Payment of Liquidated Damages With respect to any Liquidated Damages that accrue, Owner shall invoice Contractor for such Liquidated Damages. Contractor shall pay such Liquidated Damages within ten (10) Days after Contractor’s receipt of such invoice. To the extent Contractor does not pay such Liquidated Damages within such ten (10) Day period, Owner may, at its option, do one or more of the following: (i) withhold from Contractor amounts that are otherwise due and payable to Contractor in the amount of such Liquidated Damages and/or (ii) collect on the Letter of Credit in the amount of such Liquidated Damages. For the avoidance of doubt, prior to exercising such right to withhold or collect on the Letter of Credit, Owner shall not be required to provide the notice as set forth in Section 7.8. As used in this Agreement, Liquidated Damages are “paid” if and to the extent Owner exercises option (i) or (ii) above for the collection of Liquidated Damages.
Waiver of Liquidated Damages If the Partnership is unable to cause a Registration Statement to become effective on or before the Target Effective Date, then the Partnership may request a waiver of the Liquidated Damages, which may be granted by the consent of the Holders of at least the Registrable Securities Required Voting Percentage, in their sole discretion, and which such waiver shall apply to all the Holders of Registrable Securities included on such Registration Statement.
Liquidated Damages The Company’s obligations to pay any partial liquidated damages or other amounts owing under the Transaction Documents is a continuing obligation of the Company and shall not terminate until all unpaid partial liquidated damages and other amounts have been paid notwithstanding the fact that the instrument or security pursuant to which such partial liquidated damages or other amounts are due and payable shall have been canceled.
Obligation Absolute; Partial Liquidated Damages The Company’s obligations to issue and deliver the Conversion Shares upon conversion of this Debenture in accordance with the terms hereof are absolute and unconditional, irrespective of any action or inaction by the Holder to enforce the same, any waiver or consent with respect to any provision hereof, the recovery of any judgment against any Person or any action to enforce the same, or any setoff, counterclaim, recoupment, limitation or termination, or any breach or alleged breach by the Holder or any other Person of any obligation to the Company or any violation or alleged violation of law by the Holder or any other Person, and irrespective of any other circumstance which might otherwise limit such obligation of the Company to the Holder in connection with the issuance of such Conversion Shares; provided, however, that such delivery shall not operate as a waiver by the Company of any such action the Company may have against the Holder. In the event the Holder of this Debenture shall elect to convert any or all of the outstanding principal amount hereof, the Company may not refuse conversion based on any claim that the Holder or anyone associated or affiliated with the Holder has been engaged in any violation of law, agreement or for any other reason, unless an injunction from a court, on notice to Holder, restraining and or enjoining conversion of all or part of this Debenture shall have been sought and obtained, and the Company posts a surety bond for the benefit of the Holder in the amount of 150% of the outstanding principal amount of this Debenture, which is subject to the injunction, which bond shall remain in effect until the completion of arbitration/litigation of the underlying dispute and the proceeds of which shall be payable to the Holder to the extent it obtains judgment. In the absence of such injunction, the Company shall issue Conversion Shares or, if applicable, cash, upon a properly noticed conversion. If the Company fails for any reason to deliver to the Holder such Conversion Shares pursuant to Section 4(c)(ii) by the Share Delivery Date, the Company shall pay to the Holder, in cash, as liquidated damages and not as a penalty, for each $1,000 of principal amount being converted, $10 per Trading Day (increasing to $20 per Trading Day on the fifth (5th) Trading Day after such liquidated damages begin to accrue) for each Trading Day after such Share Delivery Date until such Conversion Shares are delivered or Holder rescinds such conversion. Nothing herein shall limit a Hxxxxx’s right to pursue actual damages or declare an Event of Default pursuant to Section 8 hereof for the Company’s failure to deliver Conversion Shares within the period specified herein and the Holder shall have the right to pursue all remedies available to it hereunder, at law or in equity including, without limitation, a decree of specific performance and/or injunctive relief. The exercise of any such rights shall not prohibit the Holder from seeking to enforce damages pursuant to any other Section hereof or under applicable law.
