Contractor Claims In the event of any demand by Contractor for (A) a time extension, including, without limitation, for relief from damages or penalties for delay assessed by the District under the Contract, (B) payment by the District of money or damages arising from work done by, or on behalf of, the Contractor pursuant to the Contract and payment of which is not otherwise expressly provided for or to which Contractor is not otherwise entitled to, or (C) an amount of payment disputed by the District, the parties shall attempt to resolve the dispute by those procedures set forth in Public Contract Code section 9204 and/or Article 1.5 (commencing with section 20104) of Chapter 1, Part, 3, Division 2, of the Public Contract Code, if applicable, the provisions of which are each attached hereto and incorporated herein by this reference. If a claim, or any portion thereof, remains in dispute upon satisfaction of all applicable dispute resolution requirements, the Contractor shall comply with all claims presentation requirements as provided in Chapter 1 (commencing with section 900) and Chapter 2 (commencing with section 910) of Part 3 of Division 3.6 of Title 1 of Government Code as a condition precedent to the Contractor’s right to bring a civil action against the District. For purposes of those provisions, the running of the time within which a claim must be presented to the District shall be tolled from the time the Contractor submits its written claim until the time the claim is denied, including any time utilized by any applicable meet and confer process. Pending resolution of the dispute, Contractor and its subcontractors shall continue to perform the Work under the Contract and shall not cause a delay of the Work during any dispute, claim, negotiation, mediation, or arbitration proceeding, except by written agreement of the District.
Infringement Claims You may submit an infringement claim notice to us at our Contact Formavailable here if you have a good faith belief that Your Content has been copied and made accessible through the Services (including as a part of the Service Content or Third Party Content) in violation of your Inte lectual Property Rights. A copyright infringement claims notice must include at (i) the identification of such a legedly infringing materials, including information su ficient for us to locate it within our Services, ( i) a demand that such a legedly infringing materials be removed or access disabled, ( i) a statement that you have a good faith belief that use of the material in the manner complained of is not authorized by the copyright owner, its agent, or the law; (iv) a statement that the information in the notification is accurate, and under penalty of perjury, that you are authorized to act on behalf of the owner of an exclusive right that is a legedly infringed; (v) contact information for you, such as address, phone number, and, if available, an email address; and (vi) must be signed by you or the person authorized to act on behalf of the owner of the a legedly infringed work (the “Notice Requirements”). Pursuant to 17 U.S.C. 512(c)(3), if the above Notice Requirements are not met, we may disregard the notice. Pursuant 17 U.S.C. 512(f), be advised that knowingly making a material misrepresentation that online material or activity is infringing or that material or activity was removed or disabled by mistake or misidentification, may subject you to heavy civil penalties. These penalties include monetary damages, including costs and attorneys' fees, incurred by the a leged infringer, by any copyright owner or copyright owner's authorized licensee, or by a service provider who is injured by your misrepresentation. If we make a decision to remove Your Content in response to a complaint, we may notify you and provide you with contact information for the complaining party. You may also object to such determination by writing to our designated agent, which must contain the fo lowing information pursuant to 17 U.S.C. 512(g)(3), (i) your physical or electronic signature; ( i) identification of the material that has been removed or to which access has been disabled and the location at which the material appeared before it was removed or access to it was disabled; ( i) a statement under penalty of perjury that the you have a good faith belief that the material was removed or disabled as a result of mistake or misidentification of the material to be removed or disabled; and (iv) your name, address, phone number, and a statement that you consent to the jurisdiction of Federal District Court for the judicial district in which the address is located, or if you are located outside of the United States, for any judicial district in which the service provider may be found, and that you wil accept service of process from the person who provided notification under subsection 17 U.S.C. 512(c)(1)(C) or an agent of such person.
Indemnification for Suits or Claims for Intellectual Property Infringement The Contractor shall indemnify and hold the Owner harmless from any suits or claims of infringement of any patent rights, trademarks or copyrights arising out of any patented, trademarked, or copyrighted materials, methods, or systems used by the Contractor.
RESPONSIBILITY FOR CLAIMS AND LIABILITY It is hereby stipulated and agreed between the parties that, with respect to any claim or action brought by a third party and arising out of the activities described in this IGA or stems from any matter arising out of any actual or alleged infringement of any patent, trademark, copyright, or service xxxx, or other actual or alleged unfair competition disparagement of product or service, or other tort or any type whatsoever, or any actual or alleged violation of trade regulations, each party shall only be liable for payment of that portion of any and all liability, costs, expenses, demands, settlements, or judgments resulting from the negligence actions or omissions of its own agents, officers, and employees. Either Party may self-fund its obligations under this IGA. However, nothing herein shall be construed as a waiver of any Party’s sovereign immunity or the immunities available to the officials, officers and employees of the Parties. To the extent allowed by law, the CITY shall ensure that any contractor retained or selected by the CITY to provide services related to the UTILITIES RELOCATOIN work contemplated in this IGA shall agree to indemnify and hold harmless the COUTNY as well as its commissioners, officers, officials, employees, and agents, from and against any and all loss and/or expense which it or any of them may suffer or pay as a result of claims or suits due to, because of, or arising out of any and all such injuries, deaths and/or damage, arising out of the UTILITIES RELOCATION work irrespective of the COUNTY’s negligence (except that no Party shall be indemnified for their own sole negligence). Any contractor retained by the CITY, if requested, shall assume and defend at the contractor’s own expense, any suit, action or other legal proceedings arising therefrom in which the COUNTY, and/or its commissioners, officers, officials, employees, and agents, are named as a party, and the contractor hereby agrees to satisfy, pay, and cause to be discharged of record any judgment which may be rendered against the COUNTY and/or its commissioners, officers, officials, employees, and agents, arising therefrom. The CITY shall ensure that the provisions of this Article are included in all contracts and subcontracts.
Product Warranty Claims When we receive a valid warranty claim for an HP hardware or software product, HP will either repair the relevant defect or replace the product. If HP is unable to complete the repair or replace the product within a reasonable time, Customer will be entitled to a full refund upon the prompt return of the product to HP (if hardware) or upon written confirmation by Customer that the relevant software product has been destroyed or permanently disabled. HP will pay for shipment of repaired or replaced products to Customer and Customer will be responsible for return shipment of the product to HP.
CONTRACTS (RIGHTS OF THIRD PARTIES ACT 1999 A person who is not a party to this Agreement has no right under the Contracts (Rights of Third Parties) Xxx 0000 to enforce any term of this Agreement, but this does not affect any right or remedy of a third party which exists or is available apart from that Act.
Product Claims You acknowledge that Company, not an App Distributor, is responsible for addressing any claims of yours or any third party relating to the Company application or your possession and/or use of the Company application, including, but not limited to: (i) product liability claims; (ii) any claim that the Company application fails to conform to any applicable legal or regulatory requirement; and (iii) claims arising under consumer protection or similar legislation. (5)
Contracts (Rights of Third Parties) Xxx 0000 No term of this Agreement is enforceable under the Contracts (Rights of Third Parties) Xxx 0000 by a person who is not a party to this Agreement.
Time limit for claims No Indemnified Party may make a Claim for indemnification under Section 6.1 in respect of any Claim unless notice in writing of the Claim, incorporating a statement setting out in reasonable detail the grounds on which the Claim is based, has been given by the Indemnified Party prior to the expiration of the applicable Survival Period as set forth in Part VI of Appendix B.
