MATERIAL SAMPLES Sample Clauses

MATERIAL SAMPLES. 6.6.1 The Contractor shall furnish all samples required by the drawings and specifications or that may be requested by the Project Manager of any and all materials or equipment it proposes to use. Unless specifically required, samples are not to be submitted with the bid.
AutoNDA by SimpleDocs
MATERIAL SAMPLES. The same procedure shall be followed for any re-submittals. All shop drawings, material samples and submittal literature shall be properly identified with job name, product type, model number and certification stamp. All shop drawings, material samples and/or submittal literature must be mailed or hand-delivered to Contractor’s office. Contractor will not accept or process any submittals sent by facsimile. Any exceptions to the required submittal material must be requested in writing and authorized by Contractor before they are submitted to Contractor for Owner review.
MATERIAL SAMPLES. 3.14.1 The Design-Builder shall furnish for the written approval of the Engineer any samples required by the Contract Documents or that may be requested by the Engineer of any and all materials or equipment Design-Builder proposes to use to complete the Work. The Design-Builder shall not use any materials or equipment of which samples are required to be submitted until written approval has been given by the Engineer.
MATERIAL SAMPLES. If any of the Information delivered by Liquidmetal or its Representatives to Company consists of samples of amorphous alloys or samples of other materials (referred to as "Materials"), then Company shall not take or send the Materials to any location other than the facilities of the Company without the prior written consent of Liquidmetal. The Company acknowledges that the Materials may be experimental in nature and shall be used with prudence and appropriate caution. The Company will not engage in any testing or processing of the Materials (including, but not limited to, any grinding, melting, milling, or machining of the Materials) without the express prior written consent of Liquidmetal. In no event shall Liquidmetal be liable for any use by the Company or its Representatives for any loss, claim, damage, or liability, of any kind or nature, that may arise from or in connection with the use, handling, or storage of the Materials, and the Company agrees to indemnify and hold harmless Liquidmetal and Liquidmetal's Representatives from any liability, loss, or damage they may suffer as a result of claims, demands, costs, or judgments against them arising out of the use or disposition of the Materials by the Company. (e)
MATERIAL SAMPLES. 9 Article 4 B&L License........................................ 9
MATERIAL SAMPLES. All materials believed by either party to be useful in the design of Products and prepared by such party in the course of any of its research under this Agreement will be discussed with the other party and samples of such materials will be submitted to the other party upon request.
MATERIAL SAMPLES. During the course of the work, the Project Representative shall be allowed to secure samples of the materials being used from the containers on the jobsite and submit them to an independent testing laboratory for comparison. All non-approved material installed or stored shall be removed from the construction site until it has been tested. Installed materials that do not conform to the Contract shall be removed at no additional cost to King County. May 2017 C01025C17 Georgetown Wet Weather Treatment Station 07513 - 2 MODIFIED BITUMEN ROOFING SYSTEM
AutoNDA by SimpleDocs
MATERIAL SAMPLES. Samples of all primary materials to be used in the fabrication of the Artwork.

