Electronic Execution and Delivery A digital reproduction, portable document format (“.pdf”) or other reproduction of this Agreement may be executed by one or more parties hereto and delivered by such party by electronic signature (including signature via DocuSign or similar services), electronic mail or any similar electronic transmission device pursuant to which the signature of or on behalf of such party can be seen. Such execution and delivery shall be considered valid, binding and effective for all purposes.
Delivery of Materials In the event of any expiration or termination of this Agreement, Contractor shall promptly provide the JBE with all originals and copies of the Deliverables, including any partially-completed Deliverables-related work product or materials, and any JBE-provided materials in its possession, custody, or control. In the event of any termination of this Agreement, the JBE shall not be liable to Contractor for compensation or damages incurred as a result of such termination; provided that if the JBE’s termination is not for cause, the JBE shall pay any fees due under this Agreement for Services performed or Deliverables completed and accepted as of the date of the JBE’s termination Notice.
Execution and Delivery The Guaranteeing Subsidiary agrees that the Guarantee shall remain in full force and effect notwithstanding the absence of the endorsement of any notation of such Guarantee on the Notes.
Delivery of Products All shipments of Products shall be made either F.O.B. Destination or F.O.B. Shipping Point as designated in the Purchase Order.
Preparation and Submission The Recipient will:
Preparation Awarded vendor shall not begin a project for which TIPS Member has not prepared the site, unless awarded vendor does the preparation work at no cost, or until TIPS Member includes the cost of site preparation in a purchase order. Site preparation includes, but is not limited to: moving furniture, installing wiring for networks or power, and similar pre-installation requirements. Registered sex offender restrictions: For work to be performed at schools, awarded vendor agrees that no employee of a sub-contractor who has been adjudicated to be a registered sex offender will perform work at any time when students are, or reasonably expected to be, present. Awarded vendor agrees that a violation of this condition shall be considered a material breach and may result in the cancellation of the purchase order at the TIPS Member’s discretion. Awarded vendor must identify any additional costs associated with compliance of this term. If no costs are specified, compliance with this term will be provided at no additional charge. Safety measures: Awarded vendor shall take all reasonable precautions for the safety of employees on the worksite, and shall erect and properly maintain all necessary safeguards for protection of workers and the public. Awarded vendor shall post warning signs against all hazards created by the operation and work in progress. Proper precautions shall be taken pursuant to state law and standard practices to protect workers, general public and existing structures from injury or damage.
Transportation and Delivery Prices shall include all charges for packing, handling, freight, distribution, and inside delivery. Transportation of goods shall be FOB Destination to any point within thirty (30) days after the Customer places an Order. A Contractor, within five (5) days after receiving a purchase order, shall notify the Customer of any potential delivery delays. Evidence of inability or intentional delays shall be cause for Contract cancellation and Contractor suspension.
Order and Delivery The Contract shall bind the Contractor to furnish and deliver the Goods or Services in accordance with Exhibit A and at the prices set forth in Exhibit B. Subject to the sections in this Contract concerning Force Majeure, Termination and Open Market Purchases, the Contract shall bind the Client Agency to order the Goods or Services from the Contractor, and to pay for the accepted Goods or Services in accordance with Exhibit B.
Electronic Delivery of Documents The Company may, in its sole discretion, deliver any documents related to the Units and participation in the Plan or future grants of Units that may be granted under the Plan, by electronic means unless otherwise prohibited by local law. You hereby consent to receive such documents by electronic delivery and agree to participate in the Plan through an on-line or electronic system established and maintained by the Company or a third party-designated by the Company.
Delivery of Documents The Adviser has furnished the Sub-Adviser with copies of each of the following documents:
