CPM Schedule Submission Sample Clauses

CPM Schedule Submission. On or prior to execution of this Agreement, Contractor shall prepare and submit to Owner for its review and written approval a detailed critical path method schedule for the Project (“CPM Schedule”). Owner may issue written comments, proposed changes and/or written approval or disapproval of such CPM Schedule. The CPM Schedule shall, at a minimum, (i) include separate activities for each portion of the Project, (ii) be fully integrated and shall be consistent with the Project Schedule, and (iii) show an uninterrupted critical path from the NTP through Substantial Completion and Final Completion of the Project. With respect to each activity in the CPM Schedule, the CPM Schedule shall show the activity number, activity description, early start and early finish dates, late start and late finish dates, duration, total float value, and responsible Contractor, Subcontractor or other parties. The CPM Schedule shall represent Contractor’s best judgment as to how it shall complete the Work in compliance with the Project Schedule, including the Required Mechanical Completion Date, Required Substantial Completion Date, and the Required Final Completion Date. The CPM Schedule shall be submitted in hard copy and also in its native electronic format, provided on a computer diskette. Once the CPM Schedule and the required submittals have been reviewed and approved by Owner, such version of the CPM Schedule shall be the baseline CPM Schedule for the Work.
Sample 1Sample 2
AutoNDA by SimpleDocs
CPM Schedule Submission. Within sixty (60) Days after issuance of the GTG LNTP, Contractor shall prepare and submit to Owner for its review a preliminary critical path method schedule for the Work using Oracle Primavera P6 and showing evidence of the preliminary incorporation of the Siemens engineering deliverable dates within Contractor’s schedule for engineering and construction. Thereafter, Contractor shall submit a detailed critical path method schedule for the Work, for Owner’s review and written approval, no later than one hundred twenty (120) Days after issuance of GTG LNTP which meets the requirements set forth in Attachment U. This detailed critical path method schedule (as well as, for the avoidance of doubt, any CPM Performance Measurement Baseline Schedule and Monthly Updated CPM Schedule) shall adhere to the guidelines set forth in this Section 5.4, including Attachment U.
Sample 1Sample 2
CPM Schedule Submission. Within forty-five (45) Days after the Effective Date, Contractor shall prepare and submit to Owner for its review and written approval a detailed resource/man-hour loaded critical path method schedule for the Project using Primavera Project Planner (P6) version 8.2 or later (“CPM Schedule”). Owner may issue written comments, proposed changes or written approval or disapproval of such CPM Schedule. The CPM Schedule shall, at a minimum, (i) include separate activities for each portion of the Project (including engineering, procurement and construction, along with non-physical activities related to the Work, such as submittal and approval of Drawings and Specifications, procurement of Equipment and inspection and testing of the Work, and obtaining Permits), (ii) be fully integrated and shall be consistent with the Milestone Dates, (iii) be detailed at a level 3 (with each activity containing Work for one discipline or craft having a maximum twenty (20) Day duration) for all activities for the Project, (iv) fully incorporate all Major Subcontractor schedules for the performance of their work (including off-site Subcontractors, suppliers and fabricators), (v) show the duration, early/late start dates, early/late finish dates and available float for each activity, activity number, activity description and responsible Contractor or Subcontractor, and an uninterrupted critical path from the NTP through each Milestone Date, including Mechanical Completion, Substantial Completion and Final Completion of the Project, (vi) be cost-loaded to reflect Contractor’s expected payments during the progress of the Work; and (vii) be man-hour loaded to reflect the projected manpower to be used per activity (whether provided by Contractor or any Subcontractor or Sub-subcontractor), showing the number of personnel, the positions and titles of such personnel, and a general description of the Work being performed. With respect to each activity in the CPM Schedule, the CPM Schedule shall show the activity number, activity description, early start and early finish dates, late start and late finish dates, duration, total float value, and responsible Contractor, Subcontractor or other parties (including Owner and Owner’s other contractors). The CPM Schedule shall represent Contractor’s best judgment as to how it shall complete the Work in compliance with the Milestone Dates, including the Guaranteed Substantial Completion Date and the Guaranteed Final Completion Date. The CPM Schedule ...
Sample 1
CPM Schedule Submission. On or prior to the Start Date, Contractor shall prepare and submit to Owner for its review and written approval a detailed critical path method schedule for the Project using Microsoft Project ("CPM Schedule"). Owner may issue written comments, proposed changes and/or written approval or disapproval of such CPM Schedule. The CPM Schedule shall, at a minimum, (i) include separate activities for each portion of the Project (including engineering, procurement and construction, along with non-physical activities related to the Work), (ii) be fully integrated and shall be consistent with the Project Schedule, and (iii) show an uninterrupted critical path from the notice to proceed through Commercial Operation, Substantial Completion and Final Completion. With respect to each activity in the CPM Schedule, the CPM Schedule shall show the activity number, activity description, early start and early finish dates, late start and late finish dates, duration, total float value, and responsible Contractor, Subcontractor or other parties (including Owner). The CPM Schedule shall represent Contractor's best judgment as to how it shall complete the Work in compliance with the Project Schedule, including the Guaranteed Commercial Operation Date, Guaranteed Substantial Completion Date and Guaranteed Final Completion Date. The CPM Schedule shall be submitted in hard copy and also in its native electronic format, provided on a computer diskette. Once the CPM Schedule and the required submittals have been reviewed and approved by Owner, this version of the CPM Schedule shall be the baseline CPM Schedule for the Work.
Sample 1

