Notice of Potential Claims The Contractor shall not be entitled to additional compensation or to extension of time for (1) any act or failure to act by the County Project Manager or the County, or (2) the happening of any event or occurrence, unless the Contractor has given the County a written Notice of Potential Claim within ten (10) days of the commencement of the act, failure, or event giving rise to the claim, and before final payment by the County. The written Notice of Potential Claim shall set forth the reasons for which the Contractor believes additional compensation or extension of time is due, the nature of the cost involved, and insofar as possible, the amount of the potential claim. Contractor shall keep full and complete daily records of the work performed, labor and material used, and all costs and additional time claimed to be additional.
Conduct of Claims 31.6.1 The Indemnifying Party may at its own expense and with the assistance and co-operation of the Indemnified Party have the conduct of the Third Party Claim including its settlement and the Indemnified Party will not, unless the Indemnifying Party has failed to resolve the Third Party Claim within a reasonable period (and the Indemnified Party has notified the Indemnifying Party in writing that it is of the opinion that such reasonable period has expired), take any action to settle or pursue the Third Party Claim
Notice of Claims, etc Promptly after receipt by an indemnified party of notice of the commencement of any action or proceeding involving a claim referred to in the preceding subdivisions of this Section 5, such indemnified party will, if a claim in respect thereof is to be made against an indemnifying party, give written notice to the latter of the commencement of such action, provided, however, that the failure of any indemnified party to give notice as provided herein shall not relieve the indemnifying party of its obligations under the preceding subdivisions of this Section 5. In case any such action is brought against an indemnified party, unless in such indemnified party's reasonable judgment a conflict of interest between such indemnified and indemnifying party may exist in respect of such claim, the indemnifying party shall be entitled to participate in, and to assume the defense thereof, jointly with any other indemnifying party similarly notified, to the extent that it may wish, with counsel reasonably satisfactory to such indemnified party, and after notice from the indemnifying party to such indemnified party of its election so to assume the defense thereof, the indemnifying party shall not be liable to such indemnified party for any legal or other expenses subsequently incurred by the latter in connection with the defense thereof other than reasonable costs of investigation. No indemnifying party shall, without the consent of the indemnified party, consent to entry of any judgment or enter into any settlement of such proceedings which does not include as an unconditional term thereof the giving by the claimant or plaintiff to such indemnified party of a complete and unconditional release from all liability in respect to such claim or litigation.
Notification of Claims In order that the indemnification provisions contained in this Section shall apply, upon the assertion of a claim for which either party may be required to indemnify the other, the party seeking indemnification shall promptly notify the other party of such assertion, and shall keep the other party advised with respect to all developments concerning such claim. The party who may be required to indemnify shall have the option to participate with the party seeking indemnification in the defense of such claim or to defend against said claim in its own name or in the name of the other party. The party seeking indemnification shall in no case confess any claim or make any compromise in any case in which the other party may be required to indemnify it except with the other party’s prior written consent.
Notice of Claims If the City or Contractor receives notice of any claim or circumstances which could give rise to an indemnified loss, the receiving Party shall give written notice to the other Party within 30 days. The notice must include the following:
Submission of Claims 39 If Provider submits claims for Services rendered under this Contract, the following 40 requirements shall apply:
Third Party Claim Procedures (a) The Indemnified Party seeking indemnification under Section 7.02 agrees to give reasonably prompt notice in writing to Indemnifying Party of the assertion of any claim or the commencement of any suit, action or proceeding by any third party (“Third Party Claim”) in respect of which indemnity may be sought under Section 7.02. Such notice shall set forth in reasonable detail such Third Party Claim and the basis for indemnification (taking into account the information then available to the Indemnified Party). The failure to so notify the Indemnifying Party shall not relieve the Indemnifying Party of its obligations hereunder, except to the extent such failure shall have actually materially and adversely prejudiced the Indemnifying Party.
Notice and contest of claims In the event that either Party receives a claim or demand from a third party in respect of which it is entitled to the benefit of an indemnity under this Article 38 (the "Indemnified Party") it shall notify the other Party (the "Indemnifying Party") within 15 (fifteen) days of receipt of the claim or demand and shall not settle or pay the claim without the prior approval of the Indemnifying Party, which approval shall not be unreasonably withheld or delayed. In the event that the Indemnifying Party wishes to contest or dispute the claim or demand, it may conduct the proceedings in the name of the Indemnified Party, subject to the Indemnified Party being secured against any costs involved, to its reasonable satisfaction.
