Extended Tours/Hybrid Schedules The Employer and the Union may agree to implement extended tours or hybrid schedule (mix of extended and normal tours). For clarity, a hybrid schedule may include extended tours on weekends and normal tours during the week. The following will apply:
Employee-Requested Schedule Changes Overtime-eligible employees’ workweeks and work schedules may be changed at the employee’s request and with the Employer’s approval, provided the Employer’s business and customer service needs are met and no overtime expense is incurred.
For Lump Sum Change Order The payment and extension of time (if any) provided by this Change Order constitutes compensation in full to the Contractor and its Subcontractors and Suppliers for all costs and markups directly and indirectly attributable to the Change Order herein, for all delays related thereto and for performance of changes within the time stated.
Pricing Increase Requests Subsequent to the first twelve (12) months of the Contract term and in accordance with the schedule for price adjustments established by OGS, Contractor may request an increase in the pricing contained in the Centralized Contract by submitting an update request based on change in pricing level as contained in Appendix C, Contract Modification Procedure to the OGS Contract Administrator. With any price increase request, in addition to the requirements contained in Appendix C, the Contractor must certify in writing that the price change for the Services is the same as its pricing in its GSA Supply Schedule, and that Contractor documents the request to the satisfaction of the State.
Rate Redetermination for Market Change In the event of delay or interruption, exceeding 90 days, under B8.33, Contracting Officer shall make an appraisal to determine for each species the difference between the appraised unit value of Included Timber immediately prior to the delay or interruption and the appraised unit value of Included Timber immediately after the delay or interruption. The appraisal shall be done after any rate redetermination done pursuant to B3.31, using remaining volumes. Tentative Rates and Flat Rates in effect at the time of delay or interruption or established pursuant to B3.31 will be reduced, if appraised rates declined during the delay or interruption, to become Current Contract Rates. Increases in rates will not be considered. Accordingly, Base Rates shall be adjusted to correspond to the redetermined rates if redetermined rates are less than the original Base Rates, subject to a new Base Rate limitation of the cost of essential reforestation or 25 cents per hundred cubic feet or equivalent, whichever is larger. However, existing Base Indices shall not be changed under this Subsection. Redetermined rates shall be considered established under B3.1 for timber Scaled subsequent to the delay or interruption.
Rate Redetermination for Environmental Modification In the event of a contract modification under B8.33 or partial termination under B8.34, Contracting Officer shall make an appraisal to determine for each species the difference between the appraised unit value of Included Timber remaining immediately prior to the revision and the appraised unit value of Included Timber to be cut under the modification. The appraisal shall consider the estimated cost of any construction work listed in the Schedule of Items that was performed and abandoned. Tentative Rates and Flat Rates in effect at the time of the revision will be adjusted by said differences to become Current Contract Rates. Accordingly, Base Rates shall be adjusted to correspond to the redetermined rates if redetermined rates are less than the original Base Rates, subject to a new Base Rate limitation of the cost of essential reforestation or 25 cents per hundred cubic feet or equivalent, whichever is larger. However, existing Base Indices shall not be changed under this Subsection. Redetermined rates, or differences for rates subject to B3.2, and Required Deposits shall be considered established under B3.1 for timber Scaled subsequent to the contract revision.
Alternate or Supplemental Pricing Documents No response Optional. If when completing Pricing Form 1 & Pricing Form 2 you direct TIPS to view additional, alternate, or supplemental pricing documentation, you may upload that documentation.
NOTICE OF SUPPLEMENTAL ALLOCATION OF FUNDS By the signature below, the City Controller certifies that, upon the request of the Director, the supplemental sum set out below has been allocated for the purposes of the Agreement out of funds appropriated for this purpose by the City Council of the City of Houston. This Supplemental Allocation has been charged to such appropriation. $
What Forms of Distribution Are Available from a Xxxxxxxxx Education Savings Account Distributions may be made as a lump sum of the entire account, or distributions of a portion of the account may be made as requested.
PROCEDURES FOR SUPPLEMENTAL PAYMENT CALCULATIONS All calculations required by this Article VI, including but not limited to: (i) the calculation of the Applicant’s Stipulated Supplemental Payment Amount; (ii) the determination of both the Annual Limit and the Aggregate Limit; (iii) the effect, if any, of the Aggregate Limit upon the actual amount of Supplemental Payments eligible to be paid to the District by the Applicant; and (iv) the carry forward and accumulation of any of the Applicant’s Stipulated Supplemental Payment Amounts unpaid by the Applicant due to the Aggregate Limit in previous years, shall be calculated by the Third Party selected pursuant to Section 4.3.
