Payment of Liquidated Damages With respect to any Liquidated Damages that accrue, Owner shall invoice Contractor for such Liquidated Damages. Contractor shall pay such Liquidated Damages within ten (10) Days after Contractor’s receipt of such invoice. To the extent Contractor does not pay such Liquidated Damages within such ten (10) Day period, Owner may, at its option, do one or more of the following: (i) withhold from Contractor amounts that are otherwise due and payable to Contractor in the amount of such Liquidated Damages and/or (ii) collect on the Letter of Credit in the amount of such Liquidated Damages. For the avoidance of doubt, prior to exercising such right to withhold or collect on the Letter of Credit, Owner shall not be required to provide the notice as set forth in Section 7.8. As used in this Agreement, Liquidated Damages are “paid” if and to the extent Owner exercises option (i) or (ii) above for the collection of Liquidated Damages.
Waiver of Liquidated Damages If the Partnership is unable to cause a Registration Statement to become effective on or before the Target Effective Date, then the Partnership may request a waiver of the Liquidated Damages, which may be granted by the consent of the Holders of at least the Registrable Securities Required Voting Percentage, in their sole discretion, and which such waiver shall apply to all the Holders of Registrable Securities included on such Registration Statement.
Obligation Absolute; Partial Liquidated Damages The Company’s obligations to issue and deliver the Conversion Shares upon conversion of this Debenture in accordance with the terms hereof are absolute and unconditional, irrespective of any action or inaction by the Holder to enforce the same, any waiver or consent with respect to any provision hereof, the recovery of any judgment against any Person or any action to enforce the same, or any setoff, counterclaim, recoupment, limitation or termination, or any breach or alleged breach by the Holder or any other Person of any obligation to the Company or any violation or alleged violation of law by the Holder or any other Person, and irrespective of any other circumstance which might otherwise limit such obligation of the Company to the Holder in connection with the issuance of such Conversion Shares; provided, however, that such delivery shall not operate as a waiver by the Company of any such action the Company may have against the Holder. In the event the Holder of this Debenture shall elect to convert any or all of the outstanding principal amount hereof, the Company may not refuse conversion based on any claim that the Holder or anyone associated or affiliated with the Holder has been engaged in any violation of law, agreement or for any other reason, unless an injunction from a court, on notice to Holder, restraining and or enjoining conversion of all or part of this Debenture shall have been sought and obtained, and the Company posts a surety bond for the benefit of the Holder in the amount of 150% of the outstanding principal amount of this Debenture, which is subject to the injunction, which bond shall remain in effect until the completion of arbitration/litigation of the underlying dispute and the proceeds of which shall be payable to the Holder to the extent it obtains judgment. In the absence of such injunction, the Company shall issue Conversion Shares or, if applicable, cash, upon a properly noticed conversion. If the Company fails for any reason to deliver to the Holder such Conversion Shares pursuant to Section 4(c)(ii) by the Share Delivery Date, the Company shall pay to the Holder, in cash, as liquidated damages and not as a penalty, for each $1,000 of principal amount being converted, $10 per Trading Day (increasing to $20 per Trading Day on the fifth (5th) Trading Day after such liquidated damages begin to accrue) for each Trading Day after such Share Delivery Date until such Conversion Shares are delivered or Holder rescinds such conversion. Nothing herein shall limit a Hxxxxx’s right to pursue actual damages or declare an Event of Default pursuant to Section 8 hereof for the Company’s failure to deliver Conversion Shares within the period specified herein and the Holder shall have the right to pursue all remedies available to it hereunder, at law or in equity including, without limitation, a decree of specific performance and/or injunctive relief. The exercise of any such rights shall not prohibit the Holder from seeking to enforce damages pursuant to any other Section hereof or under applicable law.
