Computer System Compatibility Sample Clauses

The Computer System Compatibility clause defines the requirement that any software, hardware, or digital services provided under the agreement must function properly with the existing computer systems of the receiving party. This clause typically specifies the technical standards, operating systems, or versions that the deliverables must support, and may require the provider to ensure compatibility through testing or documentation. Its core practical function is to prevent issues arising from incompatibility, thereby ensuring that the delivered products or services can be effectively integrated and used without additional costs or delays.
Computer System Compatibility. The Contractor shall maintain records and data in an electronic 828 format compatible with the versions of Microsoft Word and Excel currently in use by the County 829 as of the date of execution of this Agreement. The Contractor will, at its cost and expense, if 830 requested by the County Contract Manager, provide any reports or data required by this 831 Agreement via email, on computer disc, or through other electronic format. Raw or printed data 832 may not be submitted as a substitute to the Contractor's obligation to provide various reports 833 under this Agreement.
View SourceView Similar (6)
Computer System Compatibility. The Contractor shall maintain records and data in an electronic 2195 format compatible with the versions of Microsoft Word and Excel currently in use by the County at 2196 any given time during the Term of this Agreement. The Contractor will, at its cost and expense, if 2197 requested by the County Contract Manager, provide any reports or data required by this Agreement 2198 via email, on computer media device, through a shared database such as a cloud-based software 2199 platform, or through another electronic format specified by the County. Raw or printed data may 2200 not be submitted as a substitute to the Contractor's obligation to provide various reports under this 2201 Agreement. Failure to abide by these shall be an Event of Default and result in assessment of 2202 Liquidated Damages pursuant to Article 14. 2203 Section 9.2: Operation and Maintenance of the Operating Assets 2204 The Contractor, at its cost and expense, shall at all times: 1) operate the Operating Assets properly and in 2205 a safe, sound, and economical manner; 2) maintain, preserve, and keep the Operating Assets in good 2206 repair, working order, and condition; 3) staff the Operating Assets with the appropriate number of 2207 licensed employees consistent with good management practice; and, 4) make all necessary and proper 2208 repairs, replacements, and renewals, so that at all times the operation of the Operating Assets may be 2209 properly and advantageously conducted. The Contractor shall maintain the safety of the Operating Assets 2210 at a level consistent with Applicable Law, the Insurance Requirements, and prudent Solid Waste 2211 management practices. 2212 The County shall have no obligation to Contractor related to the remaining value of any Operating Assets 2213 at the expiration or earlier termination of this Agreement.
View Source

Related to Computer System Compatibility

  • Computer Systems (a) Servicer to operate systems (b) Servicer to maintain back-up facilities (c) Servicer to notify location of computer tapes

  • Computer Software The Grantee certifies that it has appropriate systems and controls in place to ensure that state funds will not be used in the performance of this Grant Agreement for the acquisition, operation, or maintenance of computer software in violation of copyright laws.

  • Year 2000 Compatibility Take all actions necessary to assure the Borrower's computer based systems are able to operate and effectively process data on and after January 1, 2000. At the request of the Lender, the Borrower shall provide the Lender with assurance acceptable to the Lender that Borrower's computer systems have Year 2000 compatibility.

  • Compatibility 1. Any unresolved issue arising from a mutual agreement procedure case otherwise within the scope of the arbitration process provided for in this Article and Articles 25A to 25G shall not be submitted to arbitration if the issue falls within the scope of a case with respect to which an arbitration panel or similar body has previously been set up in accordance with a bilateral or multilateral convention that provides for mandatory binding arbitration of unresolved issues arising from a mutual agreement procedure case. 2. Nothing in this Article and Articles 25A to 25G shall affect the fulfilment of wider obligations with respect to the arbitration of unresolved issues arising in the context of a mutual agreement procedure resulting from other conventions to which the Contracting States are or will become parties.”.

  • System Logging The system must maintain an automated audit trail which can 20 identify the user or system process which initiates a request for PHI COUNTY discloses to 21 CONTRACTOR or CONTRACTOR creates, receives, maintains, or transmits on behalf of COUNTY, 22 or which alters such PHI. The audit trail must be date and time stamped, must log both successful and 23 failed accesses, must be read only, and must be restricted to authorized users. If such PHI is stored in a 24 database, database logging functionality must be enabled. Audit trail data must be archived for at least 3 25 years after occurrence.