Related to MATERIAL SAMPLES

  • Product ACCEPTANCE Unless otherwise provided by mutual agreement of the Authorized User and the Contractor, Authorized User(s) shall have thirty (30) days from the date of delivery to accept hardware products and sixty (60) days from the date of delivery to accept all other Product. Where the Contractor is responsible for installation, acceptance shall be from completion of installation. Failure to provide notice of acceptance or rejection or a deficiency statement to the Contractor by the end of the period provided for under this clause constitutes acceptance by the Authorized User(s) as of the expiration of that period. The License Term shall be extended by the time periods allowed for trial use, testing and acceptance unless the Commissioner or Authorized User agrees to accept the Product at completion of trial use. Unless otherwise provided by mutual agreement of the Authorized User and the Contractor, Authorized User shall have the option to run testing on the Product prior to acceptance, such tests and data sets to be specified by User. Where using its own data or tests, Authorized User must have the tests or representative set of data available upon delivery. This demonstration will take the form of a documented installation test, capable of observation by the Authorized User, and shall be made part of the Contractor’s standard documentation. The test data shall remain accessible to the Authorized User after completion of the test. In the event that the documented installation test cannot be completed successfully within the specified acceptance period, and the Contractor or Product is responsible for the delay, Authorized User shall have the option to cancel the order in whole or in part, or to extend the testing period for an additional thirty (30) day increment. Authorized User shall notify Contractor of acceptance upon successful completion of the documented installation test. Such cancellation shall not give rise to any cause of action against the Authorized User for damages, loss of profits, expenses, or other remuneration of any kind. If the Authorized User elects to provide a deficiency statement specifying how the Product fails to meet the specifications within the testing period, Contractor shall have thirty (30) days to correct the deficiency, and the Authorized User shall have an additional sixty (60) days to evaluate the Product as provided herein. If the Product does not meet the specifications at the end of the extended testing period, Authorized User, upon prior written notice to Contractor, may then reject the Product and return all defective Product to Contractor, and Contractor shall refund any monies paid by the Authorized User to Contractor therefor. Costs and liabilities associated with a failure of the Product to perform in accordance with the functionality tests or product specifications during the acceptance period shall be borne fully by Contractor to the extent that said costs or liabilities shall not have been caused by negligent or willful acts or omissions of the Authorized User’s agents or employees. Said costs shall be limited to the amounts set forth in the Limitation of Liability Clause for any liability for costs incurred at the direction or recommendation of Contractor.

  • Samples The Contractor shall submit the following samples of Materials and relevant information to the Authority’s Engineer for pre-construction review:

  • Product Recalls The Company is not aware of any pattern or series of claims against the Company or any of its subsidiaries which reasonably could be expected to result in a generalized product recall relating to products sold by the Company or any of its subsidiaries, regardless of whether such product recall is formal, informal, voluntary or involuntary.

  • Product Specifications The Company agrees that all Products sold to Xxxx hereunder shall conform to the respective specifications set forth on Schedule A or to such other specifications as are from time to time agreed upon by the Parties.

  • Adverse Events Subsequent to the date hereof, there shall not have occurred any of the following: (i) a suspension or material limitation in trading in securities generally on the New York Stock Exchange, the NASDAQ National Market or the NASDAQ Global Market, (ii) a general moratorium on commercial banking activities in the People’s Republic of China or New York, (iii) the outbreak or escalation of hostilities involving the United States or the People’s Republic of China or the declaration by the United States or the People’s Republic of China of a national emergency or war if the effect of any such event specified in this clause (iii) in your reasonable judgment makes it impracticable or inadvisable to proceed with the public offering or the delivery of the Shares on the terms and in the manner contemplated in the Prospectus, or (iv) such a material adverse change in general economic, political, financial or international conditions affecting financial markets in the United States or the People’s Republic of China having a material adverse impact on trading prices of securities in general, as, in your reasonable judgment, makes it impracticable or inadvisable to proceed with the public offering of the Shares or the delivery of the Shares on the terms and in the manner contemplated in the Prospectus.

  • Product Recall (a) If a recall is required by applicable Law, or if Buyer or Supplier reasonably determines that a recall is advisable because the goods may create a potential safety hazard, are not in compliance with any applicable code, standard or legal requirement, or contain a defect or non-conformance with the requirements of this Order occurring or likely to occur in multiple goods, which such defects or non-conformances are substantially similar or have substantially similar causes or effects (collectively a “Serial Defect”), the parties shall promptly communicate such facts to each other. At Buyer’s request, Supplier shall promptly develop a corrective action plan satisfactory to Buyer, which shall include all actions required to recall and/or repair the goods and any actions required by applicable Law (“Corrective Action Plan”) for Buyer’s review and approval. At Buyer’s election, Xxxxx may develop the Corrective Action Plan. In no event shall Buyer and Supplier’s failure to agree on the Corrective Action Plan delay the timely notification of a potential safety hazard, non-compliance or Serial Defect to users of the goods, cause either party to be non-compliant with applicable Law or prevent Buyer from taking reasonable actions to prevent injury or damage to persons, equipment or other property. Supplier and Buyer shall cooperate with and assist each other in any corrective actions and/or filings, if applicable.

Draft better contracts in just 5 minutes Get the weekly Law Insider newsletter packed with expert videos, webinars, ebooks, and more!