Common use of MUTUAL RESPONSIBILITY Clause in Contracts

MUTUAL RESPONSIBILITY. 6.2.1 Contractor shall be responsible for affording Separate Contractors reasonable opportunity for introduction and storage of their materials and equipment and performance of their activities. Contractor shall schedule and coordinate its construction and operations with the construction and operations of Separate Contractors as required by the Contract Documents. 6.2.2 If a portion of the Work is dependent upon the proper execution or results of other construction or operations by Separate Contractors, Contractor shall inspect such other construction or operations before proceeding with its portion of the Work. Contractor shall promptly report to City apparent discrepancies or defects which render the other construction or operations unsuitable to receive the Contractor’s Work. Unless otherwise directed by City, Contractor shall not proceed with the portion of the Work affected until apparent discrepancies or defects have been corrected. Failure of Contractor to so report within a reasonable time after discovering such discrepancies or defects shall constitute an acknowledgment that the other construction or operations by City or Separate Contractors is suitable to receive the Work, except as to defects not then reasonably discoverable. 6.2.3 In the event of Delays, improperly timed activities or Defective Work by the Contractor or the Separate Contractors, the costs of such occurrences shall be borne by the party responsible therefor. 6.2.4 If Contractor wrongfully causes damage to completed or partially completed construction or to property of City or Separate Contractors, Contractor shall promptly remedy damage as provided in Paragraph 12.2 of these General Conditions. 6.2.5 If a dispute, or other matters in question arise between Contractor and a Separate Contractor, these occurrences shall be subject to the provisions of Section 4.2 and 4.3 of the General Conditions. Contractor shall immediately notify the Construction Manager in writing of such occurrences.

MUTUAL RESPONSIBILITY. 6.2.1 The Contractor shall be responsible for affording Separate Contractors afford the Owner and separate contractors reasonable opportunity for introduction and storage of their materials and equipment and performance of their activities. Contractor activities and shall schedule connect and coordinate its the Contractor's construction and operations with the construction and operations of Separate Contractors theirs as required by the Contract Documents. 6.2.2 If a portion part of the Contractor's Work is dependent upon the depends for proper execution or results of other upon construction or operations by Separate Contractorsthe Owner or a separate contractor, the Contractor shall inspect such other construction or operations before shall, prior to proceeding with its that portion of the Work. Contractor shall , promptly report to City the Architect and ARS apparent discrepancies or defects which render the in such other construction or operations that would render it unsuitable to receive the Contractor’s Work. Unless otherwise directed by City, Contractor shall not proceed with the portion of the Work affected until apparent discrepancies or defects have been correctedfor such proper execution and results. Failure of the Contractor so to so report within a reasonable time after discovering such discrepancies or defects shall constitute an acknowledgment that the other Owner's or separate contractors' completed or partially completed construction or operations by City or Separate Contractors is suitable fit and proper to receive the Contractor's Work, except as to defects not then reasonably discoverable. 6.2.3 In the event of Delays, Costs caused by delays or by improperly timed activities or Defective Work by the Contractor or the Separate Contractors, the costs of such occurrences defective construction shall be borne by the party responsible therefor. 6.2.4 If The Contractor wrongfully causes shall promptly remedy damage caused by the Contractor to completed or partially completed construction or to property of City the Owner of separate contractors as provided in Subparagraph 10.2.5. 6.2.5 Should the Contractor cause damage to the work or Separate Contractorsproperty of any separate contractor and/or in the event of any other claim, dispute or matter in question between the Contractor and any separate contractor, the Contractor shall promptly remedy attempt to settle with such other contractor by agreement, or otherwise to resolve the dispute. In any event, the Contractor shall indemnify, defend and hold harmless the Owner and the other indemnitees as to damage to any such work or property it causes to the full extent as provided in agreed to under Paragraph 12.2 11.8 of these General Conditions. 6.2.5 If a dispute, or other matters 6.2.6 The Owner and each separate contractor shall have the same responsibilities for cutting and patching as are described for the Contractor in question arise between Contractor and a Separate Contractor, these occurrences shall be subject to the provisions of Section 4.2 and 4.3 of the General Conditions. Contractor shall immediately notify the Construction Manager in writing of such occurrencesParagraph 3.14.

