Generator Authority. Generator may take whatever actions with regard to the Facility it deems necessary during an Emergency Condition in order to (i) preserve public health and safety;
Generator Authority Sample Clauses
Related to Generator Authority
Developer Authority Consistent with Good Utility Practice and this Agreement, the Developer may take whatever actions or inactions with regard to the Large Generating Facility or the Developer Attachment Facilities during an Emergency State in order to (i) preserve public health and safety, (ii) preserve the reliability of the Large Generating Facility or the Developer Attachment Facilities, (iii) limit or prevent damage, and (iv) expedite restoration of service. Developer shall use Reasonable Efforts to minimize the effect of such actions or inactions on the New York State Transmission System and the Connecting Transmission Owner’s Attachment Facilities. NYISO and Connecting Transmission Owner shall use Reasonable Efforts to assist Developer in such actions.
Arbitrator Authority The arbitrator shall have the sole and exclusive authority to determine whether a dispute, claim or cause of action is subject to arbitration under this Section and to determine any procedural questions which grow out of such disputes, claims or causes of action and bear on their final disposition.
Interconnection Customer Authority Consistent with Good Utility Practice, this LGIA, and the CAISO Tariff, the Interconnection Customer may take actions or inactions with regard to the Large Generating Facility or the Interconnection Customer’s Interconnection Facilities during an Emergency Condition in order to (i) preserve public health and safety, (ii) preserve the reliability of the Large Generating Facility or the Interconnection Customer’s Interconnection Facilities,
PROPER AUTHORITY Each Party represents and warrants that the person executing this Contract on its behalf has full power and authority to enter into this Contract.
Reactive Power and Primary Frequency Response 9.6.1 Power Factor Design Criteria
E1 Authority Data E1.1 For the purposes of clauses E1 and 2, the terms “Data Controller”, “Data Processor”, “Data Subject”, “
Statewide HUB Program Statewide Procurement Division Note: In order for State agencies and institutions of higher education (universities) to be credited for utilizing this business as a HUB, they must award payment under the Certificate/VID Number identified above. Agencies, universities and prime contractors are encouraged to verify the company’s HUB certification prior to issuing a notice of award by accessing the Internet (xxxxx://xxxxx.xxx.xxxxx.xx.xx/tpasscmblsearch/index.jsp) or by contacting the HUB Program at 000-000-0000 or toll-free in Texas at 0-000-000-0000.
Network Authorization For services that cannot be provided by a network provider, you can request a network authorization to seek services from a non-network provider. With an approved network authorization, the network benefit level will apply to the authorized covered healthcare service. If we approve a network authorization for you to receive services from a non- network provider, our reimbursement will be based on the lesser of our allowance, the non-network provider’s charge, or the benefit limit. For more information, please see the How Non-Network Providers Are Paid section.
New Work Authorization If the Engineer does not complete the services authorized in a work authorization before the specified completion date and has not requested a supplemental work authorization, the work authorization shall terminate on the completion date. At the sole discretion of the State, it may issue a new work authorization to the Engineer for the incomplete work using the unexpended balance of the preceding work authorization for the project. If approved by the State, the Engineer may calculate any additional cost for the incomplete work using the rates set forth in the preceding work authorization and in accordance with Attachment E, Fee Schedule.
EMPLOYER AUTHORITY 5.1 The Employer retains the full and unrestricted right to operate and manage all manpower, facilities, and equipment; to establish functions and programs; to set and amend budgets; to determine the utilization of technology; to establish and modify the organizational structure; to select, direct and determine the number of personnel; to establish work schedules; and to perform any inherent managerial function not specifically limited by this Agreement.
