Emergency Contractual Unit Count Based upon Force Majeure Sample Clauses

Emergency Contractual Unit Count Based upon Force Majeure. In the event of a Force Majeure Event (which shall be defined as war, strike, riot, crime, or act of God (e.g., hurricane, tropical depression or storm, tornado, flooding, earthquake, volcano, etc.)) which renders the Contractor unable to perform the contracted services to the Contractual Units under the regular schedule contemplated by this Contract, Contractor and the City shall, in no less than thirty (30) days but no greater than ninety (90) days of the occurrence of the Force Majeure Event, conduct an Emergency Contractual Unit Count. A Contractual Unit for the purpose of the Force Majeure Event shall be defined as a dwelling or dwellings, either temporary or permanent in nature, within the service area occupied by a person or group of persons. In instances where a permanent dwelling is being repaired and a temporary dwelling or dwellings are being used for housing during the course of the repair, the Contractual Unit shall remain at one (1) per residential lot without regard to the electrical services being provided. Contractual Units habitable prior to the occurrence of the Force Majeure Event, but rendered uninhabitable by the Force Majeure Event with no temporary dwelling placed on the property shall be removed from the Contractual Unit Count. Contractual Units that prior to the Force Majeure Event constituted one (1) unit and after the Force Majeure Event have more than one (1) familial unit using temporary housing on the property will be counted based upon the number of familial unit(s) inhabiting the property temporarily. Emergency Contractual Unit Counts will be conducted by the Contractor and the City every one hundred eighty (180) days for a period of up to two (2) years from the date of the occurrence of the Force Majeure Event. If the final Emergency Contractual Unit Count is completed between October and April, that count shall apply thru the end of the Contract year and the Contractual Unit count provided for in Section 12.02(b) shall be conducted to determine the applicable Contractual Unit count for the next Contract year. If the final Emergency Contractual Unit Count is completed between April and October, then the Contractual Unit count for the next Contract year shall be the final Emergency Contractual Unit Count. In no event shall Contractor be liable for liquidated damages as provided in this Contract for delays due to any Force Majeure Event.
View Source

Related to Emergency Contractual Unit Count Based upon Force Majeure

  • Interconnection Customer Compensation for Actions During Emergency Condition The CAISO shall compensate the Interconnection Customer in accordance with the CAISO Tariff for its provision of real and reactive power and other Emergency Condition services that the Interconnection Customer provides to support the CAISO Controlled Grid during an Emergency Condition in accordance with Article 11.6.

  • CONDITIONS FOR EMERGENCY/HURRICANE OR DISASTER - TERM CONTRACTS It is hereby made a part of this Invitation for Bids that before, during and after a public emergency, disaster, hurricane, flood, or other acts of God that Orange County shall require a “first priority” basis for goods and services. It is vital and imperative that the majority of citizens are protected from any emergency situation which threatens public health and safety, as determined by the County. Contractor agrees to rent/sell/lease all goods and services to the County or other governmental entities as opposed to a private citizen, on a first priority basis. The County expects to pay contractual prices for all goods or services required during an emergency situation. Contractor shall furnish a twenty-four (24) hour phone number in the event of such an emergency.

  • Available Relief for a Force Majeure Event 11.7.1 Subject to this Article 11: (a) no Party shall be in breach of its obligations pursuant to this Agreement except to the extent that the performance of its obligations was prevented, hindered or delayed due to a Force Majeure Event; (b) every Party shall be entitled to claim relief in relation to a Force Majeure Event in regard to its obligations, including but not limited to those specified under Article 4.5; (c) For avoidance of doubt, neither Party’s obligation to make payments of money due and payable prior to occurrence of Force Majeure events under this Agreement shall be suspended or excused due to the occurrence of a Force Majeure Event in respect of such Party. (d) Provided that no payments shall be made by either Party affected by a Force Majeure Event for the period of such event on account of its inability to perform its obligations due to such Force Majeure Event.

  • Force Majeure Events a) Neither Party shall be responsible or liable for or deemed in breach hereof because of any delay or failure in the performance of its obligations hereunder (except for obligations to pay money due prior to occurrence of Force Majeure events under this Agreement) or failure to meet milestone dates due to any event or circumstance (a "Force Majeure Event") beyond the reasonable control of the Party experiencing such delay or failure, including the occurrence of any of the following: i) acts of God; ii) typhoons, floods, lightning, cyclone, hurricane, drought, famine, epidemic, plague or other natural calamities; iii) acts of war (whether declared or undeclared), invasion or civil unrest; iv) any requirement, action or omission to act pursuant to any judgment or order of any court or judicial authority in India (provided such requirement, action or omission to act is not due to the breach by the SPG or of any Law or any of their respective obligations under this Agreement); v) inability despite complying with all legal requirements to obtain, renew or maintain required licenses or Legal Approvals; vi) earthquakes, explosions, accidents, landslides; fire; vii) expropriation and/or compulsory acquisition of the Project in whole or in part by Government Instrumentality; viii) chemical or radioactive contamination or ionizing radiation; or ix) damage to or breakdown of transmission facilities of GETCO/ DISCOMs; x) Exceptionally adverse weather condition which are in excess of the statistical measure of the last hundred (100) years.

  • Termination Payment for Force Majeure Event 30.9.1 If Termination is on account of a Non-Political Event, the Authority shall make a Termination Payment to the Concessionaire in an amount equal to 55% (fifty five per cent) of the Debt Due less Insurance Cover. 30.9.2 If Termination is on account of an Indirect Political Event, the Authority shall make a Termination Payment to the Concessionaire in an amount equal to: (a) 55% of the Debt Due less Insurance Cover; provided that if any insurance claims forming part of the Insurance Cover are not admitted and paid, then 80% (eighty per cent) of such unpaid claims shall be included in the computation of Debt Due; (b) 60.5% (sixty point five per cent) of the Adjusted Equity; and 30.9.3 If Termination is on account of a Political Event, the Authority shall make a Termination Payment to the Concessionaire in an amount that would be payable under Clause 33.3.2 as if it were Authority’s Default.