MUTUAL RESPONSIBILITY. 6.2.1 The Contractor shall be responsible for affording Separate Contractors afford the Owner and separate contractors reasonable opportunity for introduction and storage of their materials and equipment and performance of their activities. Contractor , and shall schedule connect and coordinate its the Contractor's construction and operations with the construction and operations of Separate Contractors theirs as required by the Contract Documents. 6.2.2 If a portion part of the Contractor's Work is dependent upon the depends for proper execution or results of other upon construction or operations operation by Separate Contractorsthe Owner or a separate contractor, the Contractor shall inspect such other construction or operations before shall, prior to proceeding with its that portion of the Work. Contractor shall , promptly report to City the Architect and the Owner apparent discrepancies or defects which render the in such other construction or operations that would render it unsuitable to receive the Contractor’s Work. Unless otherwise directed by City, Contractor shall not proceed with the portion of the Work affected until apparent discrepancies or defects have been correctedfor such proper execution and results. Failure of the Contractor to so report within a reasonable time after discovering such discrepancies or defects shall constitute an acknowledgment that the other Owner's or separate contractors' completed or partially completed construction or operations by City or Separate Contractors is suitable fit and proper to receive the Contractor's Work, except as to defects not then reasonably discoverable. 6.2.3 In the event of Delays, Costs caused by delays or by improperly timed activities or Defective Work by the Contractor or the Separate Contractors, the costs of such occurrences defective construction shall be borne by the party responsible therefor. 6.2.4 If The Contractor wrongfully causes shall promptly remedy damage caused by the Contractor to completed or partially completed construction or to property of City the Owner or Separate Contractors, Contractor shall promptly remedy damage separate contractors as provided in Paragraph 12.2 of these General ConditionsSubparagraph 10.2.5, below. 6.2.5 If a dispute, or Claims and other disputes and matters in question arise between the Contractor and a Separate Contractor, these occurrences separate contractor shall be subject to the provisions of Section 4.2 Paragraph 4.3 above, provided the separate contractor has reciprocal obligations. If such separate contractor initiates legal or any other proceedings against the Owner on account of any damage alleged to have been caused by the Contractor, the Owner shall notify the Contractor, who shall defend such proceedings at its own expense, and 4.3 of if any judgment or award against the General Conditions. Owner arises therefrom, the Contractor shall immediately notify pay or satisfy it, and shall reimburse the Construction Manager Owner for all attorneys' fees and court or other costs which the Owner has incurred over and above those paid for directly by the Contractor. 6.2.6 The Owner and each separate contractor shall have the same responsibilities for cutting and patching as are described for the Contractor in writing of such occurrencesParagraph 3.14, above.

MUTUAL RESPONSIBILITY. 6.2.1 The ▇▇▇▇ Contractor shall be responsible for affording Separate Contractors afford the Owner and separate Contractor’s reasonable opportunity for introduction and storage of their materials and equipment and performance of their activities. Contractor , and shall schedule connect and coordinate its the Contractor’s construction and operations with the construction and operations of Separate Contractors theirs as required by the Contract Documents. 6.2.2 If a portion part of the Contractor’s Work is dependent upon the depends for proper execution or results of other upon construction or operations by Separate Contractorsthe Owner or a separate ▇▇▇▇ Contractor, the ▇▇▇▇ Contractor shall inspect such other construction or operations before shall, prior to proceeding with its that portion of the Work. Contractor shall promptly , promptly, so as not to delay the project, report to City the Architect and Owner apparent discrepancies or defects which render the in such other construction that would render it unsuitable for proper execution and results. The Contractor’s failure to promptly report, so as not to delay the project, such discrepancies or operations unsuitable defects constitutes acknowledgement and acceptance that the Owner’s or separate Contractor’s completed or partially completed Work is fit and proper to receive the Contractor’s Work. Unless otherwise directed by City, Contractor shall not proceed with the portion of the Work affected until apparent discrepancies or defects have been corrected. Failure of Contractor to so report within a reasonable time after discovering such discrepancies or defects shall constitute an acknowledgment that the other construction or operations by City or Separate Contractors is suitable to receive the Work, except as to defects not then reasonably discoverable. 6.2.3 In The Owner shall be reimbursed by the event ▇▇▇▇ Contractor for costs incurred by the Owner which are payable to a separate ▇▇▇▇ Contractor because of Delaysdelays, improperly timed activities or Defective Work defective construction of the ▇▇▇▇ Contractor. The Owner shall be responsible to the ▇▇▇▇ Contractor for costs incurred by the ▇▇▇▇ Contractor because of delays, improperly timed activities, damage to the Work or defective construction of the Separate Contractors, the costs of such occurrences shall be borne by the party responsible thereforOwner or separate ▇▇▇▇ Contractor. 6.2.4 If The ▇▇▇▇ Contractor wrongfully causes shall promptly remedy damage caused by the ▇▇▇▇ Contractor to completed or partially completed construction or to property of City the Owner or Separate Contractors, Contractor shall promptly remedy damage separate Contractors as provided in Paragraph 12.2 of these General ConditionsSubparagraph 10.2.5. 6.2.5 If a dispute, or other matters in question arise between Contractor The Owner and a Separate Contractor, these occurrences shall be subject to the provisions of Section 4.2 and 4.3 of the General Conditions. each separate ▇▇▇▇ Contractor shall immediately notify have the Construction Manager same responsibilities for cutting and patching and clean up as are described for the ▇▇▇▇ Contractor in writing of such occurrencesSubparagraph 3.14 and 3.15.

