Sublease Term The term of the Sublease (“Sublease Term”) commences on the later to occur of (1) Sublandlord’s receipt of Prime Landlord’s written consent to this Sublease, and (2) October 1, 2009 (“Sublease Commencement Date”); and expires on January 28, 2018 (“Sublease Expiration Date”; i.e., the day prior to the Termination Date pursuant to the Prime Lease). Sublandlord shall deliver the Subleased Premises “broom clean” and free of all of Sublandlord’s personal property (other than the F&F (defined in Section 2(f))) and debris, but otherwise in “AS IS, WHERE IS” condition on the Sublease Commencement Date; provided that Subtenant shall not be responsible for, or required to remedy, any violation of any applicable law, or any condition or state of facts, with respect to the Subleased Premises, the Building or the Land existing on or prior to the Sublease Commencement Date. Sublandlord is not required to perform any work to prepare the Subleased Premises for Subtenant’s intended use. If (i) for any reason Sublandlord has not received Prime Landlord’s written consent to this Sublease in form required by Section 15(i) below by the date which is sixty (60) days from the date hereof, or (ii) Prime Landlord elects to terminate the Prime Lease in respect of the Subleased Premises pursuant to Prime Landlord’s recapture right set forth in Section 16.5 of the Prime Lease, then in the case of (i), then Sublandlord and Subtenant each may elect at any time thereafter to terminate this Sublease by written notice to the other, whereupon the parties shall deem this Sublease to be null and void and of no effect (except for those provisions expressly stated herein to survive a termination), and in the case of (ii) the Sublease will be deemed terminated in accordance with Section 16.5 of the Prime Lease.
Use of the Leased Property (a) Lessee covenants that it will proceed with all due diligence and will exercise reasonable efforts to obtain and to maintain all Licenses and other approvals needed to use and operate the Leased Property and the Hotel under applicable local, state and federal law.
Term of the Lease 4.2.1 The term of the Lease shall be sixty (60) months commencing on the Acceptance date.
ASSIGNMENT TERMINATES THIS CONTRACT; AMENDMENTS OF THIS CONTRACT This Contract shall automatically terminate, without the payment of any penalty, in the event of its assignment; and this Contract shall not be amended unless such amendment is approved at a meeting by the affirmative vote of a majority of the outstanding shares of the Fund, and by the vote, cast in person at a meeting called for the purpose of voting on such approval, of a majority of the Trustees of the Trust who are not interested persons of the Trust or of the Manager.
USE OF THE LEASED PREMISES (a) Lessor, in consideration of the rents to be paid and covenants herein contained, hereby leases to Lessee the Leased Premises.
Master Lease A. All the obligations contained in the Master Lease conferred and imposed upon Sublessor (as Tenant therein) shall be borne by Sublessor and Sublessee in accordance with the Sublessor's Percentage and the Sublessee's Percentage, respectively, except as modified and amended by this Sublease, and all rights and privileges contained in the Master Lease conferred upon Sublessor (as Tenant therein), are hereby conferred and imposed upon Sublessee, to the extent of Sublessee's Percentage. Sublessor covenants and agrees it will make payment of the rentals reserved under the Master Lease as and when due, will perform Sublessor's insurance obligations under the Master Lease, and will otherwise fully and faithfully perform the terms and conditions of the Master Lease with respect to the Sublessor's Percentage. Sublessee covenants and agrees to otherwise fully and faithfully perform the terms and conditions of the Master Lease and the Sublease on its part to be performed. Neither the Sublessor nor Sublessee shall do or cause to be done any act which would or might cause the Master Lease, or the rights of Sublessor as tenant under the Master Lease to be endangered, cancelled, terminated, forfeited or surrendered, or which would or might cause Sublessor to be in default thereunder or liable for any damage, claim or penalty. Sublessee agrees, as an express inducement for Sublessor executing this Sublease, that if there is any conflict between the provisions of the Master Lease and this Sublease which would permit Sublessee to do or cause to be done any act which is prohibited by the Master Lease then the provisions of the Master Lease shall prevail.
