Pre-Award Waiver, Release, and Limitation of Liability AgreementLimitation of Liability Agreement • June 3rd, 2021
Purchaser Contractor This PRE-AWARD WAIVER, RELEASE, AND LIMITATION OF LIABILITY AGREEMENT ("Agreement") is entered into as of this day of , between the U.S. Forest Service ("Forest Service") and (" Purchaser ") (together sometimes referred to herein as the "Parties"). Recitals WHEREAS, on or about , the Forest Service declared Purchaser to be the apparent high-bidder on thecontract to operate the Timber Sale , located on National Forest; WHEREAS, the Parties recognize that the Timber Sale may be affected by existing and/or threatenedlitigation ("Litigation") and that, due to such Litigation, the Contracting Officer may instruct Purchaser to delay or suspend operations, and/or modify or terminate the contract for the Timber Sale ; and WHEREAS, Purchaser desires the Forest Service to proceed with the award of the contract, despite the possibility that the Forest Service might delay or suspend operations, and/or modify or terminate the contract; Terms and Conditions 1. Contract Award. Af
LIMITATION OF LIABILITY AGREEMENTLimitation of Liability Agreement • June 30th, 2011 • Nomura Holdings Inc • Security brokers, dealers & flotation companies
NOMURA HOLDINGS, INC. (hereinafter, the “Company”) and (hereinafter, the “Outside Director”) hereby agree to enter into this agreement as provided for under Article 33 Paragraph 2 of the Articles of Incorporation of the Company (hereinafter, the “Agreement”) in accordance with that Article.
LIMITATION OF LIABILITY AGREEMENTLimitation of Liability Agreement • June 28th, 2023 • Nomura Holdings Inc • Security brokers, dealers & flotation companies
NOMURA HOLDINGS, INC. (hereinafter, the “Company”) and (hereinafter, the “Director”) hereby agree to enter into this limitation of liability agreement (hereinafter, the “Agreement”) in accordance with Article 427, Paragraph 1 of the Companies Act and Article 33, Paragraph 2 of the Articles of Incorporation of the Company.
LIMITATION OF LIABILITY AGREEMENTLimitation of Liability Agreement • June 25th, 2015 • Nomura Holdings Inc • Security brokers, dealers & flotation companies
NOMURA HOLDINGS, INC. (hereinafter, the “Company”) and (hereinafter, the “Director”) hereby agree to enter into this limitation of liability agreement (hereinafter, the “Agreement”) in accordance with Article 427 Paragraph 1 of the Companies Act and Article 33 Paragraph 2 of the Articles of Incorporation of the Company.
Limitation of Liability AgreementLimitation of Liability Agreement • September 4th, 2018 • Pepper Food Service Co., Ltd. • Retail-eating places
This Agreement is entered into by and between Pepper Food Service Co., Ltd. (the “Company”) and [Name], an External Director of Pepper Food Service Co., Ltd. (the “External Director”), under the following terms and conditions regarding the limitation of the External Director’s liability to the Company for damages pursuant to Article 31 of the Company’s Articles of Incorporation.
Translation] Limitation of Liability AgreementLimitation of Liability Agreement • September 4th, 2018 • Pepper Food Service Co., Ltd. • Retail-eating places
This Agreement is entered into by and between Pepper Food Service Co., Ltd. (the “Company”) and [Name], an External Corporate Auditor of Pepper Food Service Co., Ltd. (the “External Corporate Auditor”), under the following terms and conditions regarding the limitation of the External Corporate Auditor’s liability to the Company for damages pursuant to Article 42 of the Company’s Articles of Incorporation.
