229
229 Sample Clauses
Related to 229
Health, Safety and Security 22.2.1 The University and the Association agree to promote safe, secure and healthy working conditions and procedures, and to encourage Members to adopt and follow sound health, safety and security procedures in the performance of their work.
Pupil Safety and Fingerprinting CONTRACTOR shall comply with all provisions of the Education Code which protect the safety of any pupil that may come in contact with employees of the CONTRACTOR. Pursuant to Education Code section 45125.1, CONTRACTOR shall conduct criminal background checks of ALL employees of CONTRACTOR assigned to the PROJECT site, and shall certify that no employees who have been convicted of serious or violent felonies, as specified in Education Code Section 45125.1, will have contact with pupils, by utilizing the General Certification Regarding Background Checks Form. As part of such certification, CONTRACTOR must provide the District with a list of all employees providing services pursuant to this Agreement, and designate which sites such employees will be assigned. In performing the services set forth in this Agreement, CONTRACTOR shall not utilize any employees who are not included on the above-referenced list. At District’s sole discretion, District may make a finding, as authorized under Education Code section 45125.1, that CONTRACTOR’s employees will have only “limited contact” with pupils. In accordance with Education Code Section 45125.2, a CONTRACTOR performing construction, reconstruction, rehabilitation or repair services to a school facility shall not be required to perform Section 45125.1 background checks of all employees assigned to the PROJECT site if such CONTRACTOR installs a physical barrier at the worksite to limit employee contact with pupils and/or provides continual supervision and monitoring of all employees of the CONTRACTOR by an employee of the CONTRACTOR whom the Department of Justice has ascertained has not been convicted of a violent or serious felony. Such CONTRACTOR shall certify to the District its compliance with one of the aforementioned alternatives under Education Code Section 45125.2 pertaining to pupil safety with the form entitled CONSTRUCTION CONTRACTOR CERTIFICATION REGARDING BACKGROUND CHECKS which is on file at the Administrative Office of the DISTRICT. Contractor’s failure to comply with the law or Article VI, Paragraph 4 of this Agreement shall be considered a material breach of this Agreement upon where this Agreement may be terminated, at District’s sole discretion, without any further compensation to Contractor.
HEALTH, SAFETY AND ENVIRONMENT 41.1 In the performance of this Contract, Contractor and Operator shall conduct Petroleum Operations with due regard to health, safety and the protection of the environment (“HSE”) and the conservation of natural resources, and shall in particular:
ENVIRONMENT, SAFETY AND HEALTH PROTECTION (a) Seller shall perform this Agreement in a manner that ensures adequate protection for workers, the public, and the environment, and shall be accountable for actions of itself and its lower-tier subcontractors, agents and employees. Seller shall exercise a degree of care commensurate with the work and the associated hazards. Seller shall ensure that management of environment, safety and health (ES&H) functions and activities is an integral and visible part of Seller’s work planning and execution process. In the event that Xxxxxx fails to comply with this Agreement, Company may, without prejudice to any other legal or contractual rights, issue an order stopping all or any part of the work; thereafter a start order for resumption of work may be issued at Company’s discretion. Seller shall make no claim for an extension of time or for compensation or damages by reason of or in connection with such work stoppage. In addition, Company may require, in writing, that Seller remove from the work any employee the Company deems unsafe, incompetent, careless, or otherwise objectionable.
Safety and Protection 8.18.1 The Contractor shall be responsible for initiating, maintaining and supervising all safety precautions and programs in connection with the Work. The Contractor shall take all necessary precautions for the safety of, and shall provide the necessary protection to prevent damage, injury or loss to:
Legal Protection 7.14.1 The University shall provide legal representation to any Member of the Bargaining Unit who is named a defendant in a civil action based on performance of the Member’s duties within the scope of employment. Legal representation will be at the Member’s request, subject to the approval of the Ohio Attorney General and in accordance with Ohio law. Pursuant to Ohio Revised Code Section 9.87 the University shall seek indemnification from the state for liability or judgment of any Member of the Bargaining Unit resulting from the performance of his or her duties for the University. Nothing in this Section is intended to expand or conflict with current Ohio law.
Security and Safety A. The Contractor warrants it is and shall remain in compliance with all applicable local, state and federal laws, regulations, codes and ordinances relating to fire, construction, building, health, food service and safety, including but not limited to the Hotel and Motel Fire Safety Act of 1990, Public Law 101-391. The Judicial Council may terminate this Agreement, pursuant to the termination for cause provision set forth herein, without penalty or prejudice if the Contractor fails to comply with the foregoing requirements.
Environmental Protection Except as set forth in Schedule 5.13 annexed hereto:
Workplace Safety and Insurance Act It is understood that payment of income protection is for the sole and only purpose of protecting employees against the loss of income during time of such illness. Seniority and service will accrue and the Employer shall continue to pay its share of the premium for the benefit plans during the period of the income protection noted in this provision.
WORKPLACE SAFETY AND INSURANCE 41.1 Where an employee is absent by reason of an injury or an occupational disease for which a claim is made under the Workplace Safety and Insurance Act, his or her salary shall continue to be paid for a period not exceeding thirty (30) days. If an award is not made, any payments made under the foregoing provisions in excess of that to which he or she is entitled under Articles 44.1 and 44.6 (Short Term Sickness Plan) shall be an amount owing by the employee to the Employer.