Related to CPM Schedule Submission

  • Claims Submission We will submit your claims and assist you in any way we reasonably can to help get your claims paid. Your insurance company may need you to supply certain information directly. It is your responsibility to comply with their request. Please be aware that the balance of your claim is your responsibility whether or not your insurance company pays your claim. Your insurance benefit is a contract between you and your insurance company; we are not party to that contract.

  • Updated Information Submission by Developer The updated information submission by the Developer, including manufacturer information, shall occur no later than one hundred eighty (180) Calendar Days prior to the Trial Operation. Developer shall submit a completed copy of the Large Generating Facility data requirements contained in Appendix 1 to the Large Facility Interconnection Procedures. It shall also include any additional information provided to Connecting Transmission Owner for the Interconnection Feasibility Study and Interconnection Facilities Study. Information in this submission shall be the most current Large Generating Facility design or expected performance data. Information submitted for stability models shall be compatible with NYISO standard models. If there is no compatible model, the Developer will work with a consultant mutually agreed to by the Parties to develop and supply a standard model and associated information. If the Developer’s data is different from what was originally provided to Connecting Transmission Owner and NYISO pursuant to an Interconnection Study Agreement among Connecting Transmission Owner, NYISO and Developer and this difference may be reasonably expected to affect the other Parties’ facilities or the New York State Transmission System, but does not require the submission of a new Interconnection Request, then NYISO will conduct appropriate studies to determine the impact on the New York State Transmission System based on the actual data submitted pursuant to this Article 24.3. Such studies will provide an estimate of any additional modifications to the New York State Transmission System, Connecting Transmission Owner’s Attachment Facilities, or System Upgrade Facilities or System Deliverability Upgrades based on the actual data and a good faith estimate of the costs thereof. The Developer shall not begin Trial Operation until such studies are completed. The Developer shall be responsible for the cost of any modifications required by the actual data, including the cost of any required studies.

  • Invoice Submission The Contractor shall accept payment of invoices via EFT. Invoice submission information shall be contained in each individual Order. Payment of invoices will be made by the payment office designated in each individual Order.

  • Updated Information Submission by Interconnection Customer The updated information submission by the Interconnection Customer, including manufacturer information, shall occur no later than one hundred eighty (180) Calendar Days prior to the Trial Operation. The Interconnection Customer shall submit a completed copy of the Electric Generating Unit data requirements contained in Appendix 1 to the LGIP. It shall also include any additional information provided to the Participating TO and the CAISO for the Interconnection Studies. Information in this submission shall be the most current Electric Generating Unit design or expected performance data. Information submitted for stability models shall be compatible with the Participating TO and CAISO standard models. If there is no compatible model, the Interconnection Customer will work with a consultant mutually agreed to by the Parties to develop and supply a standard model and associated information. If the Interconnection Customer's data is materially different from what was originally provided to the Participating TO and the CAISO for the Interconnection Studies, then the Participating TO and the CAISO will conduct appropriate studies pursuant to the LGIP to determine the impact on the Participating TO’s Transmission System and affected portions of the CAISO Controlled Grid based on the actual data submitted pursuant to this Article 24.3. The Interconnection Customer shall not begin Trial Operation until such studies are completed and all other requirements of this LGIA are satisfied.