Initial Lease Term The terms and provisions of this Lease shall be effective as of the date of this Lease except for the provisions of this Lease relating to the payment of Rent. The term of this Lease (the “Lease Term”) shall be as set forth in Section 3.1 of the Summary, shall commence on the date (the “Lease Commencement Date”) that is the earlier to occur of (i) the date Tenant commences to conduct business in any portion of the Premises, and (ii) the of “Substantial Completion”, as that term is defined in this Article 2, of the Premises by Landlord, and shall terminate on the date determined in accordance with Section 3.3 of the Summary (the “Lease Expiration Date”) unless this Lease is sooner terminated as hereinafter provided. For purposes of this Lease, “Substantial Completion” of the Premises shall occur upon the completion of construction, as reasonably determined by Landlord, of the “Tenant Improvements,” as that term is defined in the Tenant Work Letter, in the Premises pursuant to the plans and drawings which are prepared and approved pursuant to the terms of the Tenant Work Letter and the issuance of a temporary certificate of occupancy or legal equivalent, with the exception of any Punchlist Items (as defined below) and any Tenant fixtures, work-stations, built-in furniture, or equipment to be installed by Tenant or under the supervision of Contractor (as defined in Section 3 of the Tenant Work Letter). “Punchlist Items” shall mean only commercially reasonable punchlist items, the non-completion of which does not prevent the issuance of a temporary certificate of occupancy or legal equivalent or unreasonably interfere with Tenant’s use or occupancy of the Premises, and which punchlist items shall be corrected promptly by Landlord (within thirty (30) days following Landlord’s receipt of written notice thereof from Tenant) without unreasonable interference with Tenant’s use of or access to or from the Premises. It is anticipated that the Lease Commencement Date will occur within sixteen (16) weeks after mutual execution of this Lease (such date, the “Target Commencement Date”), but this Lease shall not be void, voidable or subject to termination, nor shall Landlord be liable to Tenant for any loss or damage, resulting from Landlord’s inability to deliver the Premises to Tenant by any particular date, except as hereinafter provided. Notwithstanding anything to the contrary in this Lease, if the Lease Commencement Date does not occur within 60 days after the Target Commencement Date, other than due to Tenant Delay (as defined in the Tenant Work Letter) or Force Majeure, then Tenant, at its option, may terminate this Lease by written notice to Landlord given at any time after the expiration of such 60-day period but before the Lease Commencement Date actually occurs. In the event of such termination by Tenant, the first month’s Base Rent, Tenant’s Share of Direct Expenses paid by Tenant and the Security Deposit shall be fully refunded to Tenant (subject to Landlord’s right to draw upon such Security Deposit as provided in Article 21 below) and neither party shall have any further obligations hereunder. At any time during the Lease Term, Landlord may deliver to Tenant a notice in the form as set forth in Exhibit “C”, attached hereto, as a confirmation only of the information set forth therein, which Tenant shall (absent manifest error) execute and return to Landlord within five (5) business days of receipt thereof.
Tenant Delays A "Tenant Delay” shall be defined as any delay in the design, permitting or performance of the Base Building Work to the extent that such delay is actually caused by any act or, where there is a duty to act under this Lease, any failure to act by Tenant or Tenant's contractors, architects, engineers, or anyone else engaged by or on behalf of Tenant in connection with the construction of the Tenant Improvement Work as set forth in this Article III (including, without limitation, any delays resulting from the Approved Tenant Finishes under Section 3.l(C) above) and disclosed to Tenant as hereinafter provided. Notwithstanding the foregoing, in no event shall any delays in the completion of the Base Building Work caused by Tenant’s use of non-union labor constitute a Tenant Delay hereunder. Notwithstanding the foregoing, no event shall be deemed a Tenant Delay unless and until Landlord has given Tenant written notice (the "Tenant Delay Notice") advising Tenant: (x) that a Tenant Delay is occurring and setting forth Landlord's good faith estimate as to the likely length of such Tenant Delay; (y) of the basis on which Landlord has determined that a Tenant Delay is occurring; and (z) the actions which Landlord believes that Tenant must take to eliminate such Tenant Delay. No event shall be deemed to be a Tenant Delay unless and until Tenant has failed to rectify the situation causing the Tenant Delay within forty-eight (48) hours after Tenant's receipt of the Tenant Delay Notice (which for the purposes of determining receipt may be delivered by hand to Tenant's