Performance Delayed Sample Clauses

Performance Delayed. Neither COPR, nor STWC will be liable for any failure or delay in the performance of its obligations hereunder which are due, in whole or in part, directly or indirectly, to any cause beyond the reasonable control of such Party, which in the exercise of due diligence could not have been avoided, including without limitation, fire, explosion, earthquake, storm, flood or other weather, unavailability of necessary utilities or raw materials, strike, lockout, unavailability of any component, activities of a combination of workers or other labor difficulties, war, insurrection, riot, act of God or public enemy, law, act, order, export control regulation, proclamation decree, regulations, ordinance or instruction of government or other public authorities, or judgment or decree of a court of competent jurisdiction (not arising out of any breach by such Party of this Agreement). In the event of such occurrence, the Party so affected will give prompt notice to the other Parties, stating the period of time the occurrence is expected to continue.
View SourceView Similar (4)
Performance Delayed. Neither the Tribe, the Authority, nor the Development Manager party will be liable for any failure or delay in the performance of its obligations hereunder which are due, in whole or in part, directly or indirectly, to any cause beyond the reasonable control of such party, which in the exercise of due diligence could not have been avoided, including without limitation, fire, explosion, earthquake, storm, flood or other weather, unavailability of necessary utilities or raw materials, strike, lockout, unavailability of any component, activities of a combination of workers or other labor difficulties, war, insurrection, riot, act of God or public enemy, law, act, order, export control regulation, proclamation decree, regulations, ordinance, or instruction of government or other public authorities, or judgment or decree of a court of competent jurisdiction (not arising out of any breach by such party of this Agreement). In the event of such occurrence, the party so affected will give prompt notice to the other parties, stating the period of time the occurrence is expected to continue.
View SourceView Similar (2)
Performance Delayed. 24.1 Performance Delayed.
View Source

Related to Performance Delayed

  • Performance Delay Time is of the essence in the Vendor’s performance of this Agreement. If at any time it appears to Vendor that it may not meet any of the performance schedules or the scheduled completion date of the services to be performed for any reason, including labor disputes, Vendor shall immediately by verbal means (to be confirmed in writing) notify Customer of the reasons for and the estimated duration of such delay. If requested by Customer, Vendor shall make every effort to avoid or minimize the delay to the maximum extent possible including the expenditure of premium time. Any additional cost caused by these requirements of Customer shall be borne by Vendor, unless the delay in performance arises out of causes beyond the control and without the fault or negligence of Vendor or its subcontractors within the meaning of the Cancellation- Default clause herein. The foregoing requirements are in addition to any of Customer’s other rights and remedies as may be provided by law or this Agreement.

  • Performance Excused The Affected Party, to the extent rendered unable to perform its obligations or part thereof under this Agreement as a consequence of the Force Majeure Event shall be excused from performance of the obligations. Provided that, the excuse from performance shall be of no greater scope and of no longer duration than is reasonably warranted by the Force Majeure Event. Provided further, nothing contained herein shall absolve the Affected Party from any payment obligations accrued prior to the occurrence of the underlying Force Majeure Event.

  • Performance Schedule The Parties will perform their respective responsibilities in accordance with the Performance Schedule. By executing this Agreement, Customer authorizes Motorola to proceed with contract performance.

  • Annual Performance Review The Employee’s performance of his duties under this Agreement shall be reviewed by the Board of Directors or a committee of the Board of Directors at least annually and finalized within thirty (30) days of the receipt of the annual audited financial statements. The Board of Directors or a committee of the Board of Directors shall additionally review the base salary, bonus and benefits provided to the Employee under this Agreement and may, in their discretion, adjust the same, as outlined in Addendum B of this Agreement, provided, however, that Employee’s annual base salary shall not be less than the base salary set forth in Section 4(A) hereof.

  • Performance Measure Grantee will adhere to the performance measures requirements documented in