Project Problem definition

Project Problem is defined in Clause 7.1.
Sample 1Sample 2Sample 3
Project Problem means any of the following: the delay to any milestone in the Implementation Schedule, any material failure of either Party to conform to the requirements of the Contract, or any other problem which could have a material adverse effect on the successful completion of the works under the Contract.
Sample 1Sample 2Sample 3
Project Problem shall have the meaning given to such term in Section 10.6(b)(iii).
Sample 1Sample 2

Examples of Project Problem in a sentence

  • The records of the y inventories shall be maintained for two (2) years from the date of the inventory for y ! :; inspection by the Commis.sion, and shall include the quantities and '(inds of byproduct E g material, manufacturer's wne and model numbers, location of detector cells and the date of the inventory.

  • DBS cannot suspend performance, pending resolution of a Project Problem.

  • Compliance with the Project Problem procedure does not waive any substantive rights or remedies under this Agreement.

  • If this does not result in a resolution of the Project Problem within two weeks of such referral, any Program Manager can refer the Project Problem to the Escalation Committee (see, Clause 3.7 above); the Escalation Committee cannot impose a resolution of a Project Problem on a party without the party's consent.

  • Prior to commencing arbitration, the parties must exhaust the Project Problem procedures set forth in Section 7.

  • If any Program Manager notifies the others in writing that the Project Problem is urgent, the two week period for referral to the Steering Committee or the Escalation Committee will not apply; i.e., the Project Problem can be referred immediately.

  • A Project Problem is (i) an alleged failure of a party to perform its obligations, (ii) a disagreement about whether requested work or material is within the scope of the Project, or (iii) any circumstance, whether or not within the control of the parties, which adversely affects performance under this Agreement within the agreed time and budget.

  • If the parties resolve a Project Problem without arbitration, the parties will record the resolution in writing.

  • Figure 1: Project Problem & Solution PROBLEM:The connection costs for rapid EV charging facilities are a critical consideration for developers.

  • In your statement, include who was affected by this issue.Floodsville Project Problem Statement:A tropical storm caused major flooding in a neighborhood of the City of Floodsville.


More Definitions of Project Problem

Project Problem means any error or any other problem or circumstance encountered by Twin or PBS which in Twin's or PBS's judgment might prevent Twin or PBS from meeting a delivery date for a Deliverable or cause any increase in the estimated cost of an Interactive Game Application.
Sample 1
Project Problem shall have the meaning set forth in Section 10.8(b)(i).
Sample 1

Related to Project Problem

  • Project Work means the work required to complete the Project.

  • Project means the goods or Services described in the Signature Document or a Work Order of this Contract.

  • Project Property means the real property on or for which preconstruction service or construction work is or will be provided.

  • The Project Plan means the document to be developed by the Supplier and approved by the Purchaser, pursuant to GCC Clause 19, based on the requirements of the Contract and the Preliminary Project Plan included in the Supplier’s bid. The “Agreed and Finalized Project Plan” is the version of the Project Plan approved by the Purchaser, in accordance with GCC Clause 19.2. Should the Project Plan conflict with the Contract in any way, the relevant provisions of the Contract, including any amendments, shall prevail.

  • Development Project means a project for the development of land within a

  • Project Leader has the meaning set forth in Section 3.1.

  • Project Plan means the document to be developed by the Contractor and approved by Webel Technology Ltd., based on the requirements of the Contract and the Preliminary Project Plan included in the Contractor’s bid. For the sake of clarity, the Agreed and Finalized Project Plan” refers to the version of the Project Plan submitted by the contractor after receiving the letter of Award and the same approved by Webel Technology Ltd. The project plan may be changed/ modified during the course of the project. Should the Project Plan conflict with the provisions of the Contract in any way, the relevant provisions of the Contract, including any amendments, shall prevail.

  • Project Engineer means the surveyor or engineer employed by or private

  • Project Completion means completion of the Redevelopment in accordance with this Agreement to the state where the whole of the Morley Shopping Centre, as so redeveloped, is capable of occupation for its intended purpose;

  • Project Schedule means a document that, with respect to each Phase of the Project, identifies, coordinates and integrates the anticipated design and construction schedules, the Contracting Authority’s and Owner's responsibilities, government authority reviews and other activities as are necessary for the timely completion of the Work.

  • Project Implementation means all steps which the Grantee undertakes in order to deliver the Project which is being supported by funding provided under this Grant Contract. Any reference to UK primary legislation (Acts) or secondary legislation (Statutory Instruments) in this Grant Contract includes reference to any changes to or replacement of those Acts or Statutory Instruments.

  • Project Completion Schedule means the progressive Project Milestones set forth in Schedule-J for completion of the Project Highway on or before the Scheduled Completion Date;

  • Project Improvements means site improvements and facilities that are:

  • Disaster recovery project means a project located on property

  • Redevelopment Project Area means an area designated by the municipality, which is not less in the aggregate than 1 1/2 acres and in respect to which the municipality has made a finding that there exist conditions which cause the area to be classified as an industrial park conservation area or a blighted area or a conservation area, or a combination of both blighted areas and conservation areas.

  • Project IPR means all Intellectual Property Rights that arise or are obtained or developed by either party, or by a contractor on behalf of either party, in respect of the Deliverables in the course of or in connection with the Project;

  • Force Majeure Report means a report to be given by the Affected Party to the other party following the giving of a Force Majeure Notice;

  • Project Architect means the professional architect or engineer employed by the Owner as architect or engineer of record for the Project and its consultants.

  • Economic development project means land and existing or planned improvements suitable for use by an industrial or commercial enterprise, or housing development, or the protection of the environment, including, but not limited to, groundwater or surface water. Economic development project includes necessary buildings, improvements, or structures suitable for and intended for or incidental to use as an industrial or commercial enterprise or housing development; and includes industrial park or industrial site improvements and port improvements or housing development incidental to an industrial or commercial enterprise; and includes the machinery, furnishings, and equipment necessary, suitable, intended for, or incidental to a commercial, industrial, or residential use in connection with the buildings or structures.

  • Project Implementation Unit or “PIU” means the unit referred to in Section I.A.1(b) of Schedule 2 to this Agreement.

  • Development Site means any parcel or lot on which exists or which is intended for building development other than the following:

  • Construction project means the same as that term is defined in Section 38-1a-102.

  • Project Scope means the description or activity of work to be accomplished on the project.

  • Project Area means THE AREA WHERE WORK IS BEING PERFORMED FOR THE CITY OF SUFFOLK, VIRGINIA.

  • Project Implementing Entity means a legal entity (other than the Recipient or the Guarantor): (a) that is responsible for implementing all or a part of the Project; and (b) which is a party to the Project Agreement. If the Bank enters into a Project Agreement with more than one such entity, “Project Implementing Entity” refers separately to each such entity.

  • Projects means the projects identified in Exhibit A to the Agreement and all other projects, any costs of which are included in a Transitional Capital Plan pursuant to the Act or are Recovery Costs, and financed, by payment or reimbursement, with the proceeds of Bonds or Notes.