists or may hereafter be adopted or amended in connection with the installation, use, maintenance, management, operation, upgrading and closure of such storage tanks.
PREMISES DEEMED UNINHABITABLE If the Premises is deemed uninhabitable due to damage beyond reasonable repair the Tenant will be able to terminate this Agreement by written notice to the Landlord. If said damage was due to the negligence of the Tenant, the Tenant shall be liable to the Landlord for all repairs and for the loss of income due to restoring the Premises back to a livable condition in addition to any other losses that can be proved by the Landlord.
Tenant Delays A "Tenant Delay” shall be defined as any delay in the design, permitting or performance of the Base Building Work to the extent that such delay is actually caused by any act or, where there is a duty to act under this Lease, any failure to act by Tenant or Tenant's contractors, architects, engineers, or anyone else engaged by or on behalf of Tenant in connection with the construction of the Tenant Improvement Work as set forth in this Article III (including, without limitation, any delays resulting from the Approved Tenant Finishes under Section 3.l(C) above) and disclosed to Tenant as hereinafter provided. Notwithstanding the foregoing, in no event shall any delays in the completion of the Base Building Work caused by Tenant’s use of non-union labor constitute a Tenant Delay hereunder. Notwithstanding the foregoing, no event shall be deemed a Tenant Delay unless and until Landlord has given Tenant written notice (the "Tenant Delay Notice") advising Tenant: (x) that a Tenant Delay is occurring and setting forth Landlord's good faith estimate as to the likely length of such Tenant Delay; (y) of the basis on which Landlord has determined that a Tenant Delay is occurring; and (z) the actions which Landlord believes that Tenant must take to eliminate such Tenant Delay. No event shall be deemed to be a Tenant Delay unless and until Tenant has failed to rectify the situation causing the Tenant Delay within forty-eight (48) hours after Tenant's receipt of the Tenant Delay Notice (which for the purposes of determining receipt may be delivered by hand to Tenant's Construction Representative, with copies to follow to Tenant at the notice address set forth in Section 1.2 of this Lease within five (5) days thereafter); provided, however, that if Tenant shall fail to eliminate the delay within the aforesaid 48-hour period, then the 48-hour cure period shall be included in the period of time charged to Tenant pursuant to such Tenant Delay Notice (it being understood and agreed that if Tenant shall in fact eliminate the Tenant Delay within the 48-hour cure period, no Tenant Delay shall be deemed to have occurred for the purposes of this Article III). In addition, any delay to the extent caused by (i) Landlord Delay or (ii) subject to the limitations of subsection (D) below, Tenant's Force Majeure (as defined in said subsection (D)) shall not constitute Tenant Delay. Tenant covenants that no Tenant Delay shall delay commencement of the Term or the obligation to pay Annual Fixed Rent or Additional Rent. The Delivery Dates and/or the date of substantial completion of the Base Building Work, as applicable, shall be deemed to have occurred as of the date when such Delivery Dates and/or date of substantial completion of the Base Building Work, as applicable, would have occurred but for any Tenant Delays, as determined by Landlord in the exercise of its good faith business judgment (it being understood and agreed that the foregoing shall not be construed so as to relieve Landlord of its obligation to actually complete the Base Building Work, notwithstanding the fact that substantial completion may have been deemed to have occurred prior to actual completion as the result of Tenant Delays).