Construction Representative, with copies to follow to Tenant at the notice address set forth in Section 1.2 of this Lease within five (5) days thereafter); provided, however, that if Tenant shall fail to eliminate the delay within the aforesaid 48-hour period, then the 48-hour cure period shall be included in the period of time charged to Tenant pursuant to such Tenant Delay Notice (it being understood and agreed that if Tenant shall in fact eliminate the Tenant Delay within the 48-hour cure period, no Tenant Delay shall be deemed to have occurred for the purposes of this Article III). In addition, any delay to the extent caused by (i) Landlord Delay or (ii) subject to the limitations of subsection (D) below, Tenant's Force Majeure (as defined in said subsection (D)) shall not constitute Tenant Delay. Tenant covenants that no Tenant Delay shall delay commencement of the Term or the obligation to pay Annual Fixed Rent or Additional Rent. The Delivery Dates and/or the date of substantial completion of the Base Building Work, as applicable, shall be deemed to have occurred as of the date when such Delivery Dates and/or date of substantial completion of the Base Building Work, as applicable, would have occurred but for any Tenant Delays, as determined by Landlord in the exercise of its good faith business judgment (it being understood and agreed that the foregoing shall not be construed so as to relieve Landlord of its obligation to actually complete the Base Building Work, notwithstanding the fact that substantial completion may have been deemed to have occurred prior to actual completion as the result of Tenant Delays).
Lease Term The terms and provisions of this Lease shall be effective as of the date of this Lease. The term of this Lease (the “Lease Term”) shall commence on the “Lease Commencement Date,” as that term is set forth in Section 3.2 of the Summary, and shall terminate on the “Lease Expiration Date,” as that term is set forth in Section 3.3 of the Summary, unless this Lease is sooner terminated as hereinafter provided. Tenant hereby acknowledges that the Premises are currently occupied by another tenant of the Building. If Landlord is unable for any reason to deliver possession of the Premises to Tenant on any specific date , then Landlord shall not be subject to any liability for its failure to do so, and such failure shall not affect the validity of this Lease or the obligations of Tenant hereunder. For purposes of this Lease, the term “Lease Year” shall mean each consecutive twelve (12) month period during the Lease Term. At any time during the Lease Term, Landlord may deliver to Tenant a notice in the form as set forth in Exhibit C, attached hereto, as a confirmation only of the information set forth therein, which Tenant shall execute and return to Landlord within ten (10) business days of receipt thereof; provided, however, Tenant’s failure to execute and return such notice to Landlord within such time shall be conclusive upon Tenant that the information set forth in such notice is as specified therein. In addition to the foregoing, subject to any delays caused by Tenant or any Tenant Parties and events of Force Majeure, if Landlord fails to tender possession of the Premises to Tenant on or before January 2, 2015 (the “Base Rent Delivery Date”), Tenant shall be entitled to one (1) day of per diem Base Rent abatement for each day commencing on the day after the Base Rent Delivery Date and ending on the date Landlord so tenders possession of the Premises to Tenant. Any such Base Rent Abatement shall be separate from and in addition to any Rent Abatement described in Section 3.2 below.
Tenant Delay If the Substantial Completion of the Tenant Improvement Work is delayed (a “Tenant Delay”) as a result of (a) any failure of Tenant to approve the Construction Pricing Proposal pursuant to Section 2.6 above on or before Tenant’s Approval Deadline; (b) Tenant’s failure to timely approve any matter requiring Tenant’s approval; (c) any breach by Tenant of this Work Letter or the Lease; (d) any request by Tenant for a revision to the Approved Construction Drawings (except to the extent such delay results from any failure of Landlord to perform its obligations under Section 2.7 above); (e) Tenant’s requirement for materials, components, finishes or improvements that are not available in a commercially reasonable time given the anticipated date of Substantial Completion of the Tenant Improvement Work as set forth in this Agreement; (f) any change to the base, shell or core of the Premises or Building required by the Approved Construction Drawings; or (g) any other act or omission of Tenant or any of its agents, employees or representatives, then, notwithstanding any contrary provision of this Agreement, and regardless of when the Tenant Improvement Work is actually Substantially Completed, the Tenant Improvement Work shall be deemed to be Substantially Completed on the date on which the Tenant Improvement Work would have been Substantially Completed if no such Tenant Delay had occurred.
