Common use of Payment Amount Clause in Contracts

Payment Amount. Payment for the Services shall be as follows: (choose one) ☐ - $______________________ for the Services (“Payment”). ☐ - At an hourly rate of $____ per hour (“Payment”). ☐ - Other. ______________________________________________ (“Payment”) If the Subcontractor asserts a claim which involves, in whole or in part, acts or omissions which are the responsibility of the Client or another person for whom a claim may be submitted, including but not limited to, claims for failure to pay, an extension of time, impacts, delay damages, or extra work, the Contractor shall present the Subcontractor's claim to the Client or other responsible party provided the Subcontractor presents to Contractor competent supporting evidence and in sufficient time for the Contractor to do so. The Subcontractor shall cooperate fully with the Contractor in any and all steps the Contractor takes in connection with prosecuting such a claim and shall hold harmless and reimburse the Contractor for all expenses, including legal expenses, incurred by the Contractor which arise out of the Contractor's submission of the Subcontractor's claims to the Client or other responsible party(ies). The Subcontractor shall be bound by any adjudication or award in any action or proceeding resolving such a claim.

Payment Amount. Payment for the Services shall be as follows: (choose one) ☐ - $_____________________$ _ for the Services (“Payment”). ☐ - At an hourly rate of $____ $ per hour (“Payment”). ☐ - Other. ______________________________________________ (“Payment”) If the Subcontractor asserts a claim which involves, in whole or in part, acts or omissions which are the responsibility of the Client or another person for whom a claim may be submitted, including but not limited to, claims for failure to pay, an extension of time, impacts, delay damages, or extra work, the Contractor shall present the Subcontractor's claim to the Client or other responsible party provided the Subcontractor presents to Contractor competent supporting evidence and in sufficient time for the Contractor to do so. The Subcontractor shall cooperate fully with the Contractor in any and all steps the Contractor takes in connection with prosecuting such a claim and shall hold harmless and reimburse the Contractor for all expenses, including legal expenses, incurred by the Contractor which arise out of the Contractor's submission of the Subcontractor's claims to the Client or other responsible party(ies). The Subcontractor shall be bound by any adjudication or award in any action or proceeding resolving such a claim.

Payment Amount. Payment for the Services shall be as follows: (choose one) ☐ - $______________________ $ for the Services (“Payment”). ☐ - At an hourly rate of $____ $ per hour (“Payment”). ☐ - Other. ______________________________________________ (“Payment”) If the Subcontractor asserts a claim which involves, in whole or in part, acts or omissions which are the responsibility of the Client or another person for whom a claim may be submitted, including but not limited to, claims for failure to pay, an extension of time, impacts, delay damages, or extra work, the Contractor shall present the Subcontractor's claim to the Client or other responsible party provided the Subcontractor presents to Contractor competent supporting evidence and in sufficient time for the Contractor to do so. The Subcontractor shall cooperate fully with the Contractor in any and all steps the Contractor takes in connection with prosecuting such a claim and shall hold harmless and reimburse the Contractor for all expenses, including legal expenses, incurred by the Contractor which arise out of the Contractor's submission of the Subcontractor's claims to the Client or other responsible party(ies). The Subcontractor shall be bound by any adjudication or award in any action or proceeding resolving such a claim.