Definition of Building Where Lift Required 1.1 A passenger/materials lift shall be provided on a building which shall, when complete, consist of more than six (6) storey levels excluding the roof, parapets and basement levels (if any), but including the ground floor. (Refer to Sub Clause 2.1 herein.)
POSSESSION OF THE APARTMENT/PLOT 7.1 Schedule for possession of the said [Apartment/Plot] - The Promoter agrees and understands that timely delivery of possession of the [Apartment/Plot] to the allottee and the common areas to the association of allottees or the competent authority, as the case may be, is the essence of the Agreement. The Promoter assures to hand over possession of the [Apartment/Plot] along with ready and complete common areas with all specifications, amenities and facilities of the project in place on , unless there is delay or failure due to war, flood, drought, fire, cyclone, earthquake or any other calamity caused by nature affecting the regular development of the real estate project (“Force Majeure”). If, however, the completion of the Project is delayed due to the Force Majeure conditions then the Allottee agrees that the Promoter shall be entitled to the extension of time for delivery of possession of the [Apartment/Plot], provided that such Force Majeure conditions are not of a nature which make it impossible for the contract to be implemented. The Allottee agrees and confirms that, in the event it becomes impossible for the Promoter to implement the project due to Force Majeure conditions, then this allotment shall stand terminated and the Promoter shall refund to the Allottee the entire amount received by the Promoter from the allotment within 60 days from that date. The promoter shall intimate the allottee about such termination at least thirty days prior to such termination. After refund of the money paid by the Allottee, the Allottee agrees that he/ she shall not have any rights, claims etc. against the Promoter and that the Promoter shall be released and discharged from all its obligations and liabilities under this Agreement.
MAINTENANCE OF CONCESSION PREMISES A. Concessionaire shall preserve and maintain the Concession Premises in good and clean condition, reasonable wear and tear excepted. Concessionaire is solely responsible for the maintenance and cleanliness of the Concession Premises.
Sole purpose of the Concessionaire The Concessionaire having been set up for the sole purpose of exercising the rights and observing and performing its obligations and liabilities under this Agreement, the Concessionaire or any of its subsidiaries shall not, except with the previous written consent of the Authority, be or become directly or indirectly engaged, concerned or interested in any business other than as envisaged herein.
POSSESSION OF THE APARTMENT 7.1 Schedule for possession of the said Apartment - The Promoter agrees and understands that timely delivery of possession of the Apartment to the allottee’s and the common areas to the association of allottee’s or the competent authority, as the case may be, is the essence of the Agreement. The Promoter assures to hand over possession of the Apartment along with ready and complete common areas with all specifications, amenities and facilities of the project in place on (Date) unless there is delay or failure due to war, flood, drought, fire, cyclone, earthquake or any other calamity caused by nature affecting the regular development of the real estate project (“Force Majeure”). If, however, the completion of the Project is delayed due to the Force Majeure conditions then the Allottee’s agrees that the Promoter shall be entitled to the extension of time for delivery of possession of the Apartment, provided that such Force Majeure conditions are not of a nature, which make it impossible for the contract to be implemented. The Allottee’s agrees and confirms that, in the event it becomes impossible for the Promoter to implement the project due to Force Majeure conditions, then this allotment shall stand terminated and the Promoter shall refund to the Allottee’s the entire amount received by the Promoter from the allotment within 45 days from that date. The promoter shall intimate the allottee’s about such termination at least thirty days prior to such termination. After refund of the money paid by the Allottee’s, the Allottee’s agrees that he/ she shall not have any rights, claims etc. against the Promoter and that the Promoter shall be released and discharged from all its obligations and liabilities under this Agreement.
Suspension of unsafe Construction Works (i) Upon recommendation of the Authority’s Engineer to this effect, the Authority may by notice require the Contractor to suspend forthwith the whole or any part of the Works if, in the reasonable opinion of the Authority’s Engineer, such work threatens the safety of the Users and pedestrians.
Obligation to Notify Owner of Existing Hazardous Materials The Contractor shall immediately notify the Owner and the Design Professional, both orally and in writing, of the presence and location of any physical evidence of, or information regarding the presence of Hazardous Materials at the Site of which it becomes aware. If the Contractor encounters Hazardous Materials on the Site the Contractor shall (i) immediately stop performance of Work or that portion of the Work affected by or affecting such Hazardous Materials; (ii) secure the contaminated area against intrusion; (iii) not disturb or remove the Hazardous Materials; (iv) not proceed, or allow any subcontractor or supplier to proceed, with any Work or other activities in the area affected by such Hazardous Materials until such materials have been properly remediated and until directed in writing to do so by the Owner; and, (v) take any other steps necessary to protect life and health and the surrounding environment. The Contractor shall be entitled to adjustment of the Contract Time and the Contract Sum pursuant to Section 5, Part 2 of these General Conditions in order to compensate for the impact of any required demolition, re-work, shutdown, delay, protection of work, disruption, and start-up resulting from the encountering of such Hazardous Materials on the Site for which the Contractor is not responsible.
MAINTENANCE OF THE BUILDING /APARTMENT / PROJECT The Promoter shall be responsible to provide and maintain essential services in the Project till the taking over of the maintenance of the project by the Association upon the issuance of the completion certificate of the Project. The cost of such maintenance has been included in the Total Extras and Deposits as mentioned in clause 1.2.
No Restriction on Existing Examination and Investigative Authority That this Agreement shall in no way preclude any State Mortgage Regulator from exercising its examination or investigative authority authorized under the laws of the corresponding Participating State in the instance a determination is made wherein Respondent is found not to be adhering to the requirements of the Agreement, other than inadvertent and isolated errors that are promptly corrected by Respondent, or involving any unrelated matter not subject to the terms of this Agreement. The Parties agree that the failure of Respondent to comply with any term or condition of this Agreement with respect to a particular State shall be treated as a violation of an Order of the State and may be enforced as such. Moreover, Respondent acknowledges and agrees that this Agreement is only binding on the State Mortgage Regulators and not any other Local, State or Federal Agency, Department or Office.
SALE OF PREMISES Notwithstanding anything contained in this Lease to the contrary, the sale of the Premises by Landlord shall not constitute Landlord’s acceptance of Tenant’s abandonment of the Premises or rejection of the Lease or in any way impair Landlord’s rights upon Tenant’s default, including, without limitation, Landlord’s right to damages.