No Duty to Collect Amounts Due From Dividend and Transfer Agent The Custodian shall not be under any duty or obligation to take action to effect collection of any amount due to the Trust from any Dividend and Transfer Agent of the Trust nor to take any action to effect payment or distribution by any Dividend and Transfer Agent of the Trust of any amount paid by the Custodian to any Dividend and Transfer Agent of the Trust in accordance with this Agreement.
Certain Rules Relating to the Payment of Additional Amounts (a) Upon the request, and at the expense of the Borrower, each Lender and Agent to which the Borrower is required to pay any additional amount pursuant to Subsection 4.10 or 4.11, and any Participant in respect of whose participation such payment is required, shall reasonably afford the Borrower the opportunity to contest, and reasonably cooperate with the Borrower in contesting, the imposition of any Non-Excluded Tax giving rise to such payment; provided that (i) such Lender or Agent shall not be required to afford the Borrower the opportunity to so contest unless the Borrower shall have confirmed in writing to such Lender or Agent its obligation to pay such amounts pursuant to this Agreement and (ii) the Borrower shall reimburse such Lender or Agent for its reasonable attorneys’ and accountants’ fees and disbursements incurred in so cooperating with the Borrower in contesting the imposition of such Non-Excluded Tax; provided, however, that notwithstanding the foregoing no Lender or Agent shall be required to afford the Borrower the opportunity to contest, or cooperate with the Borrower in contesting, the imposition of any Non-Excluded Taxes, if such Lender or Agent in its sole discretion in good faith determines that to do so would have an adverse effect on it.
Payment of Damages The indemnification required hereunder shall be made by periodic payments of the amount thereof during the course of the investigation or defense, within 10 days as and when reasonably specific bills are received or loss, liability, claim, damage or expense is incurred and reasonable evidence thereof is delivered. In calculating any amount to be paid by an indemnifying party by reason of the provisions of this Agreement, the amount shall be reduced by all tax benefits and other reimbursements (including, without limitation, insurance proceeds) credited to or received by the other party related to the Damages.
Unconditional Right of Holders to Receive Principal, Premium and Interest and to Convert Notwithstanding any other provision in this Indenture, the Holder of any Security shall have the right, which is absolute and unconditional, to receive payment of the principal of and any premium and (subject to Section 307) interest on such Security on the respective Stated Maturities expressed in such Security (or, in the case of redemption, on the Redemption Date), and, if the terms of such Security so provide, to convert such Security in accordance with its terms, and to institute suit for the enforcement of any such payment and, if applicable, any such right to convert, and such rights shall not be impaired without the consent of such Holder.
Late Charges and Interest Tenant hereby acknowledges that late payment by Tenant to Landlord of Rent will cause Landlord to incur costs not contemplated by this Lease, the exact amount of which will be extremely difficult to ascertain. Such costs include, but are not limited to, processing and accounting charges, and late charges which may be imposed on Landlord by the terms of any mortgage or trust deed covering the Premises. Accordingly, if any installments of Rent shall not be received by Landlord or Landlord's designee within five (5) days after such amount shall be due, Tenant shall pay to Landlord a late charge equal to fifteen percent (15%) of such overdue amount ("Late Charge"). The parties hereby agree that such Late Charge represents a fair and reasonable estimate of the costs Landlord will incur by reason of late payments by Tenant. Acceptance of such Late Charge by Landlord shall in no event constitute a waiver of Tenant's default with respect to such overdue amount, nor prevent Landlord from exercising any of the other rights and remedies granted hereunder. In addition, Tenant shall pay interest on all Rent not paid on the date when due at an annual interest rate of eighteen percent (18%) or the highest rate permitted by law, whichever is lower ("Interest Rate"). In the event any check, bank draft or negotiable instrument given for any payments under this Lease shall be dishonored at any time for any reason whatsoever not attributable to Landlord, Landlord shall be entitled, in addition to any other remedy that may be available, to an administrative charge of $200.00.