Indemnification Procedures for Third Party Claims If a claim by a third party (including claims for breaches of fiduciary duties) is made against an Indemnified Party and such Indemnified Party intends to seek indemnity with respect thereto from the Company (in the case of a Purchaser Indemnified Party seeking such indemnity) or the Purchaser (in the case of a Company Indemnified Party seeking indemnity) (each of the Company or the Purchaser, as the case may be, in such capacity, an “Indemnifying Party”), such Indemnified Party shall give notice in writing as promptly as reasonably practicable to such Indemnifying Party of any Proceeding commenced against or by it in respect of which indemnity may be sought hereunder, but failure to so notify such Indemnifying Party shall not relieve such Indemnifying Party from any liability that it may have on account of this Article VI, so long as such failure shall not have materially prejudiced the position of such Indemnifying Party. Upon such notification, the Indemnifying Party shall assume the defense of such Proceeding brought by a third party, and, after such assumption, the Indemnified Party shall not be entitled to reimbursement of any expenses thereafter incurred by it in connection with such Proceeding, except as described below. In any such Proceeding, any Indemnified Party shall have the right to retain its own counsel (including local counsel), but the fees and expenses of such counsel shall be at the expense of such Indemnified Party unless (i) the Indemnifying Party shall have failed to promptly assume and thereafter conduct such defense, (ii) the Indemnifying Party and the Indemnified Party shall have mutually agreed to the contrary, (iii) in the reasonable determination of counsel for the Indemnified Party, representation of such Indemnified Party by counsel obtained by the Indemnifying Party would be inappropriate due to actual or potential conflicting interests between such Indemnified Party and any other party represented by such counsel in such proceeding. No Indemnifying Party, in the defense of a third-party claim, shall, except with the consent of the Indemnified Party, consent to entry of any judgment or enter into any settlement that does not include as an unconditional term thereof the giving by the claimant or plaintiff to such Indemnified Party of a release from all liability in respect of such claim. The Indemnifying Party shall not be liable for any settlement of any Proceeding effected without its written consent (which shall not be unreasonably withheld, delayed or conditioned by such Indemnifying Party), but if settled with such consent or if there be final judgment for the plaintiff, the Indemnifying Party shall indemnify the Indemnified Party from and against any Loss by reason of such settlement or judgment. The Indemnifying Party will advance expenses to an Indemnified Party as reasonably incurred so long as such indemnified party shall have provided the indemnifying party with a written undertaking to reimburse the indemnifying party for all amounts so advanced if it is ultimately determined that the indemnified party is not entitled to indemnification hereunder (which shall include breaches of fiduciary duty if permitted above).
Notice; Defense of Claims An indemnified party may make claims for indemnification hereunder by giving written notice thereof to the indemnifying party within the period in which indemnification claims can be made hereunder. If indemnification is sought for a claim or liability asserted by a third party, the indemnified party shall also give written notice thereof to the indemnifying party promptly after it receives notice of the claim or liability being asserted, but the failure to do so shall not relieve the indemnifying party from any liability except to the extent that it is prejudiced by the failure or delay in giving such notice. Such notice shall summarize the bases for the claim for indemnification and any claim or liability being asserted by a third party. Within 20 days after receiving such notice the indemnifying party shall give written notice to the indemnified party stating whether it disputes the claim for indemnification and whether it will defend against any third party claim or liability at its own cost and expense. If the indemnifying party fails to give notice that it disputes an indemnification claim within 20 days after receipt of notice thereof, it shall be deemed to have accepted and agreed to the claim, which shall become immediately due and payable. The indemnifying party shall be entitled to direct the defense against a third party claim or liability with counsel selected by it (subject to the consent of the indemnified party, which consent shall not be unreasonably withheld) as long as the indemnifying party is conducting a good faith and diligent defense. The indemnified party shall at all times have the right to fully participate in the defense of a third party claim or liability at its own expense directly or through counsel; provided, however, that if the named parties to the action or proceeding include both the indemnifying party and the indemnified party and the indemnified party is advised that representation of both parties by the same counsel would be inappropriate under applicable standards of professional conduct, the indemnified party may engage separate counsel at the expense of the indemnifying party. If no such notice of intent to dispute and defend a third party claim or liability is given by the indemnifying party, or if such good faith and diligent defense is not being or ceases to be conducted by the indemnifying party, the indemnified party shall have the right, at the expense of the indemnifying party, to undertake the defense of such claim or liability (with counsel selected by the indemnified party), and to compromise or settle it, exercising reasonable business judgment. If the third party claim or liability is one that by its nature cannot be defended solely by the indemnifying party, then the indemnified party shall make available such information and assistance as the indemnifying party may reasonably request and shall cooperate with the indemnifying party in such defense, at the expense of the indemnifying party.
