QUANTITY CHANGES PRIOR TO AWARD The Commissioner reserves the right, at any time prior to the award of a specific quantity Contract, to alter in good faith the quantities listed in the Bid Specifications. In the event such right is exercised, the lowest responsible Bidder meeting Bid Specifications will be advised of the revised quantities and afforded an opportunity to extend or reduce its Bid price in relation to the changed quantities. Refusal by the low Bidder to so extend or reduce its Bid price may result in the rejection of its Bid and the award of such Contract to the lowest responsible Bidder who accepts the revised qualifications.
Authorization Required Prior to Parallel Operation 2.2.1 The NYISO, in consultation with the Connecting Transmission Owner, shall use Reasonable Efforts to list applicable parallel Operating Requirements in Attachment 5 of this Agreement. Additionally, the NYISO, in consultation with the Connecting Transmission Owner, shall notify the Interconnection Customer of any changes to these requirements as soon as they are known. The NYISO and Connecting Transmission Owner shall make Reasonable Efforts to cooperate with the Interconnection Customer in meeting requirements necessary for the Interconnection Customer to commence parallel operations by the in-service date.
Puts Prior to the Settlement Date During the period from the Bank Closing Date to and including the Business Day immediately preceding the Settlement Date, the Assuming Bank shall be entitled to require the Receiver to purchase any Asset which the Assuming Bank can establish is evidenced by forged or stolen instruments as of the Bank Closing Date; provided, that, the Assuming Bank shall not have the right to require the Receiver to purchase any such Asset with respect to which the Assuming Bank has taken any action referred to in Section 3.4(a)(ii) with respect to such Asset. The Assuming Bank shall transfer all such Assets to the Receiver without recourse, and shall indemnify the Receiver against any and all claims of any Person claiming by, through or under the Assuming Bank with respect to any such Asset, as provided in Section 12.4.
Drawings Submitted During the Contract Term Where required to develop maintain and deliver diagrams or other technical schematics regarding the scope of work, Contractor shall do so on an ongoing basis at no additional charge, and must, as a condition of payment, update drawings and plans during the Contract term to reflect additions, alterations, and deletions. Such drawings and diagrams shall be delivered to the Authorized User’s representative.
Change in Guidelines Prior to Sentencing The defendant agrees that if any applicable provision of the Guidelines changes after the execution of this plea agreement, then any request by defendant to be sentenced pursuant to the new Guidelines will make this plea agreement voidable by the United States at its option. If the Government exercises its option to void the plea agreement, the United States may charge, reinstate, or otherwise pursue any and all criminal charges that could have been brought but for this plea agreement.
OPERATION OF PROPERTY DURING AGREEMENT PERIOD The Seller will continue to operate the Property and any business conducted on the Property in the manner operated prior to the Agreement and will take no action that would adversely impact the Property, tenants, lender, or business, if any. Any changes, such as renting vacant space, that materially affects the Property or the Buyer's intended use will be permitted only with the Buyer's consent.
Compliance Between Individual Contract and Master Agreement An individual contract between the Board and an individual employee, heretofore or hereafter executed, shall be subject to and consistent with the terms and conditions of this Agreement. If an individual contract contains any language inconsistent with this Agreement, this Agreement during its duration shall be controlling.
Notice to Proceed - Site Improvements The Recipient shall not commence, or cause to be commenced, any site improvements or other work on the Land until the Director has issued a Notice to Proceed to the Recipient. Such Notice to Proceed will not be issued until the Director is assured that the Recipient has complied with all requirements for the approval of a grant under Revised Code Sections 164.20 through 164.27 and has completed any land acquisition required by the Project. A Notice to Proceed shall be required for all Project prime contractors or direct procurement initiated by the Recipient following execution of this Agreement.
Change from Prior Year FY2023 County Executive Request
Recovery of Schedule Delays During Last Sixty Days of Contract Time At any time during the last sixty days of the Contract Time that the Design Professional finds that the Contractor is behind schedule per the Contract Time, as amended, the Design Professional shall notify the Contractor in writing. Within seven days of the date of the Design Professional's notice, the Contractor shall prepare and deliver to the Design Professional and Owner a written plan explaining how the Contractor intends to bring the Project back on schedule. The Contractor's plan must provide sufficient detail to allow the Design Professional and Owner to determine the proposal's feasibility.