Investor’s Rights and Remedies Cumulative; Liquidated Damages All rights, remedies, and powers conferred in this Agreement and the Transaction Documents are cumulative and not exclusive of any other rights or remedies, and shall be in addition to every other right, power, and remedy that Investor may have, whether specifically granted in this Agreement or any other Transaction Document, or existing at law, in equity, or by statute, and any and all such rights and remedies may be exercised from time to time and as often and in such order as Investor may deem expedient. The parties acknowledge and agree that upon Company’s failure to comply with the provisions of the Transaction Documents, Investor’s damages would be uncertain and difficult (if not impossible) to accurately estimate because of the parties’ inability to predict future interest rates and future share prices, Investor’s increased risk, and the uncertainty of the availability of a suitable substitute investment opportunity for Investor, among other reasons. Accordingly, any fees, charges, and default interest due under the Note and the other Transaction Documents are intended by the parties to be, and shall be deemed, liquidated damages (under Company’s and Investor’s expectations that any such liquidated damages will tack back to the Closing Date for purposes of determining the holding period under Rule 144 under the 1933 Act). The parties agree that such liquidated damages are a reasonable estimate of Investor’s actual damages and not a penalty, and shall not be deemed in any way to limit any other right or remedy Investor may have hereunder, at law or in equity. The parties acknowledge and agree that under the circumstances existing at the time this Agreement is entered into, such liquidated damages are fair and reasonable and are not penalties. All fees, charges, and default interest provided for in the Transaction Documents are agreed to by the parties to be based upon the obligations and the risks assumed by the parties as of the Closing Date and are consistent with investments of this type. The liquidated damages provisions of the Transaction Documents shall not limit or preclude a party from pursuing any other remedy available at law or in equity; provided, however, that the liquidated damages provided for in the Transaction Documents are intended to be in lieu of actual damages.
Sole Remedy for a Failure to Report Notwithstanding anything to the contrary in this Indenture or the Notes, the Company may elect that the sole remedy for any Event of Default (a “Reporting Event of Default”) pursuant to Section 5.01(4) arising from the Company’s failure to comply with Section 10.06 will, for each of the first 180 days on which a Reporting Event of Default has occurred and is continuing, consist exclusively of the right to receive Special Interest. If the Company has made such an election, then (i) the Notes will be subject to acceleration pursuant to Section 5.02 on account of the relevant Reporting Event of Default from, and including, the 181st day on which a Reporting Event of Default has occurred and is continuing or if the Company fails to pay any accrued and unpaid Special Interest when due; and (ii) Special Interest will cease to accrue on any Notes from, and including, such 181st day. Any Special Interest that accrues on a Note will be payable on the same dates and in the same manner as Installment Payments on such Note and will accrue at a rate per annum equal to 0.25% of the principal amount thereof for the first 90 days on which Special Interest accrues and, thereafter, at a rate per annum equal to 0.50% of the principal amount thereof. To make the election set forth in this Section 5.16, the Company must send to the Holders, the Trustee and the Paying Agent, before the date on which each Reporting Event of Default first occurs, a notice that (i) briefly describes the report(s) that the Company failed to file with the Commission; (ii) states that the Company is electing that the sole remedy for such Reporting Event of Default consist of the accrual of Special Interest; and (iii) briefly describes the periods during which and rate at which Special Interest will accrue and the circumstances under which the Notes will be subject to acceleration on account of such Reporting Event of Default. If Special Interest accrues on any Note, then, no later than five Business Days before each date on which such Special Interest is to be paid, the Company will deliver an Officer’s Certificate to the Trustee and the Paying Agent stating (i) that the Company is obligated to pay Special Interest on such Note on such date of payment; and (ii) the amount of such Special Interest that is payable on such date of payment. The Trustee will have no duty to determine whether any Special Interest is payable or the amount thereof. No election pursuant to this Section 5.16 with respect to a Reporting Event of Default will affect the rights of any Holder with respect to any other Event of Default, including with respect to any other Reporting Event of Default.
Liquidated Damages The Company’s obligations to pay any partial liquidated damages or other amounts owing under the Transaction Documents is a continuing obligation of the Company and shall not terminate until all unpaid partial liquidated damages and other amounts have been paid notwithstanding the fact that the instrument or security pursuant to which such partial liquidated damages or other amounts are due and payable shall have been canceled.