Payment of Additional Rent In addition to the Minimum Annual Rent specified in this Lease, Tenant shall pay to Landlord as "Additional Rent" for the Leased Premises, in each calendar year or partial calendar year, during the Lease Term, an amount equal to the Annual Rental Adjustment excluding Real Estate Taxes for such calendar year or partial calendar year. In the case of the calendar year of the Commencement Date, Landlord shall provide such notice prior to the Commencement Date. The Annual Rental Adjustment excluding Real Estate Taxes shall be estimated annually by Landlord, and written notice thereof shall be given to Tenant prior to the beginning of each calendar year. Tenant shall pay to Landlord each month, at the same time the Monthly Rental Installment is due, an amount equal to one-twelfth (1/12) of the estimated Annual Rental Adjustment excluding Real Estate Taxes. If the cost of utility, janitorial or other services increase during a calendar year, Landlord may increase the estimated Annual Rental Adjustment excluding Real Estate Taxes during such year by giving Tenant written notice to that effect, and thereafter Tenant shall pay to Landlord, in each of the remaining months of such year, an amount equal to the amount of such increase in the estimated Annual Rental Adjustment excluding Real Estate Taxes for the remainder of the year divided by the number of months remaining in such year. Within a reasonable time after the end of each calendar year, Landlord shall prepare and deliver to Tenant a statement showing the actual Annual Rental Adjustment excluding Real Estate Taxes. Within thirty (30) days after receipt of the aforementioned statement, Tenant shall pay to Landlord, or Landlord shall credit against the next rent payment or payments due from Tenant, as the case may be, the difference between the actual Annual Rental Adjustment excluding Real Estate Taxes for the preceding calendar year and the estimated amount paid by Tenant to Landlord during such year. In addition, Tenant shall pay, before delinquency, any and all Real Estate Taxes as defined in Section 3.02.D, above, directly to the appropriate taxing authority. If Tenant fails for any reason to pay the Real Estate Taxes when same is due and payable, Landlord shall have the right, but not the obligation, to pay the Real Estate Taxes directly to the taxing authority and Tenant shall immediately reimburse Landlord for the cost thereof. Such amount shall accrue interest from the date Landlord pays such amount, pursuant to Section 3.04, below, shall include any penalties, late fees and any interest assessed due to such delinquency. Tenant or its accountants shall have the right to inspect, at reasonable time and in a reasonable manner, during the one hundred twenty (120) day period following the delivery of Landlord's statement of the actual amount of the Annual Rental Adjustment excluding Real Estate Taxes, such of Landlord's books of account and records as pertain to and contain information concerning such costs and expenses for the Building for the prior calendar year in order to verify the amounts thereof. In the event the first audit discloses (i) errors made during the prior calendar year which, when totaled, indicate that the sum overcharged to and paid by Tenant, exceeds five percent (5%) of the Annual Rental Adjustment excluding Real Estate Taxes plus Landlord's Share of Operating Expenses (the "Total Expenses"), the audit shall be at the expense of Landlord, not to exceed Two Thousand Five Hundred Dollars ($2,500.00), or (ii) no errors or an error which equals or is less than five percent (5%) of the Total Expenses, the audit shall be at the expense of Tenant. For each subsequent audit, where the audit discloses errors exceeding five percent (5%) of the Total Expenses, Landlord shall pay for such audit and, if the audit discloses errors equal to or less than five percent (5%) of the Total Expenses, Tenant shall pay the costs of the audit. If Landlord spends more than eight (8) hours to accommodate Tenant's right to audit hereunder, Tenant shall also pay to Landlord as additional rent Seventy-five Dollars ($75.00) per hour for each additional hour that Tenant's audit takes of Landlord's property manager's or asset manager's time, provided such audit discloses no error or an error greater than five percent (5%) of the Total Expenses. The results of the audit (regardless of the degree of the error, if any) shall be binding upon Landlord and Tenant, and Landlord shall thereafter, if appropriate, change its method of calculating the Operating Expenses consistent with the results of the audit. Tenant agrees to hold the information obtained from such audit confidential and shall not disclose the same without Landlord's express written permission except as necessary to enforce the Lease or protect Tenant's rights hereunder. If Tenant shall not elect to cause an audit within the time period permitted hereby, then Landlord's statement shall be conclusively deemed to have been approved and accepted by Tenant. Pending resolution of any dispute with respect to statements of Tenant's Annual Rental Adjustment, Tenant shall pay its Annual Rental Adjustment as shown on such statement, and upon final determination of the amount of Tenant's Annual Rental Adjustment, Landlord shall promptly refund any overpayment to Tenant or Tenant shall promptly pay any amount due to Landlord, as applicable.
