Clause 0. 0.0.00: The Engineer / Employer’s Representative, referred to in the documents, is the Local Municipality of Gamagara acting through a director or an official authorized thereto in writing.
Clause 0. 00.0.0: The percentage advance on materials not yet built into the Permanent Works is 80%, upon proof of ownership.
Clause 0. 00.0.0: In the sixth line, delete the words “.. Of the second half ..”
Clause 0. 0.0.00: The time for achieving practical completion is twenty four (24) weeks, inclusive of the 14-day period referred to in Clause 5.3.2 below, and inclusive of all non-working days referred to in Clause 5.8.1 and special non-working days (Clause 5.8.1). An alternative time for achieving practical completion can be offered in Part 2: Data Provided by Contractor, which will be evaluated as part of adjudication.
Clause 0. 0.0.0: The limit of indemnity for liability insurance is R5 000 000.00 PERIOD OF VALIDITY OF TENDER 60 days from closing date for submission of tenders, excluding builders’ holidays.
Clause 0. 00.0.0: Interim Payments - Materials on Site No percentage advance on materials on site but not yet built into the Permanent Works is allowed for, or will be paid.
Clause 0. 00.0.0: Set-Off and Delayed Payments Replace the words “prime overdraft rate certified by the Contractor’s banker” with the words “interest rate as determined by the Minister of Finance, from time to time, in terms of section 80(1)(b) of the Public Finance Management Act, 1999 (Act No. 1 of 1999), will apply”
Clause 0. 0.0.00: Due Completion Date The time for achieving Practical Completion is 18 months after the Commencement Date. Commencement date for the different sub-projects will be staggered in consultation and agreement with the Employer, and has to take into consideration animal movements out of the enclosures.
Clause 0. 00.0.: Some reasons for extension of time Clause 0.00.0.0: Abnormal climatic conditions. Add the following: Regardless of the cause of any delay an extension of time will only be considered if it can be shown that the activity delayed is on the critical path indicated on the Programme of Works (Clause 5.6.1). No extension of time will be granted in respect of any delays attributed to normal climatic conditions. Normal Climatic Conditions shall be deemed to include normal rainfall and associated wet conditions and materials, strong winds and extremes of temperature. However, in the event that delays to critical activities exceed the number of working days listed below for each month, then abnormal climatic conditions shall be deemed to exist, and an extension of time shall be granted in accordance with the provisions of that Clause. The number of days quoted below shall be regarded as a fair estimate of the delays to be anticipated and allowed for under normal climatic conditions where inclement weather prevents or disrupts work on the critical path. January 3 days May 1 days September 1 days February 6 days June 1 days October 2 days March 7 days July 1 days November 2 days April 5 days August 1 days December 4 days Claims for delays for abnormal climatic conditions shall be accompanied by substantiating facts and evidence, which shall be submitted timeously as each day or half-day delay is experienced. Should an extension of time be granted by the Engineer such extension of time will be added to the Time for Completion. It shall be further noted that where the critical path is not affected, no extension of time for abnormal climatic conditions or for any other reason will be entertained. Rainfall of 10mm or less per day shall be deemed to be normal climatic conditions.
Clause 0. 0.0.0: Insurance The limit of indemnity for liability insurance is R5 000 000.00 for any single claim – the number of claims to be unlimited during the construction. 8.6.1.5 Clause 0.0.0.0: Additional Insurance Additional Insurance is required for the following: a) Where the contract involves manufacturing and/or fabrication of the works or part thereof at premises other than the Site, the Contractor shall satisfy the Employer that all materials and equipment for incorporation in the works are adequately insured during manufacture and/or fabrication. In the event of the Employer having an insurable interest in such works during manufacture or fabrication then such interest shall be noted by endorsement to the Contractor's Policies of Insurance.