MUTUAL RESPONSIBILITY. § 6.2.1 The Contractor shall be responsible for affording afford the Owner and Separate Contractors reasonable opportunity for introduction and storage of their materials and equipment and performance of their activities. Contractor , and shall schedule connect and coordinate its the Contractor’s construction and operations with the construction and operations of Separate Contractors theirs as required by the Contract Documents. § 6.2.2 If a portion part of the Contractor’s Work is dependent upon the depends for proper execution or results of other upon construction or operations by the Owner or a Separate ContractorsContractor, the Contractor shall inspect such other construction or operations before shall, prior to proceeding with its that portion of the Work. Contractor shall , promptly report to City notify om writing the Design Professional and Owner of any apparent discrepancies or defects which render the in such other construction or operations that would render it unsuitable to receive the Contractor’s Work. Unless otherwise directed by City, Contractor shall not proceed with the portion of the Work affected until apparent discrepancies or defects have been correctedfor such proper execution and results. Failure of the Contractor to so report within a reasonable time after discovering such discrepancies or defects shall constitute an acknowledgment that the other construction or operations by City Owner’s or Separate Contractors Contractor’s completed or partially completed construction is suitable fit and proper to receive the Contractor’s Work, except as to defects not then reasonably discoverable. 6.2.3 § 6.2.2.1 If part of the Contractor’s Work requires that any work being performed by the Owner or any of its Separate Contractors be performed before the Contractor can proceed, the Contractor shall give the Owner and Design Professional reasonable advance written notice of when such work must be done. In the event absence of Delayssuch written notice, the Contractor shall not be entitled to any additional costs or time arising out of delay caused by the Owner or its Separate Contractors in completing such Work. § 6.2.3 The Contractor shall reimburse the Owner for costs the Owner incurs that are payable to a Separate Contractor because of the Contractor’s delays, improperly timed activities or Defective Work by defective construction. § 6.2.4 The Contractor shall promptly remedy damage that the Contractor or the Separate Contractors, the costs of such occurrences shall be borne by the party responsible therefor. 6.2.4 If Contractor wrongfully causes damage to completed or partially completed construction or to property of City the Owner or Separate Contractors, Contractor shall promptly remedy damage as provided in Paragraph 12.2 of these General ConditionsSection 10.2.5. § 6.2.5 If a dispute, or other matters in question arise between Contractor The Owner and a each Separate Contractor, these occurrences shall be subject to the provisions of Section 4.2 and 4.3 of the General Conditions. Contractor shall immediately notify have the Construction Manager same responsibilities for cutting and patching as are described for the Contractor in writing of such occurrencesSection 3.14.

MUTUAL RESPONSIBILITY. ‌ 6.2.1 Contractor shall be responsible for affording Separate Contractors reasonable opportunity for introduction and storage of their materials and equipment and performance of their activities. Contractor shall schedule and coordinate its construction and operations with the construction and operations of Separate Contractors as required by the Contract Documents. 6.2.2 If a portion of the Work is dependent upon the proper execution or results of other construction or operations by Separate Contractors, Contractor shall inspect such other construction or operations before proceeding with its that portion of the Work. Contractor shall promptly report to City District apparent discrepancies or defects which render the other construction or operations unsuitable to receive the Contractor’s Work. Unless otherwise directed by CityDistrict, Contractor shall not proceed with the portion of the Work affected until apparent discrepancies or defects have been corrected. Failure of Contractor to so report within a reasonable time after discovering such discrepancies or defects shall constitute an acknowledgment that the other construction or operations by City or Separate Contractors is suitable to receive the Work, except as to defects not then reasonably discoverable.acknowledgment 6.2.3 In the event of Delays, improperly timed activities or Defective Work by the Contractor or the Separate ContractorsWork, the costs of such occurrences shall be borne by the party responsible therefortherefore. 6.2.4 If Contractor wrongfully causes damage to completed or partially completed construction or to property of City District or Separate Contractors, Contractor shall promptly remedy damage as provided in Paragraph 12.2 of these General Conditionsdamage. 6.2.5 If a dispute, or other matters in question arise between Contractor and a Separate Contractor, these occurrences shall be subject to the provisions of Section 4.2 and 4.3 14 (Dispute Resolution) of the General ConditionsConstruction Contract. Contractor shall immediately notify the Construction Manager in writing and within seventy-two (72) hours of such occurrences.

