Rental Rates and Wage Rates for Change Orders As soon as is practical, but prior to the completion of the Construction Preparation Period and in any event prior to the commencement of any Work on the Site, the Contractor shall submit in accordance with the style and format of a specimen to be furnished by the Owner for consideration of the Owner the following: (1) a proposal for rental rates on heavy construction equipment that shall apply in the event Change Order Work is performed, and (2) a proposal for wage rates for the types of project labor that shall apply in the event of the execution of any Change Order Work. Under penalty of false swearing, a principal of the contracting firm shall certify that the proposal for rental rates and proposal for wage rates do not exceed current costs for like services. The Owner will in no event consider a rental rate in excess of eighty percent of the rate set forth in the latest edition of the "Compilation of Nationally Averaged Rental Rates for Construction Equipment" of the Associated Equipment Distributors unless the rates proposed in excess of eighty percent are supported by proof satisfactory to the Owner that the excess rates are reasonable. If the equipment is owned by the Contractor the costs shall be charged at a maximum of eighty percent of market monthly rental rates for the amount of time used. If applicable, transportation costs may be included. The decision of the Owner shall be final, binding and conclusive on all parties. Rental rates shall be payable only for the actual time the equipment is required on the Site.
Additional Quantities For a period not exceeding ninety (90) days from the date of solicitation award, the Customer reserves the right to acquire additional quantities up to the amount shown on the solicitation but not to exceed the threshold for Category Two at the prices submitted in the response to the solicitation.
Increment Dates 1. The increment date shall be the first of the month following the month in which applicable experience accumulation is achieved.
Minimum Shipping Requirements for TIPS Sales Vendor shall ship, deliver, or provide ordered goods and services within a commercially reasonable time after acceptance of the order. If a delay in delivery is anticipated, Vendor shall notify the TIPS Member as to why delivery is delayed and provide an updated estimated time for completion. The TIPS Member may cancel the order if the delay is not commercially acceptable or not consistent with the Supplemental Agreement applicable to the order.
Delivery Dates If the due date of any notice, certificate or report required to be delivered by the Manager hereunder falls on a day that is not a Business Day, the due date for such notice, certificate or report shall be automatically extended to the next succeeding day that is a Business Day.
Hearing Dates and Date of Award Except for the Expedited Arbitration procedure described above, hearing dates shall be scheduled within thirty (30) working days of selection of an arbitrator or on the next practicable date mutually agreeable to the parties. Awards shall be due forty-five (45) calendar days following the receipt of closing arguments. As a condition of appointment to the permanent panel, arbitrators shall be advised of this requirement and shall certify their willingness to abide by these time limits.
Completion Dates The Recipient agrees to complete each Project within the time periods specified in the Underlying Agreement and all activities must be completed by the Award’s end date, unless FTA agrees in writing to extend the end date. Unless FTA determines otherwise in writing, interim milestone dates and other completion dates applicable to the Award are good faith estimates and are not intended to be firm contractual requirements. However, FTA and the Recipient agree that milestone dates and other completion dates for Full Funding Grant Agreements, Small Starts Grant Agreements or other specific agreements in which FTA expressly states that the milestone dates or other completion dates for the Underlying Agreement are firm dates that may be enforced.
Service Dates Invoice shall include the beginning and ending date of the work accomplished for the invoice.
Minimum Site Requirements for TIPS Sales (when applicable to TIPS Sale). Cleanup: When performing work on site at a TIPS Member’s property, Vendor shall clean up and remove all debris and rubbish resulting from their work as required or directed by the TIPS Member or as agreed by the parties. Upon completion of work, the premises shall be left in good repair and an orderly, neat, clean and unobstructed condition. Preparation: Vendor shall not begin a project for which a TIPS Member has not prepared the site, unless Vendor does the preparation work at no cost, or until TIPS Member includes the cost of site preparation in the TIPS Sale Site preparation includes, but is not limited to: moving furniture, installing wiring for networks or power, and similar pre‐installation requirements. Registered Sex Offender Restrictions: For work to be performed at schools, Vendor agrees that no employee of Vendor or a subcontractor who has been adjudicated to be a registered sex offender will perform work at any time when students are, or reasonably expected to be, present unless otherwise agreed by the TIPS Member. Vendor agrees that a violation of this condition shall be considered a material breach and may result in the cancellation of the TIPS Sale at the TIPS Member’s discretion. Vendor must identify any additional costs associated with compliance of this term. If no costs are specified, compliance with this term will be provided at no additional charge. Safety Measures: Vendor shall take all reasonable precautions for the safety of employees on the worksite, and shall erect and properly maintain all necessary safeguards for protection of workers and the public. Vendor shall post warning signs against all hazards created by the operation and work in progress. Proper precautions shall be taken pursuant to state law and standard practices to protect workers, general public and existing structures from injury or damage. Smoking: Persons working under Agreement shall adhere to the TIPS Member’s or local smoking statutes, codes, ordinances, and policies.
Funding Restrictions and Order Quantities The Agency reserves the right to reduce or increase estimated or actual quantities in whatever amount necessary without prejudice or liability to the Agency, if:
