Window Coverings No curtains, draperies, blinds, shutters, shades, awnings, screens or other coverings, window ventilators, hangings, decorations or similar equipment shall be attached to, hung or placed in, or used in or with any window of the Building without the prior written consent of Landlord, and Landlord shall have the right to control all lighting within the Premises that may be visible from the exterior of the Building.
Vacation, Holidays and Sick Leave During the Term, the Executive shall be entitled to paid vacation, paid holidays and sick leave in accordance with the Company's standard policies for its senior executive officers.
Elevator Service If the Building is equipped with elevators, Landlord, during Normal Business Hours of Building, shall furnish elevator service to Tenant to be used in common with others. At least one elevator shall remain in service during all other hours. Landlord may designate a specific elevator for use as a service elevator.
Tenant Delays A "Tenant Delay” shall be defined as any delay in the design, permitting or performance of the Base Building Work to the extent that such delay is actually caused by any act or, where there is a duty to act under this Lease, any failure to act by Tenant or Tenant's contractors, architects, engineers, or anyone else engaged by or on behalf of Tenant in connection with the construction of the Tenant Improvement Work as set forth in this Article III (including, without limitation, any delays resulting from the Approved Tenant Finishes under Section 3.l(C) above) and disclosed to Tenant as hereinafter provided. Notwithstanding the foregoing, in no event shall any delays in the completion of the Base Building Work caused by Tenant’s use of non-union labor constitute a Tenant Delay hereunder. Notwithstanding the foregoing, no event shall be deemed a Tenant Delay unless and until Landlord has given Tenant written notice (the "Tenant Delay Notice") advising Tenant: (x) that a Tenant Delay is occurring and setting forth Landlord's good faith estimate as to the likely length of such Tenant Delay; (y) of the basis on which Landlord has determined that a Tenant Delay is occurring; and (z) the actions which Landlord believes that Tenant must take to eliminate such Tenant Delay. No event shall be deemed to be a Tenant Delay unless and until Tenant has failed to rectify the situation causing the Tenant Delay within forty-eight (48) hours after Tenant's receipt of the Tenant Delay Notice (which for the purposes of determining receipt may be delivered by hand to Tenant's Construction Representative, with copies to follow to Tenant at the notice address set forth in Section 1.2 of this Lease within five (5) days thereafter); provided, however, that if Tenant shall fail to eliminate the delay within the aforesaid 48-hour period, then the 48-hour cure period shall be included in the period of time charged to Tenant pursuant to such Tenant Delay Notice (it being understood and agreed that if Tenant shall in fact eliminate the Tenant Delay within the 48-hour cure period, no Tenant Delay shall be deemed to have occurred for the purposes of this Article III). In addition, any delay to the extent caused by (i) Landlord Delay or (ii) subject to the limitations of subsection (D) below, Tenant's Force Majeure (as defined in said subsection (D)) shall not constitute Tenant Delay. Tenant covenants that no Tenant Delay shall delay commencement of the Term or the obligation to pay Annual Fixed Rent or Additional Rent. The Delivery Dates and/or the date of substantial completion of the Base Building Work, as applicable, shall be deemed to have occurred as of the date when such Delivery Dates and/or date of substantial completion of the Base Building Work, as applicable, would have occurred but for any Tenant Delays, as determined by Landlord in the exercise of its good faith business judgment (it being understood and agreed that the foregoing shall not be construed so as to relieve Landlord of its obligation to actually complete the Base Building Work, notwithstanding the fact that substantial completion may have been deemed to have occurred prior to actual completion as the result of Tenant Delays).
Period of Work Approximately [+] months (e.g. [+]). Deliverable: Plan, monitor, and report overall delivery of milestones and budget.
Vacations and Sick Leave The Executive shall be entitled to paid annual vacation leave in accordance with the policies as established from time to time by the Board of Directors, which shall in no event be less than four weeks per annum. The Executive shall also be entitled to an annual sick leave benefit as established by the Board for senior management employees of the Bank. The Executive shall not be entitled to receive any additional compensation from the Bank for failure to take a vacation or sick leave, nor shall he be able to accumulate unused vacation or sick leave from one year to the next; provided, however, such Executive may carry forward from year to year a maximum of ten days of unused vacation leave.
WINDOW CLEANING Tenant shall not clean, nor require, permit, suffer or allow any window in the Premises to be cleaned from the outside in violation of Section 202 of the Labor Law, or any other Requirement, or of the rules of the Board of Standards and Appeals, or of any other board or body having or asserting jurisdiction.
Building Services To install, use and maintain through the Premises, pipes, conduits, wires and ducts serving the Building, provided that such installation, use and maintenance does not unreasonably interfere with Tenant's use of the Premises.
Standard Services Landlord shall provide the following services on all days (unless otherwise stated below): (a) subject to limitations imposed by Law, customary heating, ventilation and air conditioning (“HVAC”) in season during Building HVAC Hours; (b) electricity supplied by the applicable public utility, stubbed to the Premises; (c) water supplied by the applicable public utility (i) for use in lavatories and any drinking facilities located in Common Areas within the Building, and (ii) stubbed to the Building core for use in any plumbing fixtures located in the Premises; (d) janitorial services to the Premises, except on weekends and Holidays; (e) elevator service (subject to scheduling by Landlord, and payment of Landlord’s standard usage fee, for any freight service); and (f) access to the Building for Tenant and its employees, 24 hours per day/7 days per week, subject to the terms hereof and such security or monitoring systems as Landlord may reasonably impose, including sign-in procedures and/or presentation of identification cards.
Vacation, Sick Leave and Holidays Executive shall be entitled to four (4) weeks (28 business days) of vacation, and also sick leave and holidays at full pay in accordance with the Company’s policies established and in effect from time to time.