MUTUAL RESPONSIBILITY. ‌ 6.2.1 Contractor shall be responsible for affording Separate Contractors reasonable opportunity for introduction and storage of their materials and equipment and performance of their activities. Contractor shall schedule and coordinate its construction and operations with the construction and operations of Separate Contractors as required by the Contract Documents. 6.2.2 If a portion of the Work is dependent upon the proper execution or results of other construction or operations by Separate Contractors, Contractor shall inspect such other construction or operations before proceeding with its that portion of the Work. Contractor shall promptly report to City District apparent discrepancies or defects which render the other construction or operations unsuitable to receive the Contractor’s Work. Unless otherwise directed by CityDistrict, Contractor shall not proceed with the portion of the Work affected until apparent discrepancies or defects have been corrected. Failure of Contractor to so report within a reasonable time after discovering such discrepancies or defects shall constitute an acknowledgment that the other construction or operations by City or Separate Contractors is suitable to receive the Work, except as to defects not then reasonably discoverable.report 6.2.3 In the event of Delays, improperly timed activities or Defective Work by the Contractor or the Separate ContractorsWork, the costs of such occurrences shall be borne by the party responsible therefortherefore. 6.2.4 If Contractor wrongfully causes damage to completed or partially completed construction or to property of City District or Separate Contractors, Contractor shall promptly remedy damage as provided in Paragraph 12.2 of these General Conditionsdamage. 6.2.5 If a dispute, or other matters in question arise between Contractor and a Separate Contractor, these occurrences shall be subject to the provisions of Section 4.2 and 4.3 14 (Dispute Resolution) of the General ConditionsConstruction Contract. Contractor shall immediately notify the Construction Manager in writing and within seventy-two (72) hours of such occurrences.

MUTUAL RESPONSIBILITY. 6.2.1 6.2.1. Contractor shall be responsible for affording Separate Contractors afford ▇▇▇▇ COUNTY and ▇▇▇▇ COUNTY’s separate contractor(s) reasonable opportunity for the introduction and storage of their materials and equipment and equipment, the performance of their activities. Contractor shall schedule activities and coordinate its the coordination of Contractor’s construction and operations with the construction and operations of Separate Contractors theirs, as required by the Contract Documents. 6.2.2 6.2.2. If part of Contractor’s Work depends upon the construction or operations by ▇▇▇▇ COUNTY or a portion of the Work is dependent upon separate contractor for the proper execution or results of other construction or operations by Separate Contractorsresults, Contractor shall inspect such other construction or operations before shall, prior to proceeding with its that portion of the Work. Contractor shall , promptly report to City ▇▇▇▇ COUNTY apparent discrepancies or defects which render the in such other construction or operations that would render it unsuitable to receive the Contractor’s Work. Unless otherwise directed by City, Contractor shall not proceed with the portion of the Work affected until apparent discrepancies or defects have been correctedfor such proper execution and results. Failure of Contractor to so report within a reasonable time after discovering such discrepancies or defects shall constitute an acknowledgment that the other ▇▇▇▇ COUNTY’s separate contractor’s completed or partially completed construction or operations by City or Separate Contractors is suitable fit and proper to receive the Contractor’s Work, except as to defects not then reasonably discoverable. 6.2.3 In the event 6.2.3. ▇▇▇▇ COUNTY shall be reimbursed by Contractor for costs incurred by ▇▇▇▇ COUNTY which are payable to a separate contractor because of Delaysdelays, improperly timed activities or Defective defective construction of Contractor. ▇▇▇▇ COUNTY shall be responsible to Contractor for costs incurred by Contractor because of delays, improperly timed activities and damage to the Work or defective construction of ▇▇▇▇ COUNTY’s separate contractor(s). 6.2.4. Contractor promptly shall remedy any damage wrongfully caused by the Contractor or the Separate Contractors, the costs of such occurrences shall be borne by the party responsible therefor. 6.2.4 If Contractor wrongfully causes damage its Subcontractor(s) to any completed or partially completed construction or to property of City ▇▇▇▇ COUNTY or Separate Contractors▇▇▇▇ COUNTY’s separate contractor(s), Contractor shall promptly remedy damage as provided in Paragraph 12.2 of these General ConditionsSection 10.2.5 herein. 6.2.5 If a dispute, or other matters 6.2.5. ▇▇▇▇ COUNTY and each separate contractor shall have the same responsibilities for cutting and patching as are described for Contractor in question arise between Contractor and a Separate Contractor, these occurrences shall be subject to the provisions of Section 4.2 and 4.3 of the General Conditions. Contractor shall immediately notify the Construction Manager in writing of such occurrences3.14 herein.