  • REPORT SUBMISSION 1. Copies of reporting packages for audits conducted in accordance with 2 CFR Part 200, Subpart F-Audit Requirements, and required by PART I of this form shall be submitted, when required by 2 CFR 200.512, by or on behalf of the recipient directly to the Federal Audit Clearinghouse (FAC) as provided in 2 CFR 200.36 and 200.512

  • Submission of Grievance Information a) Upon appointment of the arbitrator, the appealing party shall within five days after notice of appointment forward to the arbitrator, with a copy to the School Board, the submission of the grievance which shall include the following:

  • Application Submission Submissions of a rental application does not guarantee approval or acceptance. It does not bind us to accept the application or to sign a Lease contact. APPLICANT SCREENING CRITERIA Fair Housing Statement. Xxxxx Management is an equal housing opportunity & fair housing provider. We do not discriminate against persons on the basis of race, color, religion, national origin, sex, familial status, disability, creed, marital status, public assistance, ancestry, and sexual or affectional orientation. Identification and Application Process. Every person over 18 must give consent to be screened and provide a government issued photo ID. Social Security Number verification may be required for specific housing programs. Application Requirements. Applications must be filled out completely and accurately. Any misstatements or omissions made on your application, whether or not discovered before you move into the building, is grounds for denial of an application or termination of an existing lease. Information must be legible and verifiable. If information given on the application cannot be verified, this is a reason for rejection. Omission of information, such as an address or employer, may be grounds for rejection. Occupancy. The initial maximum number of residents in a unit is equal to two persons per bedroom unless otherwise stated in the property’s Resident Selection Plan, where applicable. Each unit is limited to no more than two (2) unrelated or four (4) related adult persons per unit. Xxxxx Management defines a related adult person as either a child, dependent, or parent of the head of household. General occupancy standards and any federal, state, or local housing ordinances will supersede this policy. Housing History. We require the name and last known telephone number of each landlord/property manager for each address you have had for the last three years. Roommate references are not acceptable. The refusal of a prior landlord to give a reference, or a negative reference, may be grounds for rejection. In the case of first-time renters, or applicants without prior rental history, this requirement may be varied subject to additional requirements of management. Eviction Filings. Unlawful detainers or evictions within the past five (5) years is a basis for denial of an application.

  • SUBMISSION OF REPORTS All applicable study reports shall be submitted in preliminary form for approval by the State before a final report is issued. The State's comments on the Engineer's preliminary report must be addressed in the final report.

  • NOTIFICATIONS AND SUBMISSION OF REPORTS Unless otherwise stated in writing after the Effective Date, all notifications and reports required under this CIA shall be submitted to the following entities: OIG: Administrative and Civil Remedies Branch Office of Counsel to the Inspector General Office of Inspector General U.S. Department of Health and Human Services Xxxxx Building, Room 5527 000 Xxxxxxxxxxxx Xxxxxx, X.X. Washington, DC 20201 Telephone: 000.000.0000 Facsimile: 202.205.0604 GSK: Xxxxxxx X. Xxxx Vice President & Compliance Officer North America Pharmaceuticals GlaxoSmithKline Three Franklin Plaza 000 X. 00xx Xxxxxx Xxxxxxxxxxxx, XX 00000 Telephone: 000.000.0000 Facsimile: 215.751.7547 Unless otherwise specified, all notifications and reports required by this CIA may be made by certified mail, overnight mail, hand delivery, or other means, provided that there is proof that such notification was received. For purposes of this requirement, internal facsimile confirmation sheets do not constitute proof of receipt. Upon request by OIG, GSK may be required to provide OIG with an electronic copy of each notification or report required by this CIA in searchable portable document format (pdf), either instead of or in addition to, a paper copy.

  • BID SUBMISSION All Bids are to be packaged, sealed and submitted to the location stated in the Bid Specifications. Bidders are solely responsible for timely delivery of their Bids to the location set forth in the Bid Specifications prior to the stated Bid opening date/time. A Bid return envelope, if provided with the Bid Specifications, should be used with the Bid sealed inside. If the Bid response does not fit into the envelope, the Bid envelope should be attached to the outside of the sealed box or package with the Bid inside. If using a commercial delivery company that requires use of their shipping package or envelope, Bidder’s sealed Bid, labeled as detailed below, should be placed within the shipper’s sealed envelope to ensure that the Bid is not prematurely opened. All Bids must have a label on the outside of the package or shipping container outlining the following information: “BID ENCLOSED (bold print, all capitals) • Group Number • IFB or RFP Number • Bid Submission date and time” In the event that a Bidder fails to provide such information on the return Bid envelope or shipping material, the receiving entity reserves the right to open the shipping package or envelope to determine the proper Bid number or Product group, and the date and time of Bid opening. Bidder shall have no claim against the receiving entity arising from such opening and such opening shall not affect the validity of the Bid or the procurement. Notwithstanding the receiving agency’s right to open a Bid to ascertain the foregoing information, Bidder assumes all risk of late delivery associated with the Bid not being identified, packaged or labeled in accordance with the foregoing requirements. All Bids must be signed by a person authorized to commit the Bidder to the terms of the Bid Documents and the content of the Bid (offer).

Time is Money Join Law Insider Premium to draft better contracts faster.