Construction Plans Tenant shall prepare final plans and specifications for the Tenant Improvements that (a) are consistent with and are logical evolutions of the Approved Schematic Plans and (b) incorporate any other Tenant-requested (and Landlord-approved) Changes (as defined below). As soon as such final plans and specifications ("Construction Plans") are completed, Tenant shall deliver the same to Landlord for Landlord's approval, which approval shall not be unreasonably withheld, conditioned or delayed. All such Construction Plans shall be submitted by Tenant to Landlord in electronic .pdf, CADD and full-size hard copy formats, and shall be approved or disapproved by Landlord within ten (10) business days after delivery to Landlord. Landlord's failure to respond within such ten (10) business day period shall be deemed approval by Landlord. If the Construction Plans are disapproved by Landlord, then Landlord shall notify Tenant in writing of its objections to such Construction Plans, and the parties shall confer and negotiate in good faith to reach agreement on the Construction Plans. Promptly after the Construction Plans are approved by Landlord and Tenant, two (2) copies of such Construction Plans shall be initialed and dated by Landlord and Tenant, and Tenant shall promptly submit such Construction Plans to all appropriate Governmental Authorities for approval. The Construction Plans so approved, and all change orders approved (to the extent required) by Landlord, are referred to herein as the "Approved Plans."
Complete Agreement; Construction This Agreement, including the Schedules hereto, shall constitute the entire agreement between the Parties with respect to the subject matter hereof and shall supersede all previous negotiations, commitments and writings with respect to such subject matter. In the event of any inconsistency between this Agreement and any Schedule, the Schedule shall prevail. The rights and remedies of the Parties herein provided shall be cumulative and in addition to any other or further remedies provided by law or equity.
Construction Contracts Lessee has entered into contracts with the Contractors or separate contracts with materialmen and laborers providing for the construction of the Improvements. Lessee will cause the Contractors to promptly furnish Lessor with the complete list of all Sub-contractors or entities as and when under contract, which Contractors propose to engage to furnish labor and/or materials in constructing the Improvements (such list containing the names, addresses, and amounts of such sub-contracts as written in excess individually of $5,000, and prior to disbursement of funds to or for the benefit of such Subcontractors, affidavits of authorized signatory and other documents commercially reasonably required by Title to insure that the Leased Premises remain lien free) and will from time to time furnish Lessor or Title with true copies of all Contracts entered into by Lessee and with the terms of all verbal agreements therefor, if any, and as to subcontractors, letters signed by sub-contractors whose contracts are in excess of $5,000 setting forth the present amount of their contract and the amounts remaining to be paid under that contract, if the same information is not stated on a lien waiver reflecting the most currently requested payment to such subcontractor.
Construction of Agreement The parties mutually acknowledge that they and their attorneys have participated in the preparation and negotiation of this Agreement. In cases of uncertainty this Agreement shall be construed without regard to which of the parties caused the uncertainty to exist.
Construction of Improvements (A) Lessee warrants and agrees that the Building will be constructed on the Leased Premises, and all other improvements to the land, including the parking lot, approaches, and service areas, will be constructed in all material respects by Lessee substantially in accordance with the plot, plans, and specifications heretofore submitted to Lessor.
Software Modifications Company may request that BNYM, at Company’s expense, develop modifications to the software constituting a part of the Licensed System that BNYM generally makes available to customers for modification (“Software”) that are required to adapt the Software for Company’s unique business requirements. Such requests, containing the material features and functionalities of all such modifications in reasonable detail, will be submitted by Company in writing to BNYM in accordance with the applicable, commercially reasonable procedures maintained by BNYM at the time of the request. Company shall be solely responsible for preparing, reviewing and verifying the accuracy and completeness of the business specifications and requirements relied upon by BNYM to estimate, design and develop such modifications to the Software. BNYM shall have no obligation to develop modifications to the Licensed System requested by Company, but may in its discretion agree to develop requested modifications which it, in its sole discretion, reasonably determines it can accomplish with existing resources or with readily obtainable resources without disruption of normal business operations provided Company agrees at such time in writing to pay all costs and expenses, including out-of-pocket expenses, associated with the customized modification. BNYM shall be obligated to develop modifications under this Section 2.16 only upon the execution of and in accordance with a writing containing, to BNYM’s reasonable satisfaction, all necessary business and technical terms, specifications and requirements for the modification as determined by BNYM in its sole judgment (“Customization Order”) and Company’s agreement to pay all costs and expenses, including out-of-pocket expenses, associated with the customized modification (“Customization Fee Agreement”). All modifications developed and incorporated into the Licensed System pursuant to a Customization Order are referred to herein as “Company Modifications”. BNYM may make Company Modifications available to all users of the Licensed System, including BNYM, at any time after implementation of the particular Company Modification and any entitlement of Company to reimbursement on account of such action must be contained in the Customization Fee Agreement.
