Shipping Delivery and Acceptance of the Product
Shipping Delivery and Acceptance of the Product Sample Clauses
Related to Shipping Delivery and Acceptance of the Product
Delivery and Acceptance 4.1 Developer shall submit to Publisher a Version of the Product at each Milestone for approval. Publisher shall (acting reasonably) review the submission for compliance with the relevant parts of the Specification at that Milestone and for Publisher’s continued awareness as to the Product status.
Inspection and Acceptance a. The Contracting Officer or the duly authorized representative will perform inspection and acceptance of materials and services to be provided.
Electronic Delivery and Acceptance The Company may, in its sole discretion, decide to deliver any documents related to current or future participation in the Plan by electronic means. The Participant hereby consents to receive such documents by electronic delivery and agrees to participate in the Plan through an on-line or electronic system established and maintained by the Company or a third party designated by the Company.
Assignment and Acceptance; Notes The parties to each assignment shall execute and deliver to the Administrative Agent an Assignment and Assumption, together with a processing and recordation fee of $4,500 ($7,500 for any Defaulting Lender) for each assignment (which fee the Administrative Agent may, in its sole discretion, elect to waive), and the assignee, if it is not a Lender, shall deliver to the Administrative Agent an Administrative Questionnaire. If requested by the transferor Lender or the assignee, upon the consummation of any assignment, the transferor Lender, the Administrative Agent and the Borrower shall make appropriate arrangements so that new Notes are issued to the assignee and such transferor Lender, as appropriate.
Delivery Location The Aircraft shall be located at the agreed Delivery Location;
Inspection and Access Landlord and its agents, representatives, and contractors may enter the Premises at any reasonable time to inspect the Premises and to make such repairs as may be required or permitted pursuant to this Lease and for any other business purpose. Landlord and Landlord’s representatives may enter the Premises during business hours on not less than 48 hours advance written notice (except in the case of emergencies in which case no such notice shall be required and such entry may be at any time) for the purpose of effecting any such repairs, inspecting the Premises, showing the Premises to prospective purchasers and, during the last year of the Term, to prospective tenants or for any other business purpose. Landlord may erect a suitable sign on the Premises stating the Premises are available to let or that the Project is available for sale. Landlord may grant easements, make public dedications, designate Common Areas and create restrictions on or about the Premises, provided that no such easement, dedication, designation or restriction materially, adversely affects Tenant’s use or occupancy of the Premises for the Permitted Use. At Landlord’s request, Tenant shall execute such instruments as may be necessary for such easements, dedications or restrictions. Tenant shall at all times, except in the case of emergencies, have the right to escort Landlord or its agents, representatives, contractors or guests while the same are in the Premises, provided such escort does not materially and adversely affect Landlord’s access rights hereunder.
Appointment of and Acceptance by Escrow Agent The Investor(s) and the Company hereby appoint Escrow Agent to serve as Escrow Agent hereunder. Escrow Agent hereby accepts such appointment and, upon receipt by wire transfer of the Escrow Funds in accordance with Section 3 below, agrees to hold, invest and disburse the Escrow Funds in accordance with this Agreement.
Appointment of and Acceptance by NCPS Issuer and Broker hereby appoint NCPS to serve as Escrow Agent hereunder, and NCPS hereby accepts such appointment in accordance with the terms of this Escrow Agreement.
Delivery; Acceptance of Premises; Commencement Date Landlord shall use reasonable efforts to deliver the Premises to Tenant on or before the Target Commencement Date, with Landlord’s Work Substantially Completed (“Delivery” or “Deliver”). If Landlord fails to timely Deliver the Premises, Landlord shall not be liable to Tenant for any loss or damage resulting therefrom, and this Lease shall not be void or voidable except as provided herein. If Landlord does not Deliver the Premises within 90 days of the Target Commencement Date for any reason other than Force Majeure delays and Tenant Delays, this Lease may be terminated by Landlord or Tenant by written notice to the other, and if so terminated by either: (a) the Security Deposit, or any balance thereof (i.e., after deducting therefrom all amounts to which Landlord is entitled under the provisions of this Lease), shall be returned to Tenant, and (b) neither Landlord nor Tenant shall have any further rights, duties or obligations under this Lease, except with respect to provisions which expressly survive termination of this Lease. As used herein, the terms “Landlord’s Work,” “Tenants’ Work,” and “Force Majeure Delays” shall have the meanings set forth for such terms in the Work Letter. If neither Landlord nor Tenant elects to void this Lease within 10 business days of the lapse of such 90 day period, such right to void this Lease shall be waived and this Lease shall remain in full force and effect; provided, however, that if Landlord does not Deliver the Premises within 150 days of the Target Commencement Date for any reason other than Force Majeure delays and Tenant Delays, this Lease may be terminated by Tenant by written notice to Landlord, in which case subsections (a) and (b) of this paragraph shall apply. If Tenant does not elected to void this Lease within 10 business days of the lapse of such 150 day period, such right to void this Lease shall be waived and this Lease shall remain in full force and effect.
Offer and Acceptance This writing is an offer by us to you which shall remain open for ten (10) days from the date first above written, but after ten (10) days from said date your acceptance hereof shall be deemed a counteroffer to us which we can accept or reject. Upon your acceptance hereof or our acceptance of your counteroffer, then this Agreement shall constitute the sole agreement between us concerning our purchase of your accounts effective as of the date first above written and shall supersede all prior agreements between us on the subject hereof. Your acceptance hereof shall be made by your execution and delivery of this Agreement to us at our office in Los Angeles, California, and our acceptance or rejection of your counteroffer will be made at our office in Los Angeles, California.