Pre-Award Waiver, Release, and Limitation of Liability AgreementLimitation of Liability Agreement • June 3rd, 2021
Purchaser Contractor This PRE-AWARD WAIVER, RELEASE, AND LIMITATION OF LIABILITY AGREEMENT ("Agreement") is entered into as of this day of , between the U.S. Forest Service ("Forest Service") and (" Contractor ") (together sometimes referred to herein as the "Parties"). Recitals WHEREAS, on or about , the Forest Service declared Contractor to be the apparent high-bidder on thecontract to operate the Stewardship , located on National Forest; WHEREAS, the Parties recognize that the Stewardship may be affected by existing and/or threatenedlitigation ("Litigation") and that, due to such Litigation, the Contracting Officer may instruct Contractor to delay or suspend operations, and/or modify or terminate the contract for the Stewardship ; and WHEREAS, Contractor desires the Forest Service to proceed with the award of the contract, despite the possibility that the Forest Service might delay or suspend operations, and/or modify or terminate the contract; Terms and Conditions 1. Contract Award
Pre-Award Waiver, Release, and Limitation of Liability AgreementLimitation of Liability Agreement • June 3rd, 2021
Purchaser Contractor This PRE-AWARD WAIVER, RELEASE, AND LIMITATION OF LIABILITY AGREEMENT ("Agreement") is entered into as of this day of , between the U.S. Forest Service ("Forest Service") and (" Purchaser ") (together sometimes referred to herein as the "Parties"). Recitals WHEREAS, on or about , the Forest Service declared Purchaser to be the apparent high-bidder on the contract to operate the Kalispel Moon DxP Timber Sale , located on Colville National Forest;WHEREAS, the Parties recognize that the Kalispel Moon DxP Timber Sale may be affected by existing and/or threatenedlitigation ("Litigation") and that, due to such Litigation, the Contracting Officer may instruct Purchaser to delay or suspend operations, and/or modify or terminate the contract for the Kalispel Moon DxP Timber Sale ; andWHEREAS, Purchaser desires the Forest Service to proceed with the award of the contract, despite the possibility that the Forest Service might delay or suspend operations, and/or modify or term
Pre-award Waiver, Release, and Limitation of Liability AgreementLimitation of Liability Agreement • October 21st, 2010
This PRE-AWARD WAIVER, RELEASE, AND LIMITATION OF LIABILITY AGREEMENT (“Agreement”) is entered into as of this day of , between the U.S. Forest Service (“Forest Service”) and (“Purchaser”) (together sometimes referred to herein as the “Parties”).
Pre-Award Waiver, Release, and Limitation of Liability Agreement (Timber Sales or Stewardship Contract) Ref FSM 2432.31bLimitation of Liability Agreement • July 1st, 2021
This PRE-AWARD WAIVER, RELEASE, AND LIMITATION OF LIABILITY AGREEMENT ("Agreement") is entered into as of this day of , between the U.S. Forest Service ("Forest Service") and (" Contractor ") (together sometimes referred to herein as the "Parties").
Limitation of Liability AgreementLimitation of Liability Agreement • March 8th, 2023 • Pixie Dust Technologies, Inc. • Electronic & other electrical equipment (no computer equip)
This Limitation of Liability Agreement (this “Agreement”) is entered into as of the date written below by and between Pixie Dust Technologies, Inc. (the “Company”) and [ ] (the “Officer”) under the terms set forth below.
Pre-award Waiver, Release, and Limitation of Liability AgreementLimitation of Liability Agreement • March 31st, 2021
This PRE-AWARD WAIVER, RELEASE, AND LIMITATION OF LIABILITY AGREEMENT (“Agreement”) is entered into as of this day of , between the U.S. Forest Service (“Forest Service”) and (“Purchaser”) (together sometimes referred to herein as the “Parties”).
Pre-award Waiver, Release, and Limitation of Liability Agreement (Timber Sales)Limitation of Liability Agreement • October 22nd, 2019
This PRE-AWARD WAIVER, RELEASE, AND LIMITATION OF LIABILITY AGREEMENT (“Agreement”) is entered into as of this day of , between the U.S. Forest Service (“Forest Service”)
Pre-Award Waiver, Release, and Limitation of Liability AgreementLimitation of Liability Agreement • June 3rd, 2021
Purchaser Contractor This PRE-AWARD WAIVER, RELEASE, AND LIMITATION OF LIABILITY AGREEMENT ("Agreement") is entered into as of this day of , between the U.S. Forest Service ("Forest Service") and (" Contractor ") (together sometimes referred to herein as the "Parties"). Recitals WHEREAS, on or about , the Forest Service declared Contractor to be the apparent high-bidder on the contract to operate the Spike DxP Stewardship , located on Colville National Forest;WHEREAS, the Parties recognize that the Spike DxP Stewardship may be affected by existing and/or threatenedlitigation ("Litigation") and that, due to such Litigation, the Contracting Officer may instruct Contractor to delay or suspend operations, and/or modify or terminate the contract for the Spike DxP Stewardship ; andWHEREAS, Contractor desires the Forest Service to proceed with the award of the contract, despite the possibility that the Forest Service might delay or suspend operations, and/or modify or terminate the contract;
PRE-AWARD WAIVER, RELEASE, AND LIMITATION OF LIABILITY AGREEMENTLimitation of Liability Agreement • October 11th, 2011
This PRE-AWARD WAIVER, RELEASE, AND LIMITATION OF LIABILITY AGREEMENT (“Agreement”) is entered into as of this day of , between the U.S. Forest Service (“Forest Service”) and (“Purchaser”) (together sometimes referred to herein as the “Parties”).
