Time Progress Schedule Sample Clauses

Time Progress Schedule. (1) To show compliance with the requirements of Section 3.01 of the Agreement, provide and maintain a Time Progress Schedule in accordance with the General Requirements, Special Conditions, Section paragraph titled “Project Schedule”. Unless otherwise accepted by the Fund, the Time Progress Schedule shall be strictly adhered to by the Contractor. The time for substantial completion shall be on or before the time specified on page A-1 of the Agreement.
Sample 1Sample 2Sample 3See All (5)
AutoNDA by SimpleDocs
Time Progress Schedule. (1) Within thirty (30) calendar days after receipt of the approval of the Office of the State Comptroller, the Contractor, unless otherwise directed by the Fund, shall submit to the Fund and the Consultant for their approval its proposed working plan and schedule for approval a proposed time schedule covering its first ninety (90) calendar days of operation. The working plan and schedule shall be in the form of suitable charts, diagrams or bar graphs and shall be based on the Contractor's logic and time estimates. Such plan and schedule shall be sufficiently detailed to show clearly, in sequence, all salient features of the work of each trade including: the anticipated time of commencement and completion of such work and the interrelationship between such work, submission of Shop Drawings and Samples for approval, approval of Shop Drawings and Samples, placing of orders of materials, fabrication and delivery of materials, installation and testing of materials, contiguous or related work under other contracts, and other items pertinent to the work.
Sample 1
Time Progress Schedule. (1) To show compliance with the requirements of Section 3.01 of the Agreement, provide and maintain a time progress schedule. After Contract Award, but before processing second progress payment application, the Contractor, unless otherwise directed by the University, shall submit to the University and the Consultant for their acceptance its proposed working plan and time progress schedule for all the work covered by the Contract, and shall include activities for preparation and submission of all Shop Drawings and Samples.
Sample 1

Related to Time Progress Schedule

  • PROGRESS SCHEDULE The Contractor, within ten (10) working days of receiving notice of the award of the contract, shall prepare and submit for the State's and Architect's information an estimated progress schedule for the Work. The progress schedule shall be related to the entire Project to the extent required by the Contract Documents, and shall provide for expeditious and practicable execution of the Work.

  • Construction Progress Schedule A schedule indicating proposed activity sequences and durations, milestone dates for receipt and approval of pertinent information, preparation, submittal, and processing of Shop Drawings and Samples, delivery of materials or equipment requiring long-lead time procurement, and proposed date(s) of Material Completion and Occupancy and Final Completion. The schedule will be developed to represent the sixteen or seventeen CSI Specification Divisions. It shall have a minimum number of activities as required to adequately represent to Owner the complete scope of work and define the Project’s critical path and associated activities. If the Project is to be phased, then each individual Phase should be identified from start through completion of the overall Project and should be individually scheduled and described, including any Owner’s occupancy requirements and showing portions of the Project having occupancy priority. The format of the schedule will have dependencies indicated on a monthly grid identifying milestone dates such as construction start, phase construction, structural top out, dry-in, rough-in completion, metal stud and drywall completion, equipment installation, systems operational, Material Completion and Occupancy Date, final inspection dates, Punchlist, and Final Completion date.

  • Work Progress Schedule Refer to Special Conditions and Division 1 General Administration Specifications for additional schedule requirements. Unless indicated otherwise in those documents, Contractor shall submit to the ODR and the A/E its initial Work Progress Schedule for the Work in relation to the entire Project not later than twenty-one (21) days after the effective date of the Notice to Proceed. Unless otherwise indicated in the Contract Documents, the Work Progress Schedule shall be based upon a computerized Critical Path Method (CPM) with full reporting capability. This initial schedule shall indicate the dates for starting and completing the various aspects required to complete the Work, including mobilization, procurement, installation, testing, inspection, and acceptance of all the Work of the Contract. When acceptable to the Owner, the initially accepted schedule shall be the Baseline Schedule for comparison to actual conditions throughout the contract duration.