Failure to Make Payment In the event of failure by the Issuer to make any required payment of principal or interest on this Note (and, in the case of payment of interest, such failure to pay shall have continued for 15 calendar days), the Issuer will, upon demand of the Holder, pay to the Holder the amount then due and payable on this Note for principal and interest (without acceleration of the Note in any manner), with interest on the overdue principal and interest at the rate borne by this Note, to the extent permitted by applicable law. If the Issuer fails to pay such amount upon such demand, the Holder may, among other things, institute a judicial proceeding for the collection of the sums so due and unpaid, may prosecute such proceeding to judgment or final decree and may enforce the same against the Issuer and collect the amounts adjudged or decreed to be payable in the manner provided by law out of the property of the Issuer. Upon the occurrence of a failure by the Issuer to make any required payment of principal or interest on the Note, or any other Event of Default until such Event of Default is cured by the Issuer, the Issuer shall not (a) declare or pay any dividends or distributions on, or redeem, purchase, acquire, or make a liquidation payment with respect to, any of the Issuer’s capital stock, (b) make any payment of principal or interest or premium, if any, on or repay, repurchase or redeem any debt securities of the Issuer that rank equal with or junior to the Subordinated Notes, or (c) make any payments under any guarantee that ranks equal with or junior to the Subordinated Notes, other than (i) any dividends or distributions in shares of, or options, warrants or rights to subscribe for or purchase shares of, any class of the Issuer’s common stock; (ii) any declaration of a dividend in connection with the implementation of a shareholders’ rights plan, or the issuance of stock under any such plan in the future, or the redemption or repurchase of any such rights pursuant thereto; (iii) as a result of a reclassification of the Issuer’s capital stock or the exchange or conversion of one class or series of the Issuer’s capital stock for another class or series of the Issuer’s capital stock; (iv) the purchase of fractional interests in shares of the Issuer’s capital stock pursuant to the conversion or exchange provisions of such capital stock or the security being converted or exchanged; or (v) purchases of any class of the Issuer’s common stock related to the issuance of common stock or rights under any benefit plans for the Issuer’s directors, officers or employees or any of the Issuer’s dividend reinvestment plans.
Rights Cumulative; Specific Performance Each and all of the various rights, powers and remedies of a Party hereto will be considered to be cumulative with and in addition to any other rights, powers and remedies which such Party may have at Law or in equity in the event of the breach of any of the terms of this Agreement. The exercise or partial exercise of any right, power or remedy will neither constitute the exclusive election thereof nor the waiver of any other right, power or remedy available to such Party. Without limiting the foregoing, the Parties hereto acknowledge and agree irreparable harm may occur for which money damages would not be an adequate remedy in the event that any of the provisions of this Agreement were not performed in accordance with their specific terms or were otherwise breached. It is accordingly agreed that the Parties shall be entitled to injunction to prevent breaches of this Agreement and to enforce specifically the terms and provisions of this Agreement.
No Implied Waiver; Cumulative Remedies No course of dealing and no delay or failure of the Agent or the Banks in exercising any right, power or privilege under this Agreement, the Notes or any other Loan Document will affect any other or future exercise of any such right, power or privilege or exercise of any other right, power or privilege except as and to the extent that the assertion of any such right, power or privilege shall be barred by an applicable statute of limitations; nor shall any single or partial exercise of any such right, power or privilege or any abandonment or discontinuance of steps to enforce such a right, power or privilege preclude any further exercise of such right, power or privilege or of any other right, power or privilege. The rights and remedies of the Agent and the Banks under this Agreement, the Notes or any other Loan Document are cumulative and not exclusive of any rights or remedies which the Banks would otherwise have.
Waiver; Cumulative Remedies No failure to exercise and no delay in exercising, on the part of Purchaser, any right, remedy, power or privilege hereunder shall operate as a waiver thereof; nor shall any single or partial exercise of any right, remedy, power or privilege hereunder preclude any other or further exercise thereof or the exercise of any other right, remedy, power or privilege. The rights, remedies, powers and privileges herein provided are cumulative and not exclusive of any rights, remedies, powers and privileges provided by law.
