Specific Instances Sample Clauses

The "Specific Instances" clause defines particular situations or events to which the terms of the contract will apply. In practice, this clause outlines certain scenarios—such as breaches, disputes, or performance failures—where the contract's provisions are triggered or enforced. By clearly identifying these instances, the clause ensures that both parties understand when contractual obligations or remedies become relevant, thereby reducing ambiguity and helping to prevent misunderstandings or disputes about the contract's scope.
Specific Instances. A “transaction” is defined as a business arrangement whereby a party thereto provides property or services to the other in exchange for compensation. The above-referenced definition of the word “transaction” does not include gift agreements between a donor and the Ag Foundation. With specific regard to financial interests, the following transactions are absolute conflicts of interest, and are hereby proscribed:
View Source
Specific Instances. Without limiting the generality of the foregoing, so long as the following events, despite the exercise of reasonable efforts, cannot be avoided or mitigated by, and are beyond the reasonable control of and without the fault or negligence of the Party relying thereon as justification for such delay, nonperformance or noncompliance, Force Majeure Events may include without limitation: (1) an act of God or the elements, subsurface or other site conditions (including, without limitation, environmental contamination, archaeological or other protected cultural resources, and endangered species or protected habitats), extreme or severe weather conditions (including without limitation Non-Generating Wind Conditions), explosion, fire, epidemic, landslide, mudslide, sabotage, terrorism, lightning, earthquake, flood or similar cataclysmic event, transportation delays, unavailability of materials, defective equipment, an act of public enemy, war, blockade, civil insurrection, riot, civil disturbance or strike or other labor difficulty caused or suffered by a Party or any third party beyond the reasonable control of such Party or its Affiliates or an event that constitutes an event of force majeure affecting the Project Owner under the Project PPA (whether such cause is similar or dissimilar to the foregoing); (2) any restraint or restriction imposed by Applicable Law or other acts of governmental authorities, whether federal, state or local (including but not limited to an order issued by a court of competent jurisdiction pursuant to an Applicable Law concerning the environment if such order enjoins or prohibits a Party from performing its obligations under this Agreement), as long as the affected Party made a good faith, diligent effort to comply with the Applicable Law concerning the environment and made a good faith, diligent effort to oppose such governmental act or order; or (3) electric transmission interruptions or curtailments because of physical events (not merely congestion or interruption of non-firm transmission) affecting the transmission facilities interconnected with the Project or transmission lying between the Project and the Delivery Point.
View Source
Specific Instances. The indemnifications contained in Section 33.01 shall include but not be limited to the following specific instances: (a) In the event the City is damaged due to the act, omission, mistake, fault, or default of the Contractor, then the Contractor shall indemnify and hold harmless and defend the City for such damage. (b) The Contractor shall indemnify and hold harmless and defend the City from any claims for payment for goods or services brought by any material suppliers, mechanics, laborers, or other subcontractors. (c) The Contractor shall indemnify and hold harmless and defend the City from any and all injuries to or claims of adjacent property owners caused by the Contractor, its agents, employees, and representatives. (d) The Contractor shall be responsible for any damage to the floor, walls, etc., caused by the Contractor’s personnel or equipment during installation. (e) The Contractor shall also be responsible for the removal of all related debris. (f) The Contractor shall also be responsible for subcontractors hired by it. (g) The Contractor shall indemnify, hold harmless, and defend the City from any liability caused by the Contractor’s failure to comply with applicable federal, state, or local regulations, that touch upon or concern the maintenance of a safe and protected working environment and the safe use and operation of machinery and equipment in that working environment, no matter where fault or responsibility lies.
View Source
Specific Instances. 36 Three requirements must be met before a judicial discretion to permit adduction of a complainant's "other" sexual activity may be permitted. The first is that the proposed evidence is "of specific instances of sexual activity". Like ▇▇▇▇▇▇▇▇▇ ▇▇▇▇▇▇▇, supra, at 8-7, I am of the view that this provision "appears to be designed to exclude evidence of the complainant's reputation" or character. This is not the nature of the evidence targeted by the applicant. He seeks, rather, the adduction of specific instances of the complainant's sexual activity that afford a factual foundation for a defence based on the issues I have identified. Put otherwise, he seeks to adduce evidence of those specific instances when the complainant was exposed to a risk of HSV infection.
View Source

Related to Specific Instances

  • Specific Requirements compensation insurance with statutory limits required by South Dakota law. Coverage B-Employer’s Liability coverage of not less than $500,000 each accident, $500,000 disease-policy limit, and $500,000 disease-each employee.

  • DISCLOSURE OF TBS ACCESS CODE TO THIRD PARTY (a) The Account Holder must exercise all care to ensure that the TBS Access Code is not disclosed to any person and shall take all steps to prevent forgery or fraud in connection with the use of his TBS Access Code and/or the operation of the TBS. If the TBS Access Code is disclosed to any person, the Account Holder must forthwith give the Bank written notice thereof, thereupon the Account Holder shall immediately cease to use the TBS Access Code. (b) Unless and until the Bank receives such written notice of disclosure, the Account Holder shall be fully liable and be bound by all transactions effected by the use of such TBS, with or without his consent or knowledge.

  • License Requirements The Hotel’s alcoholic beverage license requires that the Hotel shall: (i) request proper identification (photo ID) of any person of questionable age and refuse alcoholic beverage service if the person is either under age or proper identification cannot be produced, and (ii) refuse alcoholic beverage service to any person who, in the Hotel’s judgment, appears to be intoxicated; and (iii) instruct its personnel to avoid encouraging patrons to consume alcoholic beverages (commonly referred to as “over-pouring”).

  • Sublicense Requirements Any Sublicense: (A) is subject to this Agreement; (B) will reflect that any sublicensee will not further sublicense; (C) will prohibit sublicensee from paying royalties to an escrow or other similar account; (D) will expressly include the provisions of Sections 8, 9, and 10 for the benefit of Stanford; and (E) will include the provisions of Section 4.4 and require the transfer of all the sublicensee’s obligations to *****, including the payment of royalties specified in the Sublicense, to Stanford or its designee, if this Agreement is terminated. If the sublicensee is a spin-out from *****, ***** must guarantee the sublicensee’s performance with respect to the payment of Stanford’s share of Sublicense royalties.

  • Country Specific Terms Appendix A contains additional terms and conditions of the Agreement applicable to Participants residing in those countries. In addition, Appendix A also contains information and notices of exchange control and certain other issues of which the Participant should be aware.