  • Construction Progress Schedule; Overall Project Schedule The Contractor shall submit for review by the Design Professional and approval by the Owner a Construction Progress Schedule based upon the Design Professional’s Preliminary Design and Construction Schedule and prepared using a CPM (Critical Path Method) process within sixty days after the Effective Date of the Contract, utilizing a full-featured software package in a form satisfactory to the Design Professional and Owner, showing the dates for commencement and completion of the Work required by the Contract Documents, including coordination of mechanical, plumbing, and electrical disciplines, as well as coordination of the various subdivisions of the Work within the Contract. Milestones must be clearly indicated and sequentially organized to identify the critical path of the Project. The Construction Schedule will be developed to represent the CSI specification divisions. It shall have the minimum number of activities required to adequately represent to the Owner the complete scope of Work and define the Project’s (and each Phase’s if phased) critical path and associated activities. The format of the Construction Progress Schedule will have dependencies indicated on a monthly grid identifying milestone dates such as construction start, phase construction, structural top out, dry-in, rough-in completion, metal stud and drywall completion, equipment installation, systems operational, inspections for Material Completion and Occupancy Date, and Final Completion Date. The Contractor shall submit, along with the Construction Progress Schedule, the Submittal Schedule for approval by the Design Professional, correlating the associated approval dates for the documents with the Construction Progress Schedule. Upon recommendation by the Design Professional and approval by the Owner, the Construction Progress Schedule shall become the Overall Project Schedule, which shall be utilized by the Design Professional, Owner and Contractor. The Contractor must provide the Design Professional and the Owner with monthly updates of the Overall Project Schedule indicating completed activities and any changes in sequencing or activity durations, including approved change orders. See also Article 3.3.5.

  • Time Schedule 4.1. A project schedule is included in Appendix A.

  • Implementation Schedule TIME IS OF THE ESSENCE with regard to all dates and time periods set forth and/or incorporated herein. Any material modification or deviation from an approved schedule described in this Agreement shall occur only upon approval of the City and RDA, with any such approvals required to be in writing as an amendment to this Agreement, and which approvals shall not be unreasonably withheld. City shall cooperate and act promptly with respect to any and all permits or approvals necessary for completion of the Project. Notwithstanding the above, this Agreement shall not limit the discretion of the City, or any of its duly appointed and authorized governing bodies, boards or entities, in approving or rejecting any aspect of the Project or improvements contemplated on or about the Property.

  • Salary Schedule Progression Employees shall progress from step to step in salary grade on the basis of satisfactory job performance based upon established standards of performance. Seasonal employee's initial anniversary date shall be established after being in pay status for two thousand eighty (2,080) hours. Such date shall then be used for annual performance evaluation and step progression consideration. When an employee's anniversary date falls on any day from the first day of a pay week through Wednesday of the pay week, the employee's merit increase shall be effective as of the first day of the pay week within which the anniversary date falls. Otherwise, the merit increase shall be effective on the first day of the next pay week. Grievances arising from the denial of merit increases shall not be arbitrable under this Agreement but shall be processed as follows:

  • Milestone schedule Please state the status and progress of each Milestone and identify any completed Milestone(s) for the previous calendar quarter.

  • Development Schedule The Project shall substantially comply with the specific timetables and triggers for action set forth in Article 5 of this Agreement. The parties acknowledge that, as provided in G.S. 160A-400.25(b), the failure to meet a commencement or completion date shall not, in and of itself, constitute a material breach of this Agreement pursuant to G.S. 160A-400.27 but must be judged based upon the totality of the circumstances.

  • SCHEDULE OF WORK FIRST PARTY’S proposed schedule for the various services required will be set forth in Exhibit A-1. A4. CHANGES IN WORK -- EXTRA WORK In addition to services described in Section A1, the parties may from time to time agree in writing that FIRST PARTY, for additional compensation, shall perform additional services including but not limited to: • Change in the services because of changes in scope of the work. • Additional tasks not specified herein as required by the CITY. The CITY and FIRST PARTY shall agree in writing to any changes in compensation and/or changes in FIRST PARTY’s services before the commencement of any work. If FIRST PARTY deems work he/she has been directed to perform is beyond the scope of this agreement and constitutes extra work, FIRST PARTY shall immediately inform the CITY in writing of the fact. The CITY shall make a determination as to whether such work is in fact beyond the scope of this agreement and constitutes extra work. In the event that the CITY determines that such work does constitute extra work, it shall provide compensation to the FIRST PARTY in accordance with an agreed cost that is fair and equitable. This cost will be mutually agreed upon by the CITY and FIRST PARTY. A supplemental agreement providing for such compensation for extra work shall be negotiated between the CITY and the FIRST PARTY. Such supplemental agreement shall be executed by the FIRST PARTY and may be approved by the City Manager upon recommendation of the Department Head.

Time is Money Join Law Insider Premium to draft better contracts faster.