Indirect, Special, or Consequential Damages, Including Damages for Delay Sample Clauses

Indirect, Special, or Consequential Damages, Including Damages for Delay. LNVA shall not be liable for indirect, special, or consequential damages, including damages for delay, lost profits, loss or productivity or loss of use. Seller’s sole remedy for delay, including delays caused by LNVA, is to request and receive, if justified under the circumstances, an equitable extension of time for performance.
AutoNDA by SimpleDocs
Indirect, Special, or Consequential Damages, Including Damages for Delay. SJRA shall not be liable for indirect, special, or consequential damages, including damages for delay, lost profits, loss or productivity or loss of use. Supplier’s sole remedy for delay, including delays caused by SJRA, is to request and receive, if justified under the circumstances, an equitable extension of time for performance.

Related to Indirect, Special, or Consequential Damages, Including Damages for Delay

  • Exclusion of Consequential Damages ‌ Notwithstanding anything contained herein to the contrary, neither Party will be liable under this Agreement or under any cause of action relating to the subject matter of this Agreement for any special, indirect, incidental, punitive, exemplary or consequential damages, including loss of profits, loss of use of any property or claims of customers or contractors of the Parties for any such damages.

  • Consequential Damages Waiver NEITHER PARTY SHALL HAVE ANY LIABILITY ARISING OUT OF OR RELATED TO THIS AGREEMENT FOR ANY LOSS OF USE, LOST DATA, LOST PROFITS, FAILURE OF SECURITY MECHANISMS, INTERRUPTION OF BUSINESS, LOSS CAUSED BY THE INTERRUPTION, TERMINATION OR DELAYED OPERATION OF THE INTERNET, THIRD-PARTY TELECOMMUNICATION SERVICES OR THIRD-PARTY SECURITY FEATURES OR SYSTEMS, EXCEPT AS REQUIRED BY LAW. EXCEPT FOR CUSTOMER’S BREACH OF SECTION 1.4 (USE RESTRICTIONS) OR EITHER PARTY’S UNLAWFUL OR WILLFUL MISCONDUCT OR GROSS NEGLIGENCE, NEITHER PARTY SHALL BE LIABLE FOR ANY INDIRECT, SPECIAL, INCIDENTAL, EXEMPLARY, PUNITIVE, RELIANCE, OR CONSEQUENTIAL DAMAGES OF ANY KIND, EVEN IF INFORMED OF THE POSSIBILITY IN ADVANCE, SUFFERED BY ANY PARTY OR ANY PARTY CLAIMING ON BEHALF OF OR THROUGH THE OTHER PARTY, OR ANY OTHER THIRD PARTY RESULTING FROM OR ARISING OUT OF OR RELATED TO THIS AGREEMENT OR THE PERFORMANCE OR BREACH THEREOF.

  • Consequential Damages Neither party to this Agreement shall be liable to the other party for special, indirect or consequential damages under any provision of this Agreement or for any special, indirect or consequential damages arising out of any act or failure to act hereunder.

  • NO LIABILITY FOR CONSEQUENTIAL DAMAGES In no event shall either Party be liable to the other Party for, and no arbitral panel is authorized to award, any punitive, special, indirect or consequential damages of any kind or character resulting from or arising out of this Agreement, including, without limitation, loss of profits or business interruptions, however they may be caused.

  • No Consequential Damages Other than the Liquidated Damages heretofore described and the indemnity obligations set forth in Article 18.1, in no event shall any Party be liable under any provision of this Agreement for any losses, damages, costs or expenses for any special, indirect, incidental, consequential, or punitive damages, including but not limited to loss of profit or revenue, loss of the use of equipment, cost of capital, cost of temporary equipment or services, whether based in whole or in part in contract, in tort, including negligence, strict liability, or any other theory of liability; provided, however, that damages for which a Party may be liable to another Party under separate agreement will not be considered to be special, indirect, incidental, or consequential damages hereunder.

  • Claims for Consequential Damages The Owner retains its right to claim for consequential damages in the event the Design Professional fails to perform under this Contract.

  • Waiver of Consequential Damages, Etc To the fullest extent permitted by applicable law, the Borrower shall not assert, and hereby waives, any claim against any Indemnitee, on any theory of liability, for special, indirect, consequential or punitive damages (as opposed to direct or actual damages) arising out of, in connection with, or as a result of, this Agreement, any other Loan Document or any agreement or instrument contemplated hereby, the transactions contemplated hereby or thereby, any Loan or Letter of Credit or the use of the proceeds thereof. No Indemnitee referred to in subsection (b) above shall be liable for any damages arising from the use by unintended recipients of any information or other materials distributed to such unintended recipients by such Indemnitee through telecommunications, electronic or other information transmission systems in connection with this Agreement or the other Loan Documents or the transactions contemplated hereby or thereby other than for direct or actual damages resulting from the gross negligence or willful misconduct of such Indemnitee as determined by a final and nonappealable judgment of a court of competent jurisdiction.

  • No Special Damages In no event shall either party be liable hereunder (whether in an action in negligence, contract or tort or based on a warranty or otherwise) for any indirect, incidental, special or consequential damages incurred by the other party or any third party, even if the party has been advised of the possibility of such damages.

  • Disclaimer of Consequential Damages Notwithstanding any provision to the contrary, in no event shall any Party be liable to another Party for any incidental, consequential, special, exemplary or indirect damages, lost business profits or lost data arising out of or in any way related to the Contract Documents.

  • Waiver of Consequential Damages To the fullest extent permitted by applicable Law, the Borrower shall not assert, and hereby waives, any claim against any Indemnitee, on any theory of liability, for special, indirect, consequential or punitive damages (as opposed to direct or actual damages) arising out of, in connection with, or as a result of, this Agreement, any other Loan Document, the Related Documents or any agreement or instrument contemplated hereby or thereby, the transactions contemplated hereby or thereby, any Term Loan or the use of the proceeds thereof. No Indemnitee referred to in subsection (b) above shall be liable for any damages arising from the use by unintended recipients of any information or other materials distributed by it through telecommunications, electronic or other information transmission systems in connection with this Agreement or the other Loan Documents, the Related Documents or the transactions contemplated hereby or thereby other than for direct or actual damages resulting from the gross negligence or willful misconduct of such Indemnitee as determined by a final and nonappealable judgment of a court of competent jurisdiction.

Time is Money Join Law Insider Premium to draft better contracts faster.