Construction of the Tenant Improvements Landlord shall construct the Tenant Improvements in accordance with this exhibit and the construction contract to be executed by Landlord and its contractor(s). The construction contract for constructing the Tenant Improvements and the contractor(s) to perform the work shall be approved and/or selected, as the case may be, by Landlord at its sole and absolute discretion without the consent of Tenant.
Construction of Tenant Improvements Promptly following approval of the Final TI Working Drawings, Landlord shall apply for and use reasonable efforts to obtain the necessary permits and approvals to allow construction of Landlord’s TI Work. Upon receipt of such permits and approvals, Landlord shall, at Tenant’s expense (subject to the application of the Tenant Improvement Allowance provided in this Workletter, and subject to any other applicable provisions of the Lease or of this Workletter expressly making any specific item of expense or cost the responsibility of Landlord), diligently construct and complete Landlord’s TI Work substantially in accordance with the Approved TI Plans, subject to Unavoidable Delays and Tenant Delays (if any). Such construction shall be performed in a good and workmanlike manner and shall conform to all applicable governmental codes, laws and regulations in force at the time such work is completed. Without limiting the generality of the foregoing, Landlord shall be responsible for compliance of Landlord’s TI Work with the requirements of the Americans with Disabilities Act and all similar or related requirements pertaining to access by persons with disabilities, but nothing in this sentence shall be construed to make Landlord responsible for bearing the cost of any such compliance, to the extent the compliance work is reasonably attributable to or related to the particular nature or design of the Tenant Improvements or is for any other reason expressly made Tenant’s cost or responsibility under any applicable provision of the Lease or of this Workletter. Landlord shall have the right, in its sole discretion, to decide whether and to what extent to use union labor on or in connection with Landlord’s Work, and shall use the TI General Contractor to construct all of Landlord’s TI Work. Landlord and Tenant shall each have a right to approve all subcontractors engaged in connection with the construction of the Tenant Improvements and to review and approve all competitive bids for any elements of the Tenant Improvements, such approval in each instance not to be unreasonably withheld, conditioned or delayed by either party.
Assumption and Modification Agreements When a Mortgaged Property has been or is about to be conveyed by the Mortgagor, the Servicer shall, to the extent it has knowledge of such conveyance or prospective conveyance, exercise its rights to accelerate the maturity of the related Mortgage Loan under any “due-on-sale” clause contained in the related Mortgage or Mortgage Note; provided, however, that the Servicer shall not exercise any such right if (i) the “due-on-sale” clause, in the reasonable belief of the Servicer, is not enforceable under applicable law or (ii) the Servicer reasonably believes that to permit an assumption of the Mortgage Loan would not materially and adversely affect the interest of the Noteholders. In such event, the Servicer shall enter into an assumption and modification agreement with the Person to whom such property has been or is about to be conveyed, pursuant to which such Person becomes liable under the Mortgage Note and, unless prohibited by applicable law or the mortgage documents, the Mortgagor remains liable thereon. If the foregoing is not permitted under applicable law, the Servicer is authorized to enter into a substitution of liability agreement with such Person, pursuant to which the original Mortgagor is released from liability and such Person is substituted as Mortgagor and becomes liable under the Mortgage Note. The Mortgage Loan, if assumed, shall conform in all respects to the requirements and representations and warranties of this Agreement. The Servicer shall notify the Indenture Trustee that any applicable assumption or substitution agreement has been completed by forwarding to the Indenture Trustee the original copy of such assumption or substitution agreement, which copy shall be added by the Indenture Trustee to the related Indenture Trustee’s Mortgage File and which shall, for all purposes, be considered a part of such Indenture Trustee’s Mortgage File to the same extent as all other documents and instruments constituting a part thereof. The Servicer shall be responsible for promptly recording any such assumption or substitution agreements. In connection with any such assumption or substitution agreement, the required monthly payment on the related Mortgage Loan shall not be changed but shall remain as in effect immediately prior to the assumption or substitution, the stated maturity or outstanding Principal Balance of such Mortgage Loan shall not be changed, the Mortgage Interest Rate shall not be changed nor shall any required monthly payments of principal or interest be deferred or forgiven. Any fee collected by the Servicer for consenting to any such conveyance or entering into an assumption or substitution agreement shall be retained by or paid to the Servicer as additional servicing compensation. Notwithstanding the foregoing paragraph or any other provision of this Agreement, the Servicer shall not be deemed to be in default, breach or any other violation of its obligations hereunder by reason of any assumption of a Mortgage Loan by operation of law or any assumption which the Servicer may be restricted by law from preventing, for any reason whatsoever.
Construction of Project Purchaser shall (i) perform the Final Assembly Work which is set forth in Exhibit P hereto, (ii) perform all civil works (including roads, grading, maintenance facilities, meteorological towers and other items); (iii) perform all electrical works (including collection lines, Electrical Infrastructure, Transmission Facilities, Interconnection Facilities and other items); (iv) provide and install a remote terminal unit and cabling to the Substation, meteorological towers, and communications lines for the SCADA System to the Substation; and (v) provide any other items required for the operation of the Project; and
